The Change Order Sample Clauses

The Change Order. The Change Order is the instrument by which adjustments in the Contract Sum and the Contract Time are effected. The Change Order shall be accompanied by a breakdown as set forth in Paragraph 3.2.7.4. The breakdown is for the purpose of enabling the Design Professional and the Owner to make a judgment on the dollar amount of the adjustment in the Contract Sum and is not a part of the Change Order. No condition, term, qualification, limitation, exception, exemption, modification, or proviso, except as set forth in this Part, shall appear in the breakdown. Only such conditions, terms, qualifications, limitations, exceptions, exemptions, modifications, and provisos as are permitted under this Part are valid. The Design Professional shall certify to the dollar amount and description of the adjustments permitted by the Change Order.
Sample 1Sample 2Sample 3See All (125)
AutoNDA by SimpleDocs
The Change Order. The Change Order is the instrument by which adjustments in the Contract Sum and the Contract Time are effected. The Change Order shall be accompanied by a breakdown as set forth in Paragraph
Sample 1Sample 2Sample 3See All (4)
The Change Order. If any provision of this Agreement is found to be unenforceable by a court of law, the parties shall negotiate in good faith to agree upon a substitute provision that is consistent with the intentions underlying the original provision and the remainder shall be enforced to the extent permitted by Law. No waiver will be valid unless in writing and signed by the Party against which such waiver is sought to be enforced. The waiver or failure of either Party to exercise any right will not be deemed a waiver of any future right. The following Sections of these Terms shall survive termination or expiration of the Agreement for any reason: 3, 5, 6, 7, 8, 9 and 10.
Sample 1

Related to The Change Order

  • Change Order (5) The Change Order is then submitted to the Project Manager who immediately processes the CO with OPC as required by Bulletin 3.5 and BGS’ Contracting Plan.

  • Change Orders Any alteration or deviation from the Services mentioned or any other contractual specifications that result in a revision of this Agreement shall be executed and attached to this Agreement as a change order (“Change Order”).

  • For Lump Sum Change Order The payment and extension of time (if any) provided by this Change Order constitutes compensation in full to the Contractor and its Subcontractors and Suppliers for all costs and markups directly and indirectly attributable to the Change Order herein, for all delays related thereto and for performance of changes within the time stated.

  • Construction Change Directive A written order prepared and issued by the District, the Construction Manager, and/or the Architect and signed by the District and the Architect, directing a change in the Work.

  • Other Change Orders For Change Orders involving the following situations that would materially affect the completion of the Work by lengthening the critical path of the Construction Progress Schedule, the Design Professional shall determine the appropriate number of days and thereby extend the Material Completion and Occupancy Date. The Contractor expressly agrees that the Contractor’s sole monetary remedy for such extensions of Contract Time shall be calculated at the daily rate established for Time Dependent Overhead Costs in the Contract.

  • Implementation Specifications 1. The Non-Exchange Entity must obtain informed consent from individuals for any use or disclosure of information that is not permissible within the scope of the Privacy Notice Statement and any relevant agreements that were in effect as of the time the PII was collected. Such consent must be subject to a right of revocation.

  • Change Order Procedure The Agency may at any time request a modification to the Scope of Work using a change order. The following procedures for a change order shall be followed:

Time is Money Join Law Insider Premium to draft better contracts faster.