CHANGE IN SCOPE OF WORK definition

CHANGE IN SCOPE OF WORK. Any change in the scope of the Work, method of performance, nature of materials or price thereof, or any other matter materially affecting the performance or nature of the Work shall not be paid for or accepted unless such change, addition, or deletion is approved in advance and in writing by a valid change order executed by the District. Contractor specifically understands, acknowledges, and agrees that the District shall have the right to request any alterations, deviations, reductions, or additions to the Project or Work, and the cost thereof shall be added to or deducted from the amount of the Contract Price by fair and reasonable valuations. Contractor also agrees to provide the District with all information requested to substantiate the cost of the change order and to inform the District whether the Work will be done by the Contractor or a subcontractor. In addition to any other information requested, Contractor shall submit, prior to approval of the change order, its request for a time extension (if any), as well as all information necessary to substantiate its belief that such change will delay the completion of the Work. If Contractor fails to submit its request for a time extension or the necessary supporting information, it shall be deemed to have waived its right to request such extension.
Sample 1

Examples of CHANGE IN SCOPE OF WORK in a sentence

  • NOTE TO ENGINEER AND CONTRACTOR: ABSOLUTELY NO CHANGE IN SCOPE OF WORK OR INCREASE IN QUANTITIES WILL BE ALLOWED ON THIS PROJECT WITHOUT PRIOR WRITTEN APPROVAL FROM THE TEBM(Transportation Engineering Branch Manager) FOR OPERATIONS OR HIS REPRESENTATIVE IN THE DISTRICT OFFICE.

  • NOTE TO ENGINEER AND CONTRACTOR: ABSOLUTELY NO CHANGE IN SCOPE OF WORK OR INCREASE IN QUANTITIES WILL BE ALLOWED ON THIS PROJECT WITHOUT PRIOR WRITTEN APPROVAL FROM THE DISTRICT PROJECT DELIVERY AND PRESERVATION BRANCH MANAGER.

  • NOTESSLIDE REPAIR PROJECTPage 3 NOTE TO ENGINEER AND CONTRACTOR: ABSOLUTELY NO CHANGE IN SCOPE OF WORK OR INCREASE IN QUANTITIES WILL BE ALLOWED ON THIS PROJECT WITHOUT PRIOR WRITTEN APPROVAL FROM THE TEBM(Transportation Engineering Branch Manager) FOR OPERATIONS OR HIS REPRESENTATIVE IN THE DISTRICT OFFICE.

  • NOTE TO ENGINEER AND CONTRACTOR: THE DEPARTMENT WILL ABSOLUTELY NOT ALLOW ANY CHANGE IN SCOPE OF WORK OR INCREASE IN QUANTITIES ON THE PROJECT WITHOUT PRIOR WRITTEN APPROVAL FROM THE DISTRICT BRANCH MANAGER FOR PROJECT DELIVERY AND PRESERVATION.

  • NOTESSLIDE REPAIR PROJECTPage 3 NOTE TO ENGINEER AND CONTRACTOR: ABSOLUTELY NO CHANGE IN SCOPE OF WORK OR INCREASE IN QUANTITIES WILL BE ALLOWED ON THIS PROJECT WITHOUT PRIOR WRITTEN APPROVAL FROM THE DISTRICT PROJECT DELIVERY AND PRESERVATION BRANCH MANAGER.

  • NOTE TO ENGINEER AND CONTRACTOR: ABSOLUTELY NO CHANGE IN SCOPE OF WORK OR INCREASE IN QUANTITIES WILL BE ALLOWED ON THIS PROJECT WITHOUT PRIOR WRITTEN APPROVAL FROM THE TEBM (Transportation Engineering Branch Manager) FOR OPERATIONS OR HIS REPRESENTATIVE IN THE DISTRICT OFFICE.

  • CHANGE IN SCOPE OF WORK – a modification or amendment that alters the project from what was originally envisioned.

  • CHANGE IN SCOPE OF WORK: Any change in the scope of Services or Work, method of performance, nature of materials or price thereof, or any other matter materially affecting the performance or nature of the Work shall not be paid for or accepted unless such change, addition, or deletion is approved in advance and in writing by a valid change order executed by the District.

  • NOTE TO ENGINEER AND CONTRACTOR: ABSOLUTELY NO CHANGE IN SCOPE OF WORK OR INCREASE IN QUANTITIES WILL BE ALLOWED ON THIS NOTESSLIDE REPAIR PROJECTPage 3 PROJECT WITHOUT PRIOR WRITTEN APPROVAL FROM THE TEBM(Transportation Engineering Branch Manager) FOR OPERATIONS OR HIS REPRESENTATIVE IN THE DISTRICT OFFICE.

  • Xxxxxxx Executive Director of Administration 11/8/2002 10/29/02 ---------------------------- ------------------------------------ Date Date RFP NITRO2 Jan 01-001 January 18, 2001 Proposal for Clinical Trial Services BiDil(R) in the Treatment of Heart Failure CLIENT AUTHORITIES CHANGE IN SCOPE OF WORK The purpose of this notice is to inform NITROMED, INC.

