No Force Majeure. To the Knowledge of the Borrower, no event of force majeure or other event or condition exists which (a) provides any Material Project Party the right to cancel or terminate any Material Project Document to which it is a party in accordance with the terms thereof, which cancellation or termination could reasonably be expected to have a Material Adverse Effect, or (b) provides any Material Project Party the right to suspend its performance (or be excused of any liability) under any Material Project Document to which it is a party in accordance with the terms thereof, which suspension (or excuse) could reasonably be expected to (x) result in the Project failing to achieve (A) the Train 1 DFCD under and as defined in the BG FOB Sale and Purchase Agreement on or before the BG DFCD Deadline, (B) the Date of First Commercial Delivery under and as defined in the GN FOB Sale and Purchase Agreement on or before the GN DFCD Deadline, (C) the Date of First Commercial Delivery under and as defined in the KoGas FOB Sale and Purchase Agreement on or before the KoGas DFCD Deadline, (D) the Date of First Commercial Delivery under and as defined in the GAIL FOB Sale and Purchase Agreement on or before the GAIL DFCD Deadline, (E) the Date of First Commercial Delivery under and as defined in the Centrica FOB Sale and Purchase Agreement on or before the Centrica DFCD Deadline, or (F) the Date of First Commercial Delivery under and as defined in the Total FOB Sale and Purchase Agreement on or before the Total DFCD Deadline, or (y) materially impair the expected revenues of the Borrower under the FOB Sale and Purchase Agreements.
No Force Majeure. As of the Closing Date, no event of force majeure or other event or condition exists which (a) provides any Material Project Party the right to cancel or terminate any Material Project Document to which it is a party in accordance with the terms thereof or (b) provides any Material Project Party the right to suspend its performance (or be excused of any liability) under any Material Project Document to which it is a party in accordance with the terms thereof, which suspension (or excuse) could reasonably be expected to result in the Project failing to achieve the Project Completion Date on or before the Date Certain.
No Force Majeure. To the best of its knowledge and belief, no event of force majeure as defined in or contemplated by any Project Contract has occurred and is continuing for the purposes of that Project Contract.
No Force Majeure. The Issuer’s, the Lessor’s and the Manager’s obligations under this Agreement are unconditional and shall not be subject to suspension, delay or interruption on account of the occurrence of any event, whether or not such event is beyond its control.
No Force Majeure. The obligations of the Owners, Manager, and Back-up Manager under this Agreement are unconditional and shall not be subject to suspension, delay or interruption on account of the occurrence of any event, whether or not such event is beyond its control.
No Force Majeure. The Servicer’s and Subservicer’s obligations under this Agreement are unconditional and shall not be subject to suspension, delay or interruption on account of the occurrence of any event, whether or not such event is beyond its control.
No Force Majeure. Tenant's obligation to Complete construction of the Initial Tenant Improvements as set forth in Section 4.1 above shall be final and absolute and shall not be subject to Force Majeure, Port delays, Regulatory Approval delays or any other delays.
No Force Majeure. There shall not have occurred a force majeure event (to be defined as a significant global disruption in the financial markets caused by outbreak of war, terrorism, or other incidents, but not adverse changes in the financial, banking or capital markets generally).
No Force Majeure. On or after the Applicable Time there shall not have occurred any of the following: (i) a suspension or material limitation in trading in securities generally on the NYSE or the Xxxxxxxx Stock Exchange; (ii) a suspension or material limitation in trading in the Company’s securities on the NYSE or the Xxxxxxxx Stock Exchange; (iii) a general moratorium on commercial banking activities declared by either Federal or New York State or Chilean or Colombian authorities or a material disruption in commercial banking or securities settlement or clearance services in the United States or Chile or Colombia; (iv) the outbreak or escalation of hostilities involving the United States or Chile or Colombia or the declaration by the United States or Chile or Colombia, respectively, of a national emergency or war; (v) the imposition of the proposal of exchange controls by any governmental authority in Chile or Colombia; or (vi) the occurrence of any other calamity or crisis or any change in financial, political or economic conditions in the United States or elsewhere, if the effect of any such event specified in clause (iv) or (vi) in your judgment makes it impracticable or inadvisable to proceed with the public offering or the delivery of the Securities on the terms and in the manner contemplated in the Prospectus.
No Force Majeure. On or after the Effective Date, there shall not have occurred any of the following: (a) a suspension or material limitation in trading in securities generally on the New York Stock Exchange, Inc., NYSE MKT or NASDAQ; (b) a general moratorium on commercial banking activities declared by either Federal or New York authorities or a material disruption in commercial banking or securities settlement or clearance services in the United States; (c) the outbreak or escalation of hostilities involving the United States or the declaration by the United States of a national emergency or war or (d) the occurrence of any other calamity or crisis or any change in financial, political or economic conditions in the United States or elsewhere, if the effect of any such event specified in clause (c) or (d) in the judgment of the Selling Agent makes it impracticable or inadvisable to proceed with the offering or the delivery of the Securities being delivered on such Closing Date on the terms and in the manner contemplated in the Prospectus.
