Delay Damages means the damages assessed pursuant to Section 3.2(a) hereof.
Damages means any loss, claim, damage, liability, costs and expenses (including, without limitation, reasonable attorney's fees and disbursements and costs and expenses of expert witnesses and investigation).
Direct Damage has the meaning given to it in clause 26.2;
Actual Damages has the meaning set forth in Section 12.4(C).
Compensatory Damages are those amounts awarded to compensate for the actual damages sustained, and are not awarded as a penalty, nor fixed in amount by statute.
Environmental Damages means all liabilities (including strict liability), losses, damages (excluding consequential, special, exemplary or punitive damages except to the extent such damages were imposed upon an Indemnitee as a result of any claims made against such Indemnitee by a governmental entity or any other third party), judgments, penalties, fines, costs and expenses (including fees, costs and expenses of attorneys, consultants, contractors, experts and laboratories), of any and every kind or character, at law or in equity, contingent or otherwise, matured or unmatured, foreseeable or unforeseeable, made, incurred, suffered, brought, or imposed at any time and from time to time, whether before or after the Release Date and arising in whole or in part from:
Special Damages has the meaning specified in Section 11.21.
Economic damages means objectively verifiable monetary losses, including medical expenses, loss of earnings, burial costs, loss of use of property, cost of replacement or repair, cost of obtaining substitute domestic services, loss of employment, and loss of business or employment opportunities.
Punitive Damages are those damages awarded as a penalty, the amount of which is neither governed nor fixed by statute.
Consequential Damages means Losses claimed to have resulted from any indirect, incidental, reliance, special, consequential, punitive, exemplary, multiple or any other Loss, including damages claimed to have resulted from harm to business, loss of anticipated revenues, savings, or profits, or other economic Loss claimed to have been suffered not measured by the prevailing Party’s actual damages, and any other damages typically considered consequential damages under Applicable Law, regardless of whether the Parties knew or had been advised of the possibility that such damages could result in connection with or arising from anything said, omitted, or done hereunder or related hereto, including willful acts or omissions.
Loss or Damage means any loss or damage to the Vehicle, including that caused by theft of the Vehicle or by adverse weather events, that requires repair or replacement including the loss of use of the Vehicle (demurrage), legal expenses, assessment fees, towing and recovery costs, storage, service charges and any appraisal fees of the Vehicle;
Compensable injury means an injury by accident arising out of and in the course of hazardous employment which must be established by medical evidence supported by objective medical findings.
Property damage means physical injury to, destruction of, or loss of use of tangible property.
Seller Damages shall have the meaning given to such term in Section 14.3.
Daily Delay Damages means with respect to a Guaranteed Project Milestone, an amount equal to (a) the Project Development Security Amount posted as of the first date that Daily Delay Damages are payable under this Agreement with respect to such Guaranteed Project Milestone, divided by (b) 120.
Cover Damages means, with respect to any Delivery Failure, an amount equal to (a) the positive net amount, if, any, by which the Replacement Price exceeds the applicable Price that would have been paid pursuant to Section 5.1 hereof, multiplied by the quantity of that Delivery Failure, plus (b) any applicable penalties and other costs assessed by ISO-NE or any other Person against Buyer as a result of Seller’s failure to deliver such Products in accordance with the terms of this Agreement. Buyer shall provide a statement for the applicable period explaining in reasonable detail the calculation of any Cover Damages.
Environmental Damage means any material injury or damage to persons, living organisms or property or any material pollution or impairment of the environment resulting from the discharge, emission, escape or migration of any substance, energy, noise or vibration;
Injury/Injured means a bodily injury caused by an accident occurring while the Insured’s coverage under this Policy is in force and resulting directly and independently of all other causes of Loss covered by this Policy. The injury must be verified by a Physician.
Catastrophic Damage as used hereunder is major change or damage to In- cluded Timber on Sale Area, to Sale Area, to access to Sale Area, or a combination thereof:
Severe property damage means substantial physical damage to property, damage to the treatment facilities which would cause them to become inoperable, or substantial and permanent loss of natural resources which can reasonably be expected to occur in the absence of a bypass. Severe property damage does not mean economic loss caused by delays in production.
Indemnity Obligations means all obligations of the Company to Indemnitee under this Agreement, including the Company’s obligations to provide indemnification to Indemnitee and advance Expenses to Indemnitee under this Agreement.
Serious bodily injury means bodily injury which involves a substantial risk of death, extreme physical pain, protracted obvious disfigurement or protracted loss or impairment of the function of a bodily member, organ or mental faculty.
Indemnified Damages shall have the meaning assigned to such term in Section 6(a).
Serious damage ’ means any specific defect defined in this section; or an equally objectionable variation of any one of these defects, any other defect, or any combination of defects which se- riously detracts from the appearance, or the edible or marketing quality of the fruit. The following specific defects shall be considered as serious damage:
Maximum Liability has the meaning assigned to such term in Section 10.10.
Indemnification Obligations means each of the Debtors’ indemnification obligations in place as of the Effective Date, whether in the bylaws, certificates of incorporation or formation, limited liability company agreements, other organizational or formation documents, board resolutions, management or indemnification agreements, or employment or other contracts, for their current and former directors, officers, managers, members, employees, attorneys, accountants, investment bankers, and other professionals and agents of the Debtors.