Work Progress Schedule definition

Work Progress Schedule means the continually updated time schedule prepared and monitored by Contractor that accurately indicates all necessary appropriate revisions as required by the conditions of the Work and the Project while maintaining a concise comparison to the Baseline Schedule.

Work Progress Schedule means the continually updated time schedule prepared and monitored by Contractor that accurately indicates all necessary appropriate revisions as required by the conditions of the Work and the Project while maintaining a concise comparison to the Baseline Schedule. (Remainder of Page Intentionally Left Blank)

Work Progress Schedule or “WPS” shall have the meaning given in Paragraph 5.3.1.

Examples of Work Progress Schedule in a sentence

• Contractor shall submit electronic and paper copy of the initial Work Progress Schedule reflecting accurate and reliable representations of the planned progress of the Work, the Work to date if any, and of Contractor’s actual plans for its completion.

• Contractor shall update the Work Progress Schedule and the Submittal Register monthly, as a minimum, to reflect progress to date and current plans for completing the Work, while maintaining original schedule as Baseline Schedule and submit electronic copies of the update to Owner and Architect as directed, but as a minimum with each request for payment.

• Contractor may revise the Work Progress Schedule when in Contractor’s judgment it becomes necessary for the management of the Work.

• Unless indicated otherwise, the Work Progress Schedule shall be computerized Critical Path Method (CPM) with fully editable logic.

• Owner has no duty to make progress payments unless accompanied by the updated Work Progress Schedule.

More Definitions of Work Progress Schedule

Work Progress Schedule has the same meaning as defined in UGC Section 1.49.

Work Progress Schedule means the continually updated time schedule prepared and monitored by Contractor that coordinates and integrates activities of the Project, including Contractor’s services, Design Professional’s services, the work of other consultants, suppliers, and Owner’s activities with the anticipated construction schedules for other contractors. The Work Progress Schedule accurately indicates all necessary and appropriate revisions, including a Longest Path impact analysis, as required by the conditions of the Work and the Project while maintaining a concise comparison to the Baseline Schedule.

Work Progress Schedule means the continually updated time schedule prepared and monitored by Contractor that accurately indicates all necessary and appropriate revisions, including a critical path impact analysis, as required by the conditions of the Work and the Project while maintaining a concise comparison to the Baseline Schedule.

Work Progress Schedule means the schedule prepared and maintained in accordance with the Critical Path Method and the requirements of the Special Conditions, if any, and the UGC, for design and construction of the Project, reflecting the CMR’s actual progress of the construction of the Work and the scheduled activities and current plans for completing the Work. The Work Progress Schedule may subsequently modified by mutual agreement between TFC and CMR to reflect any refinement in its requirements.

Work Progress Schedule means the CPM Schedule prepared and maintained in accordance with the Critical Path Method and the requirements of the Agreement, the Special Conditions (if any), and the UGC, reflecting the Contractor’s actual progress of the construction of the Work and the scheduled activities and current plans for completing the Work and updated as required in Paragraph 7.3.

Work Progress Schedule means the continually updated time schedule prepared and monitored by Contractor that accurately indicates all necessary appropriate revisions as required by the conditions of the Work and the Project while maintaining a concise comparison to the Baseline Schedule. Article 2. Wage Rates and Other Laws Governing Construction

Work Progress Schedule means the timeline for completion of each principal category of the Work for achieving Substantial Completion of the Facility by the Contract Completion Date. The Work Progress Schedule is attached hereto as Exhibit B.