Unavoidable Delays means delays due to any of the following, and only the following, (provided that such delay is beyond Construction Manager’s reasonable control): war, insurrection, civil commotion, strikes, slowdowns, lock outs, riots, flood, earthquakes, fires, casualties, acts of God, acts of a public enemy, acts of terrorism, epidemics, quarantine restrictions, freight embargoes, lack of transportation, governmental moratoriums, unusually severe or abnormal weather conditions, failure of utilities, or a court order which causes a delay (unless resulting from a wrongful act of Construction Manager). In no event shall the application to Construction Manager of any applicable law, regulation, rule or other governmental requirement constitute an Unavoidable Delay. Contractor shall use reasonable good faith efforts to notify Owner not later than five (5) days after Construction Manager knows of the occurrence of an Unavoidable Delay. An extension of time for an Unavoidable Delay shall only be for the period of the Unavoidable Delay, which period shall commence to run from the time of the commencement of the cause of the Unavoidable Delay.
Unavoidable Delays means delays due to strikes, lockouts, power failure, acts of God, governmental restrictions, enemy action, civil commotion, fire, unavoidable casualty or other causes beyond the control of the party responsible for performing an obligation hereunder, PROVIDED THAT lack of funds shall not be deemed a cause beyond the control of either party hereto unless such lack of funds is caused by the failure of the other party hereto to perform any obligations of such party under this Lease.
Unavoidable Delays means delays beyond the reasonable control of the party seeking to be excused, which are the direct result of strikes, other labor troubles, weather, fire, or other casualty to the Minimum Improvements or Site Improvements, litigation commenced by third parties which, by injunction or other similar judicial action, results in delays, or acts of any federal, state or local governmental unit (other than the EDA in exercising its rights under this Agreement) that result in delays.
Examples of Unavoidable Delays in a sentence
Until Final Completion of the Project, Tenant will always prosecute construction of the Project (and, for purposes of this clause, “prosecute construction of the Project” will include actions necessary to obtain construction financing) with reasonable diligence and continuity (subject to Unavoidable Delays) in accordance with the then applicable Project Schedule.
Any further delay in Final Completion resulting from Unavoidable Delays that occur after the 2.06 Termination Notice is sent will not be counted against the 90 days to achieve Final Completion.
The Developer agrees and commits to the City that construction of the Development shall be substantially complete by August 31, 2025, subject to Unavoidable Delays.
Tenant, whether or not the award or awards, if any, will be sufficient for the purpose will (subject to Unavoidable Delays) proceed diligently to Restore any remaining part of the Project not so taken so that the latter will be complete, operable and in good condition and repair in conformity with the requirements of Section 8.01.
All Construction Work, once commenced, will be completed within the time periods required in this Lease (subject to Unavoidable Delays), in a good and workmanlike manner and, with respect to Construction Work for which this Lease requires Tenant to prepare plans and specifications, in substantial accordance with such plans and specifications, and all Applicable Laws.
More Definitions of Unavoidable Delays
Unavoidable Delays shall have the meaning set forth in Article 25 hereof.
Unavoidable Delays means delays due to acts of God, government restrictions, stays, judgments, orders, decrees, enemy actions, acts of terrorism, civil commotion, fire, casualty, strikes, work stoppages, shortages of labor or materials, or other causes beyond the reasonable control of Borrower; provided that the lack or insufficiency of funds shall not constitute an Unavoidable Delay.
Unavoidable Delays. Delays due to strikes, lockouts, inability to procure materials, power failure, acts of God, governmental restrictions, enemy action, civil commotion, fire, unavoidable casualty or other causes beyond the control of the party responsible for performing an obligation hereunder, provided that lack of funds shall not be deemed a cause beyond the control of either party hereto unless such lack of funds is caused by the failure of the other party hereto to perform any obligations of such party, under this Lease, or any guaranty of this Lease, including any obligation to provide financing undertaken by Lessor pursuant to ARTICLE X below.
Unavoidable Delays means (i) with respect to Tenant or its obligations hereunder, delays incurred by Tenant due to strikes, lockouts, work stoppages due to labor jurisdictional disputes, acts of God, inability to obtain labor or materials due to governmental restrictions, enemy action, civil commotion, fire, unavoidable casualty, unseasonably adverse weather conditions, or other similar causes beyond the control of Tenant (but not including Tenant’s insolvency or financial condition or the availability or applicability of insurance proceeds or condemnation awards), and (ii) with respect to the FCRHA or its obligations hereunder, delays incurred by the FCRHA due to strikes, lockouts, work stoppages due to labor jurisdictional disputes, acts of God, inability to obtain labor or materials due to governmental restrictions (other than any governmental restrictions imposed by the FCRHA, in its governmental or regulatory capacity), enemy action, civil commotion, fire, unavoidable casualty, unseasonably adverse weather conditions, or other similar causes beyond the control of the FCRHA (but not including the FCRHA’s insolvency or financial condition); in each case provided (x) such party shall have notified the other party reasonably promptly after such party knows or should have known of the occurrence of same and the effects of which a prudent Person in the position of the party asserting such delay could not have reasonably prevented and (y) such party takes reasonable steps to minimize the impact of such event upon the performance in question and keeps the other party reasonably informed, upon request, of the nature of the steps so taken and of the progress of the performance which is subject to Unavoidable Delay.
Unavoidable Delays means delays beyond the reasonable control of the party seeking to be excused as a result thereof which are the direct result of strikes, other labor troubles, prolonged adverse weather or acts of God, fire or other casualty to the Minimum Improvements, litigation commenced by third parties which, by injunction or other similar judicial action, directly results in delays, or acts of any federal, state or local governmental unit (other than the Authority in exercising its rights under this Agreement) which directly result in delays.
Unavoidable Delays means delays caused by war, riot, civil commotion, strikes, labor action, acts of God, force majeure, shortages of supplies or labor, adverse weather condition not reasonably anticipatable given the location of a Property and the season of year, or any other cause not reasonably within the control of Lessee but excluding the financial condition of the Lessee.
Unavoidable Delays means delays beyond the reasonable control of the party seeking to be excused as a result thereof which are the direct result of strikes, other labor troubles, prolonged adverse weather or acts of God, fire or other casualty to the Project, litigation commenced by third parties which, by injunction or other similar judicial action, directly results in delays, or acts of any federal, state or local governmental unit (other than the City or the County in exercising their rights under this Agreement) which directly result in delays. Unavoidable Delays shall not include delays in the Developer’s obtaining of permits or governmental approvals necessary to enable construction of the Project by the dates such construction is required under Section 4.2 of this Agreement.