Injury or Damage to Person or Property If either party suffers injury or damage to person or property because of an act or omission of the other party, or of others for whose acts such party is legally responsible, written notice of such injury or damage, whether or not insured, shall be given to the other party within a reasonable time not exceeding twenty-one (21) calendar days after discovery. The notice shall provide sufficient detail to enable the other party to investigate the matter.
Damage to Personal Property The Employer will provide reimbursement for reasonable repair or replacement of damages incurred to the employee's eyeglasses, contact lenses or other prosthesis, ripped uniforms, or personal clothing, as a result of being assaulted while performing his/her work. The employee must report the incident by the end of their shift. The employee will present her or his receipt to the Employer within seven (7) days after the event, unless it was impossible for her or him to do so during this period. The Employer will reimburse up to a maximum of one hundred dollars ($100) per incident except for eyeglasses, which shall have a maximum reimbursement of three hundred dollars ($300).
No Indirect Damages No Participant shall be liable to any other Participant for any indirect or consequential loss or similar damage such as, but not limited to, loss of profit, loss of revenue or loss of contracts, regardless of whether such liability arises from a claim based in contract, warranty, tort or otherwise, provided such damage was not caused by a wilful act, gross negligence or by a breach of confidentiality.
Incidental and Consequential Damages Contractor shall be responsible for incidental and consequential damages resulting in whole or in part from Contractor’s acts or omissions. Nothing in this Agreement shall constitute a waiver or limitation of any rights that City may have under applicable law.
No Consequential Damages Other than the Liquidated Damages heretofore described and the indemnity obligations set forth in Article 18.1, in no event shall any Party be liable under any provision of this Agreement for any losses, damages, costs or expenses for any special, indirect, incidental, consequential, or punitive damages, including but not limited to loss of profit or revenue, loss of the use of equipment, cost of capital, cost of temporary equipment or services, whether based in whole or in part in contract, in tort, including negligence, strict liability, or any other theory of liability; provided, however, that damages for which a Party may be liable to another Party under separate agreement will not be considered to be special, indirect, incidental, or consequential damages hereunder.
Responsibility For Damages Or Injury The County its elected and appointed officials, officers, employees, agents and those special districts and agencies which County’s Board of Supervisors acts as the governing Board (“County Indemnitees”) shall not be answerable or accountable in any manner: for any loss or damage that may happen to the Project or any part thereof; for any loss or damage to any of the materials or other things used or employed in performing the Project; for injury to or death of any person either workers or the public; or for damage to property from any cause which might have been prevented by the Contractor, or his workers, or anyone employed by him. The Contractor shall be responsible for any liability imposed by law and for injuries to or death of any person or damage to property resulting from defects or obstructions or from any cause whatsoever during the progress of the Project or at any time before its completion and final acceptance. The Contractor shall indemnify, defend with counsel approved in writing by County and save harmless the County Indemnitees from all claims, suits or actions of every name, kind and description, brought for, or on account of, injuries to or death of any person or damage to property resulting from the construction of the Project or by or in consequence of any negligence in guarding the Project; use of improper materials in construction of the Project; or by or on account of any act or omission by the Contractor or his agents during the progress of the Work or at any time before the completion and final acceptance of the Project. In addition to any remedy authorized by law, so much of the money due the Contractor under and by virtue of the Contract as shall be considered necessary by the County may be retained by it until disposition has been made of such suits or claims for damages as aforesaid. If judgment is entered against Contractor and County by a court of competent jurisdiction because of the concurrent active negligence of County and County Indemnitees, Contractor and County agree that liability will be apportioned as determined by the court. Neither Party shall request a jury apportionment. Notwithstanding anything stated above, nothing contained herein shall relieve Contractor of any insurance requirements of obligations created elsewhere in this Contract.
NO LIABILITY FOR CONSEQUENTIAL DAMAGES In no event shall either Party be liable to the other Party for, and no arbitral panel is authorized to award, any punitive, special, indirect or consequential damages of any kind or character resulting from or arising out of this Agreement, including, without limitation, loss of profits or business interruptions, however they may be caused.