Related to CHANGE IN SCOPE OF WORK

  • Scope of Work means the description of Services and Deliverables specified in the Contract and as may be amended.

  • Scope of Works means the sections of the RFQ detailing the technical requirements of the work to be carried out as existing at the Date of Acceptance of the Quotation and any modification of such Works thereafter directed or the use of which has been permitted by the Superintendent for the purposes of the Contract.

  • Change of Scope Order shall have the meaning set forth in Clause 13.2 (iv); “Completion Certificate” shall have the meaning set forth in Clause 12.2; “Construction” shall have the meaning set forth in Clause 1.2 (f);

  • Project Scope means the description or activity of work to be accomplished on the project.

  • Changes/Extra Work The SUBRECIPIENT shall make no changes to this CONTRACT without the COUNTY’s written consent. In the event that there are new or unforeseen requirements, the COUNTY with the SUBRECIPIENT’s concurrence has the discretion to request official changes at any time without changing the intent of this CONTRACT.

  • Statement of Work means the description of activities performed in completing the Project, as specified in the Contract and as may be amended.

  • Change of Scope Notice shall have the meaning set forth in Clause 13.2 (i); “Change of Scope Request” shall have the meaning set forth in Clause 13.2 (ii); “Change of Scope Order” shall have the meaning set forth in Clause 13.2 (iv); “Completion Certificate” shall have the meaning set forth in Clause 12.2; “Construction” shall have the meaning set forth in Clause 1.2 (f);

  • Work Order means an individually negotiated document that is executed by both Parties and which authorizes a Project, if any, in an indefinite quantity Contract.

  • Scope of Services or “Scope of Work” means the work to be performed by the Proposer or Consultant as described in Section 2.0 of this RFP, as amended thereto.

  • Planned Outage means the removal of equipment from service availability for inspection and/or general overhaul of one or more major equipment groups. To qualify as a Planned Outage, the maintenance (a) must actually be conducted during the Planned Outage, and in Seller’s sole discretion must be of the type that is necessary to reliably maintain the Project, (b) cannot be reasonably conducted during Project operations, and (c) causes the generation level of the Project to be reduced by at least ten percent (10%) of the Contract Capacity.

  • service well means a well drilled or completed for the purpose of supporting production in an existing field. Wells in this class are drilled for the following specific purposes: gas injection (natural gas, propane, butane or flue gas), water injection, steam injection, air injection, salt water disposal, water supply for injection, observation or injection for combustion.

  • Work Plan means a plan that describes each individual activity to be conducted to complete eligible activities and the associated costs of each individual activity.

  • Programme of work means the Programme of work submitted by the contractor and approved by the Engineer-in-charge and includes an amendment thereto made from time to time and approved by the Engineer-in-charge;

  • Cost of work , in table above, shall mean the agreement amount of the work.

  • Scope Change means any change to the scope of a contract to accommodate a need not originally provided for in the contract and which may include the acquisition of additional deliverables or the extension of the term of the contract and which may require an adjustment to the contract price;

  • Completion of work means completion of the entire contracted work. Exhaustion of quantity of any particular item mentioned in the bid document shall not imply completion of work or any component thereof.

  • Project Milestones means the project milestones set forth in Schedule-G;

  • Milestone Schedule means Seller’s milestone schedule, the form of which is attached to this Agreement as Exhibit Q.

  • job work means any treatment or process undertaken by a person on goods belonging to another registered person and the expression “job worker” shall be construed accordingly;

  • Project Plan means the document to be developed by the Contractor and approved by WTL, based on the requirements of the Contract and the Preliminary Project Plan included in the Contractor’s bid. For the sake of clarity, the Agreed and Finalised Project Plan” refers to the version of the Project Plan submitted by the contractor after receiving the letter of Award and the same approved by WTL. The project plan may be changed/ modified during the course of the project. Should the Project Plan conflict with the provisions of the Contract in any way, the relevant provisions of the Contract, including any amendments, shall prevail.

  • Working level (WL) means any combination of short-lived radon daughters in 1 liter of air that will result in the ultimate emission of 1.3E+5 MeV of potential alpha particle energy. The short-lived radon daughters are—for radon-222: polonium-218, lead-214, bismuth-214, and polonium-214; and for radon-220: polonium-216, lead-212, bismuth-212, and polonium-212.

  • Similar Nature of Work means of Delivery and Installation of Zoology Laboratory instruments of Diamond Harbour Women’s University.

  • Extra Work means any work which is determined by City to be necessary for the proper completion of the Project, but which the Parties did not reasonably anticipate would be necessary at the execution of this Agreement. Consultant shall not perform, nor be compensated for, Extra Work without written authorization from City’s Representative.

  • SLA means service level agreement.

  • Project Milestone means the project milestone set forth in Schedule-J;

  • Change Order means a written order to the Contractor signed by the Contracting Officer, issued after execu- tion of the Contract, authorizing a change in the term or scope of the Contract.