Lease Completion Date definition

Lease Completion Date. Library and Learning Centre" "Library and Learning Centre Planning Date" "Library and Learning Centre Specification" "Licence to Enter" "Listed Buildings Act" "Local Planning Authority" "London Living Wage"

Lease Completion Date the day that is 10 Working Days after the Practical Completion Date Liaison Process: the process referred to in Clause 16.2 of this Agreement Management Agreement: a community use and management agreement to be entered into simultaneously with the grant of the Lease between the Council and HTH Limited in the form of the draft at Annex 3 or as amended in accordance with Clause M&E Engineer: the mechanical and electrical engineer appointed by the Council, the Architect or the Building Contractor in relation to this Agreement and the Building New Site: the land on which the Building and 00 Xxxxx Xxxxxx are located as is shown edged red on the Site Plan Option: the option in the form of the draft annexed to this Agreement at Annex 4 in favour of HTH Limited to acquire 00 Xxxxx Xxxxxx, Xxxxxxx to be made between the Hitchin Property Trust Limited (1) and HTH Limited (2)

Lease Completion Date shall have the meaning set forth in Section 7.1.6 hereof.

Examples of Lease Completion Date in a sentence

• In no event shall any Lease Completion Date under the Bank One Lease or the Holland & Knight Lease be modified or amended without the prior written consent of the Agent, such consent not to be unreasonably withheld or delayed.

• The Borrower acknowledges that each “Required Segment Delivery Date”, under and as defined in the Bank One Lease, shall constitute a separate Lease Completion Date under this Agreement.

• The Council warrants to HTH Limited that on the Lease Completion Date there shall be no employees of the Council that will transfer to HTH Limited under the provisions of the Transfer of Undertakings (Protection of Employment) Regulations 2006 as a result of the terms of this Agreement.

• The interest shall be payable at the Contract Rate on any unpaid amount for the period from the Lease Completion Date to the date of actual payment.

• The Lease shall be completed at the offices of the Landlord's solicitors (or at such other place as they shall reasonably direct or agree) on the Lease Completion Date.

More Definitions of Lease Completion Date

Lease Completion Date means 10 working days after:- (a) if the LB Depot Condition has been satisfied (or is deemed to have been satisfied) the Practical Completion Date; (b) if the LB Depot Condition has not been satisfied the expiry of the Long Stop Period or in either case, if later, the date the counterpart and the Lease shall be delivered to LUL's Solicitors pursuant to Clause 9.3; and the Lease Completion Date shall also be the "completion date" for the purposes of the Standard Conditions

Lease Completion Date means the date falling Ten (10) Business Days after the Practical Completion Date [OR ANY OTHER DATE AS AGREED BETWEEN THE PARTIES];

Lease Completion Date means the date falling three Business Days after the date upon which:

Lease Completion Date means the date of Completion (as defined in the Sale of Business Agreement) or, if later, on the fifth working day after the date of obtaining the court order referred to in clause 6;

Lease Completion Date means the later of:-

Lease Completion Date means the latest of the tenth Working Day after:-

Lease Completion Date means the latest of the tenth Working Day after:- (a) the date of service of a valid Phase Drawdown Notice in respect of a Phase or Sub-Phase and (b) the date on which the form of the relevant Phase Lease is agreed or determined pursuant to Clause 19 and (c) the date of agreement or determination of the Premium in relation to the Phase or Sub-Phase