Construction Services definition

Construction Services means either of the following for construction-manager-at-risk, design-build and job-order-contracting project delivery methods:

Construction Services. Means construction, repair, renovation or restoration of any work except a vessel and includes; the supply and erection of a prefabricated structure; dredging; demolition; environmental services related to a real property; or, the hire of equipment to be used in or incidentally to the execution of any construction services referred to above.

Construction Services means the implementation and execution of the construction work required by the Contract Documents. The construction phase of the Project may be divided into different stages, each with different start and completion dates.

Examples of Construction Services in a sentence

• The District Contingency shall be utilized for the payment of: (1) any unforeseen costs which are within the scope of work for the Project which are not caused by the acts, errors, or omissions of Contractor; or (2) additional work desired by District pursuant to Section 9 of this Construction Services Agreement (collectively, the "Additional Services").

• Contractor accepts the contractual relationship established between it and District by this Amended Construction Services Agreement, and Contractor covenants with District to furnish its best skill and judgment in constructing the Project as set forth in the Construction Documents.

• All rights and obligations under this Construction Services Agreement shall inure to and be binding upon the successors and assigns of the parties hereto.

• The terms and provisions of this Construction Services Agreement shall be construed in accordance with the laws of the State of California.

• Basis This Contractor Proposal is made as of , 20 , and, if accepted by the Judicial Council in accordance with the Service Work Order Process provision of the Contract, this Contractor Proposal will become an authorized Service Work Order and the Service Work Order will form a part of the Master Contract for Construction Services between the Judicial Council of California and Contractor.

More Definitions of Construction Services

Construction Services means all labor and services necessary for the construction of the Project, and all materials, equipment, tools, supplies, and incidentals incorporated or to be incorporated in such construction as fully described in the Construction Scope of Work set forth in Section 8, below, and Exhibit “A.” Unless otherwise expressly stipulated, Contractor shall perform all work and provide and pay for all materials, labor, tools, equipment, and utilities necessary for the proper execution and completion of the Project.

Construction Services means the coordination, implementation, and execution of the Work required by the Contract Documents.

Construction Services means all labor, services, and materials provided in connection with the construction, alteration, repair, demolition, reconstruction, or any other improvements to real property.

Construction Services means that portion of the Work to be performed during the Construction

Construction Services means the process of planning, acquiring, building, equipping, altering, repairing, improving, or demolishing any structure or appurtenance thereto, including facilities, utilities or other improvements to any real property, excluding highways, roads, bridges, dams, turnpikes or related structures, or stand-alone parking lots.

Construction Services means either of the following for

Construction Services means the work performed by a construction contractor to commence and complete a project;