Tenant Work. All work installed or furnished to the Premises by Tenant in connection with Tenant’s initial occupancy pursuant to Rider 2 and the Workletter.
Tenant Work. Any alterations, improvements, additions, repairs or installations on the building performed by or on behalf of any Tenant.
Examples of Tenant Work in a sentence
Installation and ongoing maintenance of EVIDS will be at Company’s cost and may be performed by Authority or by an outside vendor approved by Authority, subject to a Tenant Work Permit.
Except for routine maintenance on installed equipment, an Authority Tenant Work Permit is required anytime Company performs or hires an outside contractor to perform any construction on or modification or alterations to the Premises.
Within 90 days of completion of any construction herein permitted, Company will cause to be prepared and delivered to Authority record documents as required under the Tenant Work Permit process, including but not limited to as-builts, legal descriptions, boundary surveys, and certified final cost of construction.
Company will make no improvements or alterations whatsoever to the common use areas; Company will make no improvements or alterations whatsoever to the Premises without the prior written approval of Authority under the Tenant Work Permit, which consent will not be unreasonably withheld or delayed.
Company will make no improvements or alterations whatsoever to the Premises without the prior written approval of Authority under the Tenant Work Permit, which consent will not be unreasonably withheld or delayed.
More Definitions of Tenant Work
Tenant Work means all work including demolition, improvements, additions and alterations in or to the Premises. Without limitation, Tenant Work includes any penetrations in the walls, partitions, ceilings or floors and all attached carpeting, all signs visible from the exterior of the Premises, and any change in the exterior appearance of the windows in the Premises (including shades, curtains and the like). All Tenant Work shall be subject to Landlord’s prior written approval, which approval shall not be unreasonably withheld, conditioned or delayed, and shall be arranged and paid for by Tenant all as provided herein; provided that any interior, non-structural Tenant Work (including any series of related Tenant Work projects) that (a) costs less than the “Tenant Work Threshold Amount” (which shall be $10,000.00), (b) does not affect any fire-safety, telecommunications, electrical, mechanical, ventilation or plumbing systems of the Building (“Core Building Systems”), and (c) does not affect any penetrations in or otherwise affect any walls, floors, roofs, or other structural elements of the Building or any signs visible from the exterior of the Premises or any change in the exterior appearance of the windows in the Premises (including shades, curtains and the like) shall not require Landlord’s prior approval if Tenant delivers the Construction Documents (as defined in Section 10.05(b)) for such work to Landlord at least five (5) business days’ prior to commencing such work. Whether or not Landlord’s approval is required, Tenant shall neither propose nor effect any Tenant Work that in Landlord’s reasonable judgment (i) adversely affects any structural component of the Building, (ii) would be incompatible with the Core Building Systems, (iii) affects the exterior or the exterior appearance of the Building or common areas within or around the Building or other property than the Premises, (iv) diminishes the value of the Premises, or (v) requires any unusual expense to readapt the Premises. Prior to commencing any Tenant Work affecting air disbursement from ventilation systems serving Tenant or the Building, including, without limitation, the installation of Tenant’s exhaust systems, Tenant shall provide Landlord with a third party report from a consultant, and in a form, reasonably acceptable to Landlord, showing that such work will not adversely affect the ventilation systems of the Building (or of any other tenant in the Building) and shall, upon completion of such wor...
Tenant Work. All work installed or furnished to the Premises by Xxxxxx, if any, pursuant to the Workletter.
Tenant Work means all work, including demolition, improvements, additions and alterations, in or to the Premises. Without limitation, Tenant Work includes any apertures in the walls, partitions, ceilings or floors and all attached carpeting, all signs visible from the exterior of the Premises, and any change in the exterior appearance of the Premises. All Tenant Work shall be subject to Landlord's prior written approval, not to be unreasonably withheld, conditioned or delayed, and shall be arranged and paid for by Tenant all as provided herein; provided that any interior, non- structural Tenant Work (including any series of related Tenant Work projects) that costs less than the Tenant Work Threshold Amount and does not affect any mechanical, electrical, plumbing, or telecommunications systems of the Premises (collectively, the "Building Systems") shall not require Landlord's prior approval if Tenant delivers the Construction Documents for such work to Landlord at least five (5) business days' prior to commencing such work and such work does not require the approval of Landlord's mortgagee. Whether or not Landlord's approval is required, Tenant shall neither propose nor effect any Tenant Work that would in Landlord's reasonable judgment (i) adversely affect any structural component of the Premises, (ii) is incompatible with the Building Systems, (iii) affects the exterior appearance of the Premises or areas around the Building or other property than the Premises, (iv) diminishes the value of the Premises, or (v) requires any unusual expense to readapt the Premises. Title to all additions, alterations, improvements and replacements made to the Premises, including all Tenant Work, shall vest in Landlord and remain part of the realty subject to this Lease, except to the extent provided in Section 5.12, without any obligation to pay any compensation therefor to Tenant.
Tenant Work shall have the meaning set forth in Section 3.01 of this Lease.
Tenant Work means the tenant improvement work necessary to complete the Premises, which work will be performed pursuant to Article 29 herein.
Tenant Work means the work that Borrower is obligated to perform pursuant to Leases for individual Tenants in their respective leased premises in the Improvements.
Tenant Work as used herein, shall mean all construction work performed pursuant to and in accordance with the plans and specifications which have been approved by Lessor. Lessee may request to perform additional work different from or in addition to the Tenant Work, except Lessee may not make any modifications to the Tenant Work without Lessor’s prior written consent.