Time Limits on Claims. Claims by either party must be made within twenty-one (21) days after occurrence of the event giving rise to such Claim or within twenty-one (21) days after the claimant first recognizes the condition giving rise to the Claim, whichever is later. Claims must be made by written notice and include all facts and detailed cost data substantiating the Claim. An additional Claim made after the initial Claim has been implemented by Change Order will not be considered unless submitted in a timely manner.
Time Limits on Claims. The Owner and Design-Builder shall commence all claims and causes of action, whether in contract, tort, breach of warranty or otherwise, against the other, arising out of or related to the Contract in accordance with the requirements of the binding dispute resolution method selected in Section 1.3, within the time period specified by applicable law, but in any case not more than 10 years after the date of Substantial Completion of the Work. The Owner and Design-Builder waive all claims and causes of action not commenced in accordance with this Section 14.1.2.
Time Limits on Claims. The Owner and Contractor shall commence all claims and causes of action, whether in contract, tort, breach of warranty or otherwise, against the other arising out of or related to the Contract in accordance with the time limits provided by law. Nothing herein shall be construed as shortening the period of time Owner has for commencing claims to less than what is required by law.
Time Limits on Claims. The Owner and Contractor shall commence all claims and causes of action against the other and arising out of or related to the Contract in accordance with the requirements of the final dispute resolution method selected in this Agreement whether in contract, tort, breach of warranty, or otherwise, within the period specified by applicable law, but in any case not more than 10 years after the date of Substantial Completion of the Work. The Owner and Contractor waive all claims and causes of action not commenced in accordance with this Section 21.3.
Time Limits on Claims. Claims by Contractor must be made within 21 days after occurrence of the event giving rise to such claim or within 21 days after the claimant first recognizes, or reasonably should have recognized, the condition giving rise to the claim, whichever is the later. An additional claim made after the initial claim has been resolved will not be considered unless submitted in a timely manner.
Time Limits on Claims. Contractor Claims must be made by written notice within 14 days after the occurrence of the event giving rise to such Claim or within 14 days after the Contractor would have reasonably first recognized the condition giving rise to the Claim, whichever is later. Claims for additional time and additional compensation must be made in accordance with the conditions of this Article. Such written notice of Contractor Claims shall be complete. Written notice which is incomplete and only partially identifies a claim, with wording such as ‟(time or cost) impact to be determined at a later date” or ‟we reserve the right to claim additional (time or cost) at a later date” will not be considered.
Time Limits on Claims. Claims shall be made within sixty (60 ) days after occurrence of the event giving rise to such Claim or within 60 days after the claimant first recognizes the condition giving rise to the Claim, whichever is later. Claims shall be made by written notice to the Authority and shall be fully documented. The failure to give notice of any Claim in accordance with the foregoing shall constitute waiver of such Claim.
Time Limits on Claims. Except as provided in Subparagraph 6.2.6 below, and except for Claims asserted by the Authority, Claims by any Person that are discovered during the performance of the Trade Contractor Work must be made within twenty-one
Time Limits on Claims. Except as otherwise provided in this Section 9.5, the representations and warranties of each of the parties hereto set forth in this Agreement or in any certificate delivered by any party hereto at the Closing shall survive the Closing until the Expiration Date, at which time they shall expire and be of no further force and effect; provided, however, that (a) the representations and warranties set forth in Sections 3.1 (Organization), 3.2 (Authorization), 3.5 (Ownership of the Shares), and 3.7 (Brokers); Sections 4.1 (Organization; Qualification), 4.2 (Authorization), 4.5(a) (Capitalization; Ownership), 4.6 (Subsidiaries), and 4.25 (Brokers); and Sections 5.1 (Organization), 5.2 (Authorization), and 5.6 (Availability of Funds; Solvency) (collectively, the “Fundamental Representations”) shall survive indefinitely and (b) the representations and warranties in Section 4.19 (Tax Matters) (the “Tax Representations”) shall survive until the 60th day after the expiration of the statute of limitations (including any extensions or tolling thereof) applicable thereto, at which time such representations and warranties shall expire and be of no further force and effect. All covenants and agreements of the parties contained herein shall survive the Closing indefinitely or for the period explicitly specified therein; provided that covenants to be fully performed at or prior to the Closing shall expire upon the occurrence of the Closing. Notwithstanding the preceding portion of this Section 9.5, any claim relating to the breach of a representation, warranty, covenant or agreement set forth herein that is asserted in writing pursuant to Section 9.4 prior to the applicable survival end date described above shall survive until such claim is finally resolved and satisfied in accordance with this Article IX. Notwithstanding anything herein to the contrary, the applicable survival end date set forth in this Section 9.5 shall be tolled during the time in which Purchaser is using its commercially reasonable efforts to recover under the R&W Policy pursuant to Section 9.6(b)(ii)(B).
Time Limits on Claims. Except as provided in Subparagraph 6.2.6 below, and except for Claims asserted by the Authority, Claims by any Person that are discovered during the performance of the Trade Contractor Work must be made within twenty-one (21) Days after occurrence of the event giving rise to such Claim or within twenty-one (21) Days after the claimant first recognizes the condition giving rise to the Claim, whichever is later, or said Claim shall be deemed waived. In addition to the foregoing, as soon as the claimant recognizes the conditions giving rise to the Claim, claimant shall provide notice of such conditions to the Authority, and shall use its best efforts to cooperate with the Authority and the Party against whom the Claim is made in any effort to mitigate the alleged or potential damages, delay, or other adverse consequences arising out of the condition which is the cause of such a Claim. Any additional Claim related to the initial Claim that is made after the initial Claim has been adjusted and dealt with by Contract Revision will not be considered. Claims may also be reserved in writing within the time limits set forth in this Subparagraph 6.2.3. If a Claim is reserved, the Resolution of Claims and Disputes procedures described in Paragraph 6.3 and Paragraph 6.4 hereof shall not commence until a written notice from the claimant is received by the Authority. Any notice of Claim or reservation of Claim must clearly identify the alleged cause and the nature of the Claim and include data and information then available to the claimant that will facilitate prompt verification and evaluation of the Claim, and it shall be assumed that the Authority has been prejudiced if it does not receive said information.
