Change in Laws definition

Change in Laws means the occurrence of any of the following after the date of Bid:

AI-Powered Contracts

Draft, Review & Redline at the Speed of AI

Change in Laws means the occurrence of any of the following after the date of Bid: a. the enactment of any new Indian law as applicable to the State; b. the repeal, modification or re-enactment of any existing Indian law as applicable to the State; c. the commencement of any Indian law, as applicable to the State, which has not entered into effect until the date of Bid; and d. a change in the interpretation or application of any Indian law, as applicable to the State, by a judgment of a court of record which has become final, conclusive and binding, as compared to such interpretation or application by a court of record prior to the date of Bid; or any change in the rates of any of the Taxes that have a direct effect on the Project.

Change in Laws. As defined in Section 4.3.

Examples of Change in Laws in a sentence

This change is considered a unilateral change in accordance with Attachment D: HHS Uniform Terms and Conditions; Article XI: General Provisions, Section 11.7, Change in Laws and Compliance with Laws and does not require a bilateral amendment.
This change is considered a unilateral change in accordance to Attachment D: HHS Uniform Terms and Conditions; Article XI: General Provisions, Section 11.7, Change in Laws and Compliance with Laws and does not require a bilateral amendment.
Therefore, Customer agrees that Company is not liable for damages caused by Force Majeure Events, including, but not limited to, acts of God, acts of any governmental authority, including the PUCT or ERCOT, accidents, strikes, labor trouble, required maintenance work, inability to access the TDU or ERCOT system, nonperformance of the TDU or ERCOT, delay or impact of Change in Laws, or any cause beyond Company’s reasonable control.
Builder agrees that subject to the provisions of this Contract {including but not limited to Articles VI (Change in Laws, Rules and Regulations), X (Force Majeure and Permissible Delays), and XIII (Variations)}, or by reason of any default in performance of Buyer or any act of prevention or breach of this Contract by Buyer, it shall make delivery of the completed outfitted and tested Rig on the Delivery Date.
Vietnam shall not create or permit to exist or occur, and shall ensure that no Government Body shall create or permit to exist or occur, any circumstances or Change in Laws of Vietnam which would render obligations under the BOT Contract, the Relevant Project Agreements or the Government Guarantee illegal, invalid, unenforceable, ineffective or void in whole or part.

More Definitions of Change in Laws

Change in Laws means, in South Africa, any implementation, introduction, abolition, withdrawal, or variation of any applicable laws, regulation, published practice, concession, official directive, ruling, notice, announcement (including but not limited to any budget speech) or any change in the interpretation, or any new or further interpretation or different interpretation by any court, governmental, revenue, central bank or other competent authority or compliance with any existing, new or different request, circular, official directive or direction from any government entity, revenue, central bank or other competent authority;

Change in Laws means the occurrence, after the date of this Agreement, of any of the following: (a) the adoption or taking effect of any Applicable Laws, (b) any change in any Applicable Laws or in the administration, interpretation, implementation or application thereof by any Governmental Authority or (c) the making or issuance of any Applicable Laws by any Governmental Authority; provided that notwithstanding anything herein to the contrary, (x) the ▇▇▇▇-▇▇▇▇▇ ▇▇▇▇ Street Reform and Consumer Protection Act and all requests, rules, guidelines or directives thereunder or issued in connection therewith and (y) all requests, rules, guidelines or directives promulgated by the Bank for International Settlements, the Basel Committee on Banking Supervision (or any successor or similar authority) or Canada, the United States or foreign regulatory authorities, in each case pursuant to Basel III, shall in each case be deemed to be a “Change in Laws”, regardless of the date enacted, adopted or issued.

Change in Laws or shall mean a change to a Law, or a change in the interpretation or application of a Law by the cognizant executive or judicial authorities occurring after the date of Seller’s original proposal to Purchaser.

Change in Laws means the occurrence, after the date of this Agreement, of any of the following: (a) the adoption or taking effect of any Applicable Laws, (b) any change in any Applicable Laws or in the administration, interpretation, implementation or application thereof by any Governmental Authority or (c) the making or issuance of any Applicable Laws by any Governmental Authority; provided that notwithstanding anything herein to the contrary, (x) the D▇▇▇-F▇▇▇▇ ▇▇▇▇ Street Reform and Consumer Protection Act and all requests, rules, guidelines or directives thereunder or issued in connection therewith and (y) all requests, rules, guidelines or DOCPROPERTY "DocID" \* MERGEFORMAT 065093/564287 MT MTDOCS 45761290 directives promulgated by the Bank for International Settlements, the Basel Committee on Banking Supervision (or any successor or similar authority) or Canada, the United States or foreign regulatory authorities, in each case pursuant to Basel III, shall in each case be deemed to be a “Change in Laws”, regardless of the date enacted, adopted or issued.

Change in Laws means any addition, amendment, decision, ruling, order, or binding interpretation to or regarding any Laws, by or of a Governmental Authority having jurisdiction or authority, that is enacted, issued, or becomes legally effective after the Effective Date, but excludes any Adverse Governmental Action.

Change in Laws means (a) any binding adoption, promulgation, issuance, modification or change in administrative or judicial interpretation of Laws after the Effective Date (excluding any other Laws relating to Taxes or to the organization, existence, good standing, qualification, or licensing of EPCM-Contractor or its Subcontractors in any jurisdiction) or (b) the imposition of any material condition or requirement (except for any conditions or requirements which result from the acts or omissions of EPCM-Contractor or any Subcontractor) not required as of the Effective Date affecting the issuance, renewal or extension of any Government Approval (excluding any Government Approval relating to the organization, existence, good standing, qualification, or licensing of EPCM-Contractor or its Subcontractors in any jurisdiction), and in each case (a) and (b) above, renders a Party unable, as demonstrated by credible evidence, to perform its respective obligations under this Agreement (excluding payment obligations) or materially increases EPCM- Contractor’s cost to perform its obligations.

Change in Laws means (a) any change in, binding change in the judicial or administrative interpretation of, or adoption of any Laws (excluding any Laws relating to net income Taxes and excluding any Laws relating to the organization, existence, good standing, qualification, or licensing of Owner and Contractor or their Affiliates or Subcontractors in any jurisdiction) which is inconsistent or at variance with any Laws in effect on December 21, 2001, (b) the imposition of any condition or requirement (except for any conditions or requirements which result from the acts or omissions of Contractor or any Subcontractor) not required as of December 21, 2001 affecting the issuance, renewal or extension of any Governmental Approval (excluding any Governmental Approval relating to the organization, existence, good standing, qualification, or licensing of Contractor or its Subcontractors in any jurisdiction), and (c) any amendment, modification or other change in, or binding change in the judicial or administrative interpretation of, the air permit (Authority to Construct) dated June 3, 2004, or the imposition of any condition or requirement (except for any condition or requirement which results from the acts or omissions of Contractor or any Subcontractor) not required as of June 3, 2004.