Other Force Majeure Events definition

Other Force Majeure Events bears the meaning ascribed thereto in Section 16.1(c); “Parties” means both BPDB and the Company;
Sample 1Sample 2Sample 3
Other Force Majeure Events bears the meaning ascribed thereto in Section 11.1(c); “Parties” means the GOB and the Company;
Sample 1Sample 2Sample 3
Other Force Majeure Events bears the meaning ascribed thereto in Section 16.1(c);
Sample 1Sample 2

Examples of Other Force Majeure Events in a sentence

  • The government has signaled some comfort with the pace of rebound in economic activity (despite its expansionary reaction on the fiscal and credit sides following the publication of the 3Q12 GDP figure) and there were no significant surprises in the growth figures.


More Definitions of Other Force Majeure Events

Other Force Majeure Events shall have the meaning ascribed thereto in Clause 9.1.2.
Sample 1Sample 2
Other Force Majeure Events bears the meaning ascribed thereto in Section 14.1(c); “Parties” means both the Gas Supplier and the Company;
Sample 1
Other Force Majeure Events bears the meaning ascribed thereto in Section 16.1(c); “Parties” means, collectively, the Off-Taker and the Company;
Sample 1

Related to Other Force Majeure Events

  • Force Majeure Events means acts of war, domestic and/or international terrorism, civil riots or rebellions, quarantines, embargoes and other similar unusual governmental actions, extraordinary elements of nature or acts of God.

  • Force Majeure Event means an event beyond the affected party’s reasonable control, including (without limitation) accidents, severe weather events, acts of God, actions of any government agency, epidemic, pandemic, acts of terrorism, or the stability or availability of the Internet or a portion thereof.

  • Force Majeure means an event beyond the control of the supplier and not involving the supplier’s fault or negligence and not foreseeable. Such events may include, but is not restricted to, acts of the purchaser in its sovereign capacity, wars or revolutions, fires, floods, epidemics, quarantine restrictions and freight embargoes.

  • Relevant Force Majeure Event means a Force Majeure Event in relation to which an Affected Party is claiming relief under this Clause 17; and

  • Force Majeure Delay means with respect to the Servicer, any cause or event which is beyond the control and not due to the negligence of the Servicer, which delays, prevents or prohibits such Person’s delivery of the reports required to be delivered or the performance of any other duty or obligation of the Servicer under the Indenture, as the case may be, including, without limitation, computer, electrical and mechanical failures, acts of God or the elements and fire; provided, that no such cause or event shall be deemed to be a Force Majeure Delay unless the Servicer shall have given the Indenture Trustee written notice thereof as soon as practicable after the beginning of such delay.

  • Force Majeure Period has the meaning specified in Section 13.1.

  • Force Majeure Report means a report to be given by the Affected Party to the other party following the giving of a Force Majeure Notice;

  • Event of Force Majeure means one of the following events:

  • Force Majeure Notice means a notice to be given by the Affected Party to the other party stating that a Force Majeure Event has occurred;

  • Unplanned Service Interruption means any Service Interruption where events or circumstances prevent the timely communication of prior warning or notice to the Trader or any affected Customer;

  • Service Interruption means, in relation to the supply of electricity to an ICP the cessation of supply to that ICP for a period exceeding the time allowed for interruptions in the relevant Service Standard, other than in accordance with this agreement;

  • Excusable Delay means a delay due to acts of God, governmental restrictions, stays, judgments, orders, decrees, enemy actions, civil commotion, fire, casualty, strikes, work stoppages, shortages of labor or materials or other causes beyond the reasonable control of Borrower, but lack of funds in and of itself shall not be deemed a cause beyond the control of Borrower.

  • Unavoidable Delay means an event which delays Closing which is a strike, fire, explosion, flood, act of God, civil insurrection, act of war, act of terrorism or pandemic, plus any period of delay directly caused by the event, which are beyond the reasonable control of the Vendor and are not caused or contributed to by the fault of the Vendor. “Unavoidable Delay Period” means the number of days between the Purchaser’s receipt of written notice of the commencement of the Unavoidable Delay, as required by paragraph 5(b), and the date on which the Unavoidable Delay concludes.

  • Outage means the state of a component when it is not available to perform its intended function due to some event directly associated with that component. An outage may or may not cause an interruption of service to customers, depending on system configuration.

  • Planned Service Interruption means a Service Interruption that has been scheduled to occur in accordance with Schedule 5;

  • Unavoidable Delays means delays due to any of the following, and only the following, (provided that such delay is beyond Construction Manager’s reasonable control): war, insurrection, civil commotion, strikes, slowdowns, lock outs, riots, flood, earthquakes, fires, casualties, acts of God, acts of a public enemy, acts of terrorism, epidemics, quarantine restrictions, freight embargoes, lack of transportation, governmental moratoriums, unusually severe or abnormal weather conditions, failure of utilities, or a court order which causes a delay (unless resulting from a wrongful act of Construction Manager). In no event shall the application to Construction Manager of any applicable law, regulation, rule or other governmental requirement constitute an Unavoidable Delay. Contractor shall use reasonable good faith efforts to notify Owner not later than five (5) days after Construction Manager knows of the occurrence of an Unavoidable Delay. An extension of time for an Unavoidable Delay shall only be for the period of the Unavoidable Delay, which period shall commence to run from the time of the commencement of the cause of the Unavoidable Delay.

  • Excusable Delays means delays due to acts of terrorism, acts of war or civil insurrection, strikes, riots, floods, earthquakes, fires, tornadoes, casualties, acts of God, labor disputes, governmental restrictions or priorities, embargoes, national or regional material shortages, failure to obtain regulatory approval from any Federal or State regulatory body, unforeseen site conditions, extraordinary rainfall or snowfall, or any other condition or circumstances beyond the reasonable or foreseeable control of the applicable Party using reasonable diligence to overcome which prevents such Party from performing its specific duties or obligation hereunder in a timely manner; provided, however, Excusable Delay does not include lack of financing, unanticipated or unexpected increases in the costs of construction, or errors in business judgment by a Party; and provided further that Excusable Delay shall only extend the time of performance for the period of such Excusable Delay, which shall begin on the date which the event of Excusable Delay first occurs and extend until the date which the event which has caused the Excusable Delay has been corrected or performed, or reasonably should have been corrected or performed.

  • Outages means the planned unavailability of transmission and/or generation facilities dispatched by PJM or the NYISO, as described in Section 35.9 of this Agreement.

  • Essential functions means the fundamental job duties of the employment position the individual with a disability holds or desires. “Essential functions” does not include the marginal functions of the position.

  • Excused Downtime means the number of minutes in the Charging Period, rounded to the nearest minute that the link state of Customer’s Port is ‘down’ due to:

  • Uncontrollable Circumstance means any act, event or condition that is:

  • Excused Outage means any disruption to or unavailability of Services caused by or due to (i) Scheduled Maintenance,