Architect’s Contract definition

Architect’s Contract means Lessee's contract with the Project Architect.

Architect’s Contract means the agreement to be executed by and between Borrower and Architect relating to the design of the Improvements, subject to review and acceptance by Lender, and any and all extensions, renewals, modifications, amendments, supplements and replacements thereto or therefor.

Architect’s Contract mean the architect's contract between Borrower and the architect for the Project.

Examples of Architect’s Contract in a sentence

• Borrower’s Architect shall have duly executed and delivered to Lender a consent to the assignment of the Architect’s Contract, in form and substance satisfactory to Lender, and Lender shall have received a certified copy or a fully executed duplicate original thereof.

• If Borrower’s Architect consists of more than one Person, then each such Person shall deliver a consent to the assignment of the Architect’s Contract in form and substance satisfactory to Lender, and Lender shall have received a certified copy or a fully executed duplicate original thereof.

• Borrower shall enforce the Architect’s Contract in the best interests of Borrower consistent with the construction of the Project Improvements using sound business judgment, (b) waive none of the material obligations of Borrower’s Architect thereunder, (c) do no act which would relieve Borrower’s Architect from its material obligations under the Architect’s Contract and (d) make no amendments to the Architect’s Contract without the prior approval of Lender.

• Borrower shall have furnished Lender with an original Architect’s Certificate, in form and substance reasonably acceptable to Lender, from the Architect relating to the Architect’s Contract for architectural services necessary to construct the Project.

• The Architect’s Contract in form and substance satisfactory to Lender, shall have been duly executed and delivered by the parties thereto, shall be in full force and effect and Lender shall have received a certified copy or a fully executed duplicate original thereof.

More Definitions of Architect’s Contract

Architect’s Contract means the architect’s contract entered into by Owner and Architect providing for the plans, drawings, specifications, contract administration and related materials necessary or appropriate for the construction of the Project.

Architect’s Contract mean the architect's contract between Borrower and Harry Teague Architects, the architect for the Project.

Architect’s Contract means that certain Architectural Services Agreement dated as of December 18, 2015 between Borrower and Architect, as (i) amended by that certain letter agreement, dated as of March 30, 2021, and (ii) may be further amended, supplemented or otherwise modified, from time to time, in accordance with this Agreement or any other contract between Borrower and Architect approved by Lender (which approval shall not be unreasonably withheld, conditioned or delayed).

Architect’s Contract means the agreement dated ___________, [YEAR], by and between Borrower, as owner, and the Architect, as architect, and any other contract for architectural services relating to the development of the Property and/or the construction of the Improvements between Borrower and an architect, and approved in writing by Lender, as the same may be amended from time to time with the prior written approval of Lender.

Architect’s Contract. As defined in Section 1.6.

Architect’s Contract. As defined in Section 3.1.1.

Architect’s Contract means the contract with the Architect with respect to the Project.