Litigation and Unilateral Commencement of Arbitration Notwithstanding the foregoing provisions of this Article VII, (a) a Party may seek preliminary provisional or injunctive judicial relief with respect to a Dispute without first complying with the procedures set forth in Section 7.1, Section 7.2 and Section 7.3 if such action is reasonably necessary to avoid irreparable damage and (b) either Party may initiate arbitration before the expiration of the periods specified in Section 7.2 and Section 7.3 if (i) such Party has submitted a Mediation Request or Arbitration Request, as applicable, and the other party has failed, within the applicable periods set forth in Section 7.3, to agree upon a date for the first mediation session to take place within thirty (30) days after the appointment of such mediator or such longer period as the Parties may agree to in writing or (ii) such Party has failed to comply with Section 7.3 in good faith with respect to commencement and engagement in arbitration. In such event, the other Party may commence and prosecute such arbitration unilaterally in accordance with the CPR Arbitration Procedure.
Commencement The term of the Company shall commence upon the filing of the Certificate of Formation with the Secretary of State.
COMMENCEMENT AND TERMINATION 10.1 This Agreement shall be effective as of the date hereof and shall continue in force until terminated in accordance with the provisions herein.
Commencement of Work Upon Contractor’s receipt from Owner of the limited notice to proceed (“Limited Notice to Proceed” or “LNTP”), Contractor shall promptly commence with the performance of the portion of the Work specified in such LNTP; provided that the Parties have executed a Change Order defining the LNTP Work. The LNTP shall be issued in the form attached hereto as Attachment H, Schedule H-1. Contractor shall not, and shall not be obligated to, commence performance of such Work until receipt from Owner of such LNTP.
Commencement of the Offer Provided that this Agreement shall not have been terminated in accordance with Article 9, as promptly as practicable after the Agreement Date (but in no event more than ten (10) Business Days after the Agreement Date), Purchaser shall (and Parent shall cause Purchaser to) commence (within the meaning of Rule 14d-2 under the Exchange Act) the Offer.
Mediation If the Requesting Party selects mediation for dispute resolution:
Commencement and Term This Agreement shall commence upon the Effective Date and continue for the Agreement Term.
Lease Commencement Notwithstanding anything contained herein to the contrary, if Lessor, for any reason whatsoever, including Lessor's negligence except as provided for in Article 27(b), cannot deliver possession of the Premises, as provided for in Article 27(a), to Lessee at the commencement of the agreed Term as set forth in Article 2, this Lease shall not be void or voidable, nor shall Lessor be liable to Lessee for any loss or damage resulting therefrom, but in that event, the Term shall be for the full term as specified above to commence from and after the date Lessor shall have delivered possession of the Premises to Lessee or from the date Lessor would have delivered possession of the Premises to Lessee but for Lessee's failure to timely supply to Lessor such drawings and/or information required by Exhibit C or for any other reason attributable to Lessee (herein the "Commencement Date") and to expire midnight of the day immediately preceding Term anniversary of the Commencement Date, and if requested by Lessor, Lessor and Lessee shall, ratify and confirm said Commencement and Expiration Dates by completing and signing Exhibit G attached hereto and made a part hereof.
Adjustment of Commencement Date; Possession 3.01 If Landlord is required to perform Landlord Work prior to the Commencement Date: (a) the date set forth in Section 1.06 as the Commencement Date shall instead be defined as the “Target Commencement Date”; (b) the actual Commencement Date shall be the date on which the Landlord Work is Substantially Complete (defined below); and (c) the Termination Date will the last day of the Term as determined based upon the actual Commencement Date. Landlord’s failure to Substantially Complete the Landlord Work by the Target Commencement Date shall not be a default by Landlord or otherwise render Landlord liable for damages. Promptly after the determination of the Commencement Date, Landlord and Tenant shall enter into a commencement letter agreement in the form attached as Exhibit D. If the Termination Date does not fall on the last day of a calendar month, Landlord and Tenant may elect to adjust the Termination Date to the last day of the calendar month in which Termination Date occurs by the mutual execution of a commencement letter agreement setting forth such adjusted date. The Landlord Work shall be deemed to be “Substantially Complete” on the date that all Landlord Work has been performed, other than any details of construction, mechanical adjustment or any other similar matter, the non-completion of which does not materially interfere with Tenant’s use of the Premises. If Landlord is delayed in the performance of the Landlord Work as a result of the acts or omissions of Tenant, the Tenant Related Parties (defined in Section 13) or their respective contractors or vendors, including, without limitation, changes requested by Tenant to approved plans, Tenant’s failure to comply with any of its obligations under this Lease, or the specification of any materials or equipment with long lead times (a “Tenant Delay”), the Landlord Work shall be deemed to be Substantially Complete on the date that Landlord could reasonably have been expected to Substantially Complete the Landlord Work absent any Tenant Delay.
Arbitration Hearing An Arbitration Hearing will be held within thirty (30) days after the Administrative Conference if no discovery is taken, or within thirty (30) days after the close of discovery, unless all parties and the Panel agree to extend the Arbitration Hearing date, or unless the parties agree in writing to waive the Arbitration Hearing. The parties may mutually agree on the location of the Arbitration Hearing. If the parties fail to agree, the Arbitration Hearing shall be held in Chicago, Illinois, or at such other location determined by the Presiding Arbitrator to be most convenient to the participants. The Panel will determine the date(s) and time(s) of the Arbitration Hearing(s) after consultation with all parties and shall provide reasonable notice thereof to all parties or their representatives.
