Consequential Damages means Losses claimed to have resulted from any indirect, incidental, reliance, special, consequential, punitive, exemplary, multiple or any other Loss, including damages claimed to have resulted from harm to business, loss of anticipated revenues, savings, or profits, or other economic Loss claimed to have been suffered not measured by the prevailing Party’s actual damages, and any other damages typically considered consequential damages under Applicable Law, regardless of whether the Parties knew or had been advised of the possibility that such damages could result in connection with or arising from anything said, omitted, or done hereunder or related hereto, including willful acts or omissions.
Punitive Damages are those damages awarded as a penalty, the amount of which is neither governed nor fixed by statute.
Special Damages shall have the meaning as set forth in Section 5.07.
Direct Damage has the meaning given to it in clause 26.2;
Consequential Loss means loss of profits, anticipated loss of profit or revenue, loss of production, loss of business opportunity, loss of or damage to goodwill or reputation, loss of use or any other similar loss, but excludes:
Actual Damages has the meaning set forth in Section 12.4(C).
Environmental Damages means all claims, demands, liabilities (including strict liability), losses, damages (including consequential damages), causes of action, judgments, penalties, fines, costs and expenses (including reasonable fees, costs and expenses of attorneys, consultants, contractors, experts and laboratories), of any and every kind or character, contingent or otherwise, matured or unmatured, known or unknown, direct or indirect, foreseeable or unforeseeable, made, incurred, suffered or brought at any time and from time to time and arising in whole or in part from:
Loss or Damage means any loss or damage to the Vehicle, including that caused by theft of the Vehicle or by adverse weather events, that requires repair or replacement including the loss of use of the Vehicle (demurrage), legal expenses, assessment fees, towing and recovery costs, storage, service charges and any appraisal fees of the Vehicle;
Limitation of Liability Insert the following Section 15, after Section 14:
Compensatory Damages are those amounts awarded to compensate for the actual damages sustained, and are not awarded as a penalty, nor fixed in amount by statute.
Breach of Agreement provisions of Section 5(a)(ii) will apply to Party A and will not apply to Party B.
Substantial damage means damage of any origin sustained by a structure whereby the cost of restoring the structure to its before damaged condition would equal or exceed 50 percent of the market value of the structure before the damage occurred.
Delay Damages means the damages assessed pursuant to Section 3.2(a) hereof.
Cover Damages means, with respect to any Delivery Shortfall, an amount equal to (a) the positive net amount, if, any, by which the Replacement Price exceeds the applicable Price that would have been paid pursuant to Section 5.1 and the Cover Sheet, multiplied by the quantity of that Delivery Shortfall, plus (b) any applicable penalties and other costs assessed by ISO-NE or any other Person against Buyer as a result of Seller’s failure to deliver such Products in accordance with the terms of this Agreement. Buyer shall provide a statement for the applicable period explaining in reasonable detail the calculation of any Cover Damages.
Structural damage means a covered building, regardless of the date of its construction, has experienced the following.
Economic damages means objectively verifiable monetary losses, including medical expenses, loss of earnings, burial costs, loss of use of property, cost of replacement or repair, cost of obtaining substitute domestic services, loss of employment, and loss of business or employment opportunities.
Material Damage and “Materially Damaged” means damage which, in Seller’s reasonable estimation, exceeds $500,000.00 to repair or which, in Seller’s reasonable estimation, will take longer than ninety (90) days to repair.
Breach of Contract means the failure of a Party to perform any of its obligations in accordance with this Contract, in whole or in part or in a timely or satisfactory manner. The institution of proceedings under any bankruptcy, insolvency, reorganization or similar law, by or against Contractor, or the appointment of a receiver or similar officer for Contractor or any of its property, which is not vacated or fully stayed within 30 days after the institution of such proceeding, shall also constitute a breach. If Contractor is debarred or suspended under §24-109-105, C.R.S. at any time during the term of this Contract, then such debarment or suspension shall constitute a breach.
Damages means any loss, claim, damage, liability, costs and expenses (including, without limitation, reasonable attorney's fees and disbursements and costs and expenses of expert witnesses and investigation).
Indirect Losses means loss of profits, loss of production, loss of business, loss of business opportunity, or any claim for consequential loss or for indirect loss of any nature;
Physical Damage means any tangible injury to a Property, whether caused by accident, natural occurrence, or any other reason, including damage caused by defects in construction, land subsidence, earth movement or slippage, fire, flood, earthquake, riot, vandalism or any Environmental Condition.
Seller Damages shall have the meaning given to such term in Section 14.3.
Environmental Damage means any injury or damage to persons, living organisms or property (including offence to man’s senses) or any pollution or impairment of the environment resulting from the discharge, emission, escape or migration of any substance, energy, noise or vibration;
Daily Delay Damages means with respect to a Guaranteed Project Milestone, an amount equal to (a) the Project Development Security Amount posted as of the first date that Daily Delay Damages are payable under this Agreement with respect to such Guaranteed Project Milestone, divided by (b) 120.
Attorneys’ Fees means the full and actual cost of any legal services actually performed in connection with the matter involved calculated on the basis of the usual fee charged by the attorney performing such services and shall not be limited to "reasonable attorneys' fees" as defined in any statute or rule of court.