Special Damages shall have the meaning as set forth in Section 5.07.
Actual Damages has the meaning set forth in Section 12.4(C).
Cover Damages means, with respect to any Delivery Shortfall, an amount equal to (a) the positive net amount, if, any, by which the Replacement Price exceeds the applicable Price that would have been paid pursuant to Section 5.1 and the Cover Sheet, multiplied by the quantity of that Delivery Shortfall, plus (b) any applicable penalties and other costs assessed by ISO-NE or any other Person against Buyer as a result of Seller’s failure to deliver such Products in accordance with the terms of this Agreement. Buyer shall provide a statement for the applicable period explaining in reasonable detail the calculation of any Cover Damages.
Punitive Damages are those damages awarded as a penalty, the amount of which is neither governed nor fixed by statute.
Consequential Damages means Losses claimed to have resulted from any indirect, incidental, reliance, special, consequential, punitive, exemplary, multiple or any other Loss, including damages claimed to have resulted from harm to business, loss of anticipated revenues, savings, or profits, or other economic Loss claimed to have been suffered not measured by the prevailing Party’s actual damages, and any other damages typically considered consequential damages under Applicable Law, regardless of whether the Parties knew or had been advised of the possibility that such damages could result in connection with or arising from anything said, omitted, or done hereunder or related hereto, including willful acts or omissions.
Limitation of Liability Insert the following Section 15, after Section 14:
Indemnified Damages shall have the meaning assigned to such term in Section 6(a).
Economic damages means objectively verifiable monetary losses, including medical expenses, loss of earnings, burial costs, loss of use of property, cost of replacement or repair, cost of obtaining substitute domestic services, loss of employment, and loss of business or employment opportunities.
Indemnifiable Damages shall have the meaning set forth in Section 9.1 herein.
Daily Delay Damages means with respect to a Guaranteed Project Milestone, an amount equal to (a) the Project Development Security Amount posted as of the first date that Daily Delay Damages are payable under this Agreement with respect to such Guaranteed Project Milestone, divided by (b) 120.
Direct Damage has the meaning given to it in clause 26.2;
Delay Damages means the damages assessed pursuant to Section 3.2(a) hereof.
Seller Damages shall have the meaning given to such term in Section 14.3.
Attorneys’ Fees and Expenses means such funds as may be awarded to Class Counsel by the Court to compensate them (and all other attorneys for Plaintiff or the Settlement Class) for their fees and all expenses incurred by Plaintiff or Class Counsel in connection with the Litigation.
Compensatory Damages are those amounts awarded to compensate for the actual damages sustained, and are not awarded as a penalty, nor fixed in amount by statute.
Attorneys’ Fees means the full and actual cost of any legal services actually performed in connection with the matter involved calculated on the basis of the usual fee charged by the attorney performing such services and shall not be limited to "reasonable attorneys' fees" as defined in any statute or rule of court.
Damages means any loss, claim, damage, liability, costs and expenses (including, without limitation, reasonable attorney's fees and disbursements and costs and expenses of expert witnesses and investigation).
Environmental Damages means all claims, demands, liabilities (including strict liability), losses, damages (including consequential damages), causes of action, judgments, penalties, fines, costs and expenses (including reasonable fees, costs and expenses of attorneys, consultants, contractors, experts and laboratories), of any and every kind or character, contingent or otherwise, matured or unmatured, known or unknown, direct or indirect, foreseeable or unforeseeable, made, incurred, suffered or brought at any time and from time to time and arising in whole or in part from:
Indemnification Obligations means each of the Debtors’ indemnification obligations in place as of the Effective Date, whether in the bylaws, certificates of incorporation or formation, limited liability company agreements, other organizational or formation documents, board resolutions, management or indemnification agreements, or employment or other contracts, for their current and former directors, officers, managers, members, employees, attorneys, accountants, investment bankers, and other professionals and agents of the Debtors.
Indemnification Provisions means each of the Debtors’ indemnification provisions currently in place whether in the Debtors’ bylaws, certificates of incorporation, other formation documents, board resolutions, or contracts for the current and former directors, officers, managers, employees, attorneys, other professionals, and agents of the Debtors and such current and former directors’, officers’, and managers’ respective Affiliates.
Limit of Liability means, with respect to any Insuring Agreement, the limit of liability of the Underwriter for any Single Loss covered by such Insuring Agreement as set forth under the heading “Limit of Liability” in Item 3 of the Declarations or in any Rider for such Insuring Agreement.
Indemnification Obligation means any existing or future obligation of any Debtor to indemnify current and former directors, officers, members, managers, agents or employees of any of the Debtors who served in such capacity, with respect to or based upon such service or any act or omission taken or not taken in any of such capacities, or for or on behalf of any Debtor, whether pursuant to agreement, the Debtors’ respective memoranda, articles or certificates of incorporation or formation, corporate charters, bylaws, operating agreements, limited liability company agreements, or similar corporate or organizational documents or other applicable contract or law in effect as of the Effective Date, excluding any obligation to indemnify any of the foregoing parties with respect to any act or omission for or on behalf of the Debtors arising out of any act or omission determined by a Final Order to constitute actual fraud, willful misconduct, or gross negligence.
Indirect Losses means loss of profits, loss of production, loss of business, loss of business opportunity, or any claim for consequential loss or for indirect loss of any nature;
Attorneys’ Fees and Costs means: (i) fees and out of pocket costs of Lender’s and Loan Servicer’s attorneys, as applicable, including costs of Lender’s and Loan Servicer’s in-house counsel, support staff costs, costs of preparing for litigation, computerized research, telephone and facsimile transmission expenses, mileage, deposition costs, postage, duplicating, process service, videotaping and similar costs and expenses; (ii) costs and fees of expert witnesses, including appraisers; (iii) investigatory fees; and (iv) costs for any opinion required by Lender pursuant to the terms of the Loan Documents.
Resale Damages means, with respect to any Rejected Purchase, an amount equal to (a) the positive net amount, if any, by which the applicable Price that would have been paid pursuant to Section 5.1 hereof for such Rejected Purchase, had it been accepted, exceeds the Resale Price multiplied by the quantity of that Rejected Purchase, plus (b) any applicable penalties assessed by ISO-NE or any other Person against Seller as a result of Buyer’s failure to accept such Products. Seller shall provide a written statement explaining in reasonable detail the calculation of any Resale Damages.