Outside Start Date definition

Outside Start Date. Defined in Section 4.3, Start Date.
Sample 1Sample 2
Outside Start Date means December 31, 2009.
Sample 1Sample 2
Outside Start Date means September 15, 2008.
Sample 1Sample 2

Examples of Outside Start Date in a sentence

  • The “Outside Start Date” means October 1, 2007; provided, however, that the Outside Start Date shall be extended on a day for day basis for each day of Landlord Delay (defined in the Work Letter) that occurs.

  • In consideration for the long-term incentive compensation at your current employer that you are forgoing to accept this offer, subject to you becoming CEO on or before the Outside Start Date, you will be paid a cash amount (“Replacement Cash Amount”) and granted six time-based restricted stock unit awards (“Replacement RSUs”).

  • In consideration for deferred compensation at your current employer that you are forgoing and relocation expenses that you are incurring to accept this offer, subject to you becoming CEO on or before the Outside Start Date, you will be paid a cash amount equal to $1,600,000 within 30 days following the Start Date.

  • In consideration for the 2017 annual incentive compensation at your current employer that you are forgoing to accept this offer, subject to you becoming CEO on or before the Outside Start Date, you will be paid a cash amount equal to $1,225,000.

  • The parties agree that the Contribution Date Passage date shall be extended day for day as a result of any decision by Boyd, made prior to the Outside Start Date, to delay the comxxxxement of construction and/or pre-construction activities of a material portion of Echelon Place (excluding the Hotels, to the extent caused by a breach of Morgans as set forth above) beyond June 30, 2008.

  • The parties agree that the Contribution Date Passage date shall be extended day for day as a result of any decision by Xxxx, made prior to the Outside Start Date, to delay the commencement of construction and/or pre-construction activities of a material portion of Echelon Place (excluding the Hotels, to the extent caused by a breach of Morgans as set forth above) beyond June 30, 2008.

  • Any disputes between the parties as to the date upon which the Substantial Completion Date or the Outside Start Date would have occurred had Tenant Delay(s) or Landlord Delay(s), as applicable, not occurred shall be resolved by means of arbitration pursuant to Section 30.18 of the Lease.

  • Subject to you becoming CEO on or before the Outside Start Date, the Company will pay up to $35,000 on your behalf to your attorney for your legal fees related to this Agreement and the Severance Agreement (the entire amount of which will have been incurred during 2017) on or as soon as administratively practicable following the Start Date, but in no event later than March 15, 2018.

  • Subject to you becoming CEO on or before the Outside Start Date, you will be granted a performance-based restricted stock unit award (the “Performance-Based RSU”) on the first day of the month following the Start Date.

  • The “ New Rent Commencement Date” means the date that is five (5) days (including a weekend) after the earlier to occur of (i) the Substantial Completion Date (defined below) or (ii) the Outside Start Date (defined below).


More Definitions of Outside Start Date

Outside Start Date means September 15, 2008. The following new definition shall be added to the Operating Agreement:
Sample 1
Outside Start Date means January 31, 2010, or such later date as the Authority may approve in its sole and subjective discretion in a written instrument duly executed and delivered by each party hereto.
Sample 1
Outside Start Date means October 1, 2007; provided, however, that the Outside Start Date shall be extended on a day for day basis for each day of Landlord Delay (defined in the Work Letter) that occurs. Any disputes between the parties as to the date upon which the Substantial Completion Date or the Outside Start Date would have occurred had Tenant Delay(s) or Landlord Delay(s), as applicable, not occurred shall be resolved by means of arbitration pursuant to Section 30.18 of the Lease.
Sample 1

Related to Outside Start Date

  • Start Date for Term Calculation Purposes Only: Regardless of actual award/effective date of Contract, for Agreement “term” calculation purposes only, the Agreement “start date” is the last day of the month that Award Notifications are anticipated as published in the Solicitation. Example: If the anticipated award date published in the Solicitation is August 27, 2020 but extended negotiations delay award until September 24, 2020 the end date of the resulting initial “two-year” term Agreement, (which is subject to an extension(s)) will still be August 31, 2022 in this example

  • Service Start Date means the date on which services were first supplied under this Agreement.

  • Commencement Date means the date of this Agreement;

  • Project Start Date means the first Milestone Start Date specified in Schedule B;

  • Supply Start Date means the date(s) specified in clause 2.8;

  • Vesting Commencement Date means the Grant Date or such other date selected by the Committee as the date from which an Award begins to vest.

  • Contract Start Date means the date specified in your Contract for Signature as the date this Contract starts;

  • Services Start Date means the date as set out in the Specification (Schedule 1);

  • Start-up period means up to a maximum of 7 Academy Financial Years and covers the period up to and including the first Academy Financial Year in which all age groups are present at the Academy (that is, all the pupil cohorts relevant to the age-range of the Academy will have some pupils present).

  • Service Commencement Date means the date the Transmission Provider begins to provide service pursuant to the terms of an executed Service Agreement, or the date the Transmission Provider begins to provide service in accordance with Tariff, Part II, section 15.3 or Tariff, Part III, section 29.1.

  • Billing Commencement Date means the earlier of:

  • Services Commencement Date means the date delivery of the Services shall commence as specified in the Key Provisions. If no date is specified in the Key Provisions this date shall be the Commencement Date;

  • Lease Commencement Date means the Closing Date. The “Lease Expiration Date” shall mean the later of (i) the date of the final payment in full of the French Advances and (ii) the Vehicle Lease Expiration Date for the last Lease Vehicle leased by the Lessee hereunder. The “Term” of this Agreement shall mean the period commencing on the Lease Commencement Date and ending on the Lease Expiration Date.

  • Offering Commencement Date means the first day of each Offering Period.

  • the commencement date means the date on which the Contract shall take effect, as notified by the Authority to the Contractor in a letter awarding the Contract.

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • Index Start Date means 19 January 2015.

  • Offer Commencement Date means the date on which Purchaser commences the Offer, within the meaning of Rule 14d-2 under the Exchange Act.

  • Employment Commencement Date means the date on which the Employee first performs an Hour of Service.

  • Anticipated Termination Date Any Distribution Date on which it is anticipated that the Trust Fund will be terminated pursuant to Section 9.01(c) of this Agreement.

  • Project Commencement Date means the commencement date notified to the Minister pursuant to clause 4(1);

  • Construction Commencement Date means the date set out in the Addendum, if applicable, by which you must commence construction of the Hotel. For the Hotel to be considered under construction, youmust have begun to pour concrete foundations for the Hotel or otherwise satisfied any site-specific criteria for “under construction” set out in the Addendum.

  • Transition Period means the period beginning with the Registration Date and ending as of the earlier of: (i) the date of the first annual meeting of stockholders of the Company at which directors are to be elected that occurs after the close of the third calendar year following the calendar year in which the Registration Date occurs; and (ii) the expiration of the “reliance period” under Treasury Regulation Section 1.162-27(f)(2).

  • Recommencement Date As defined in Section 6(d) hereof.

  • Pre commencement condition means a condition imposed on the grant of permission which must be complied with: before any building/ other operation/ or use of the land comprised in the development is begun.

  • Outside Termination Date shall have the meaning set forth in Section 8.01(f).