Engineer-in-charge. The expression Engineer or Engineer-in-charge as used in the tender paper shall mean the Engineer-in-charge of the work
Engineer-in-charge. Engineer Engineer-In-Charge (EIC) or Engineer means the Employers personnel authorized to direct, supervise and be in-charge of the works on behalf of the Employer.
Engineer-in-charge. The Engineer-in-charge shall have general supervision and direction of the work. He has authority to stop the work whenever such a stoppage may be necessary to ensure the proper execution of the contract. He shall also have authority to reject all work which directs the application of forces to any portion of the work as in his judgment is required and order force increased or diminished and to decide disputes, which arise in the execution of the work. The Engineer-in-charge reserves the right to suspend the work of the part thereof at any time and no claim whatsoever on this account will be entertained. In case of any dispute the contractor may appeal to the Engineer-in-charge whose decision shall be final and binding.
Engineer-in-charge. The ‘Engineer-in-charge’ means the Group Head, CMG/ Head CMD/ Engineer-SG/ Engineer-SF/ Engineer-SE/ Engineer-SD, as the case may be, or the appropriate competent authority declared by the Government who shall supervise and be in charge of the work and who shall sign the contract on behalf of the President.
Engineer-in-charge. 26.1 Engineer in charge A senior level officer of the Authority shall be appointed by the Authority as the ‘Engineer in charge’ to act as its authorised representative for the purpose of administration and supervision of the Project (“Engineer in charge”). The appointment shall be made no later than 90 (ninety) days from the date of this Agreement. It is hereby clarified that the Engineer in charge shall always be appointed by the Authority from among its employees/officers. The Engineer in chargeshall be responsible for supervising and administering the Agreement, certifying payment due to the Mine Operator, valuing variations to the Agreement, awarding extension of time and valuing compensation events. The Engineerincharge may, on its behalf, further appoint itsrepresentativesi.e.,Project manager/any other competent person for carrying out its functions as specified herein and notify to the Mine Operator / Contractor, who is directly responsible for supervising the work being executed at the Site, regarding such appointment of its representatives. However, the Engineer in charge shall at all times be responsible and liable for its obligations, duties and responsibilities under this Agreement.
Engineer-in-charge. 19 6.1 Appointment of Engineer-in-Charge 19
Engineer-in-charge. The Engineer In-Charge shall have general supervision and direction of the work. He has authority to stop the work whenever such a stoppage may be necessary to ensure the proper execution of the contract. He shall also have authority to reject all work, direct the application of forces to any portion of the work as, in his judgment, is required and order force increased or diminished and to decide disputes which arise in the execution of the work. The Engineer In-Charge reserves the right to suspend the work or the part thereof at any time and no claim whatsoever on this account will be entertained. In case of any dispute the Contractor may appeal to the Engineer In-Charge whose decision shall be final and binding. The decision of the Engineer In-Charge of Ramagundam Fertilizers & Chemical Limited shall be final in regard to all matters relating to this tender including for determining the category of work with reference to material of an item not mentioned in the Scope of Work.
Engineer-in-charge. For Air-conditioning & Refrigeration/Electrical items of work Executive Engineer, Institute Works Department IIT, Kanpur
Engineer-in-charge. Concerned Divisional Head / authorized Engineer of the NESCO Utility shall be the Engineer in charge for the Project.
Engineer-in-charge. DM/AM (Elect.Maint), works Division, NSIC Ltd, New Delhi will acts as Engineer-In-Charge. Thanking you, Yours truly X.X. Xxxxx Manager (Works) Annexure-“A” Schedule of items, quantities and price S. No. Description Unit Qty Rates (Rs.) Amount ( Rs.)
