Notice of Delay definition

Notice of Delay has the meaning set forth in Paragraph 52.0 (
Sample 1Sample 2Sample 3
Notice of Delay means a written notice of a possible delay which includes details of the possible delay and the cause;
Sample 1Sample 2
Notice of Delay has the meaning given in clause 6.2(d) of the Base Agreement; O&M Services means those operational services and maintenance services to be provided by the Company relating to the Network during the Term as described in Schedule 4 (O&M Services);
Sample 1

Examples of Notice of Delay in a sentence

  • Varnum at the address listed below.(signature page to follow)Respectfully submitted, this the 3rd day of September, 2020, by:Opposer Coastal Carolina Prosthetics, LLC, by and through its attorneys / Thomas G.

  • The Notice of Delay shall indicate the date of commencement of the delay and the date on which the delay terminated and shall include a brief description of the delaying event.

  • E.4 Notice of Delay If the Contractor receives a notice of any change in the work, or if any other conditions arise which are likely to cause or are actually causing delays which the Contractor believes may result in late completion of the project, the Contractor shall notify the Contracting Officer.

  • A TEA fragnet must start with a specific new activity describing the work contained in either a Notice of Delay previously submitted to the Department per Subsection722.64.A - Notice of Delay or an EWO.

  • A Notice of Delay or Proposed Change Order are less formal procedures that proceed the formal claim and do not constitute a Claim.

  • In the event of a delay, the CONTRACTOR shall provide a Notice of Delay within 24 hours of the event, and submit a schedule fragnet depicting the delay with all substantiating documentation within ten (10) days of the event.

  • As explained in the preceding section, only Bering—not the Jinsun Plaintiffs—could have been harmed by a loss of APA rescission rights.The Jinsun Plaintiffs appear to rely on Reneker v.

  • The submission of a revised schedule shall not relieve the Contractor of the responsibility for the notification required by Section 6.22H.2.d of the San Francisco Administrative Code and as required by subparagraph 7.02.D – Notice of Delay of the General Conditions.

  • Contractor recognizes and acknowledges that timely submission of a formal Notice of Delay and a formal Request for Extension, whether or not the circumstances of a Delay may be known to County or available to County through other means, are not mere formalities but are of crucial importance to the ability of County to promptly identify, prioritize, evaluate and mitigate the potential effects of Delay.

  • If the bid tabulation with recommended awards is not posted by said date and time, A "Notice of Delay of Posting" will be posted to inform all bidders of the new posting date and time.


More Definitions of Notice of Delay

Notice of Delay has the meaning set forth in Paragraph 15 (Notice of Delay) of Exhibit A (Additional Terms and Conditions).
Sample 1
Notice of Delay means a formal written notice prepared and submitted by Contractor pursuant to Paragraph 8.2.2, below, notifying County of circumstances that Contractor believes may give rise to a Contract Adjustment to the Contract Time for Excusable Delay or Compensable Delay or a Contract Adjustment to the Contract Price for Compensable Delay.
Sample 1
Notice of Delay has the meaning assigned to such term in paragraph 2 of Appendix G.
Sample 1
Notice of Delay means a formal written notice required to be prepared and submitted by DBE as required below notifying District of circumstances that DBE believes may give rise to a Contract Adjustment to the Contract Time for Excusable Delay or Compensable Delay or a Contract Adjustment to the Contract Sum Payable for Compensable Delay.
Sample 1

Related to Notice of Delay

  • Notice means notice in writing;

  • Cure Notice means a notice of a proposed amount to be paid on account of a Cure Claim in connection with an Executory Contract or Unexpired Lease to be assumed under the Plan pursuant to section 365 of the Bankruptcy Code, which notice shall include: (a) procedures for objecting to proposed assumptions of Executory Contracts and Unexpired Leases; (b) Cure Claims to be paid in connection therewith; and (c) procedures for resolution by the Bankruptcy Court of any related disputes.

  • CAFA Notice refers to the notice requirements imposed by 28 U.S.C. § 1715(b).

  • Notice of Purchase Withdrawal Has the meaning specified in the Deposit Agreement.

  • Rectification Notice means a notice in writing that identifies a defect in a work and requires rectification of the defect within a specified period of time.

  • Notice of Revocation means, in connection with the revocation by a Beneficial Owner or its Agent Member of its Notice of Tender, a notice, substantially in the form attached to the Tender and Paying Agent Agreement, delivered by a Beneficial Owner or its Agent Member to the Tender and Paying Agent indicating an intention to revoke the tender of some or all of the VRDP Shares for sale on a Purchase Date pursuant to Section 1 of Part II of this Statement.

  • Due notice means notice published at least twice, with an interval of at least six days between the two publication dates, in a newspaper or other publication of general circulation within the appropriate area; or, if no such publication of general circulation be available, by posting at a reasonable number of conspicuous places within the appropriate area, suchposting to include, where possible, posting at public places where it may be customary to post notices concerning county or municipal affairs generally. At any hearing held pursuant to such notice, at the time and place designated in such notice, adjournment may be made from time to time without the necessity of renewing such notice for such adjourned dates.

  • Pre-Notice shall have the meaning ascribed to such term in Section 4.13.

  • Notice of Intent means a notice that an environmental impact statement will be prepared and considered. The notice shall briefly:

  • Notice of Tender means, in connection with an Optional Tender, a notice, substantially in the form attached to the Tender and Paying Agent Agreement, delivered by a Beneficial Owner or its Agent Member to the Tender and Paying Agent, indicating an intention to tender VRDP Shares for sale on a Purchase Date pursuant to Section 1 of Part II of this Statement.

  • Notice of Sale means the Notice of Sale of the Trust relating to the sale of the Series 2016A-1 Bonds to be dated on or about May 2, 2016, substantially in the form attached hereto as Exhibit D.

  • Notice of Completion means a document issued by the Department or Delegated Agency at the end of project construction when all items and conditions of the approved Sediment and Stormwater Management Plan have been satisfied, post construction verification documents demonstrate that the stormwater management systems have been constructed in accordance with the approved Sediment and Stormwater Management Plan, and final stabilization of disturbed areas on the site has been achieved.

  • OJEU Notice means the contract notice published in the Official Journal of the European Union.

  • Notice of Breach means a written notice delivered to the other party within the time period required under the definition of “Cause” or “Good Reason,” as applicable, that (a) indicates, as applicable, the specific provision in this Agreement that the party contends the other party has breached or the specific clause of the definition of “Cause” or “Good Reason” that the party alleges to exist, and (b) to the extent applicable, sets forth in reasonable detail the facts and circumstances Executive or the Company, as applicable, claims provide the basis for such breach or other condition.

  • Notice of Renewal has the meaning specified in Section 2.01(b).

  • Requisite Notice means a notice delivered in accordance with Section 10.02.

  • Notice of Extension has the meaning specified in Section 2.20.

  • Election Notice has the meaning set forth in Section 11.01(b).

  • Confirmation Notice means a notice provided by the Issuer to an Investor in accordance with clause 1.3(c) of the Terms;

  • Notice of Default means a written notice of the kind specified in Section 501(4).

  • Nomination Notice means all information and documents that a Nominating Stockholder is required to submit to the Secretary of the Corporation pursuant to Section 1.13(f).

  • Option Notice has the meaning set forth in Section 5.2(a).

  • Completion Notice means a notice issued by the Developer in accordance with clause 6.1.

  • Form of Notice of Conversion means the “Form of Notice of Conversion” attached as Attachment 1 to the Form of Note attached hereto as Exhibit A.

  • Notice of Action shall have the meaning set forth in Section 7.1C.