Common use of 212 Construction Staking Clause in Contracts

212 Construction Staking. Contractor shall avoid careless or negligent damage to construc- tion stakes, flags, or marks. If such damage occurs, Contractor shall be required to replace stakes neces- sary to construction. Contractor’s replacement staking shall be approved by Forest Service. Alternatively, upon Contractor’s request, Contracting Officer may agree to perform such work under B4.218.‌‌ When A7 shows that construction stakes are to be set by Forest Service after clearing, Contractor shall submit to Forest Service a written schedule for clearing, construction staking, and construction that will provide Forest Service a reasonable period for setting construc- tion stakes. Time for setting construction stakes may be modified by written agreement.‌ If Forest Service performs construction staking for Specified Roads, timing of such staking shall permit Contractor’s clearing and other construction activity to proceed without hindrance or delay, provided Contrac- tor’s construction activity is reasonably consistent with needs identified in Contractor’s Operating Schedule or amendments thereto.‌ Should Forest Service be unable to perform con- struction staking in such reasonable period, upon writ- ten agreement, Contractor shall assume the responsi- bility for construction staking for agreed upon portions of Specified Roads. In such event, Contracting Officer shall revise:‌‌‌‌

212 Construction Staking. Contractor shall avoid careless or negligent damage to construc- tion stakes, flags, or marks. If such damage occurs, Contractor shall be required to replace stakes neces- sary to construction. Contractor’s replacement staking shall be approved by Forest Service. Alternatively, upon Contractor’s request, Contracting Officer may agree to perform such work under B4.218.‌‌ B4.218. When A7 shows that construction stakes are to be set by Forest Service after clearing, Contractor shall submit to Forest Service a written schedule for clearing, construction staking, and construction that will provide Forest Service a reasonable period for setting construc- tion stakes. Time for setting construction stakes may be modified by written agreement.‌ agreement. If Forest Service performs construction staking for Specified Roads, timing of such staking shall permit Contractor’s clearing and other construction activity to proceed without hindrance or delay, provided Contrac- tor’s construction activity is reasonably consistent with needs identified in Contractor’s Operating Schedule or amendments thereto.‌ thereto. Should Forest Service be unable to perform con- struction staking in such reasonable period, upon writ- ten agreement, Contractor shall assume the responsi- bility for construction staking for agreed upon portions of Specified Roads. In such event, Contracting Officer shall revise:‌‌‌‌revise:

212 Construction Staking. Contractor shall avoid careless or negligent damage to construc- tion stakes, flags, or marks. If such damage occurs, Contractor shall be required to replace stakes neces- sary to construction. Contractor’s replacement staking shall be approved by Forest Service. Alternatively, upon Contractor’s request, Contracting Officer may agree to perform such work under B4.218.‌‌ B4.218. When A7 shows that construction stakes are to be set by Forest Service after clearing, Contractor shall submit to Forest Service a written schedule for clearing, construction staking, and construction that will provide Forest Service a reasonable period for setting construc- tion stakes. Time for setting construction stakes may be modified by written agreement.‌ agreement. SAMPLE If Forest Service performs construction staking for Specified Roads, timing of such staking shall permit Contractor’s clearing and other construction activity to proceed without hindrance or delay, provided Contrac- tor’s construction activity is reasonably consistent with needs identified in Contractor’s Operating Schedule or amendments thereto.‌ thereto. Should Forest Service be unable to perform con- struction staking in such reasonable period, upon writ- ten agreement, Contractor shall assume the responsi- bility for construction staking for agreed upon portions of Specified Roads. In such event, Contracting Officer shall revise:‌‌‌‌revise:

212 Construction Staking. Contractor shall avoid careless or negligent damage to construc- tion stakes, flags, or marks. If such damage occurs, Contractor shall be required to replace stakes neces- sary to construction. Contractor’s replacement staking shall be approved by Forest Service. Alternatively, upon Contractor’s request, Contracting Officer may agree to perform such work under B4.218.‌‌ When A7 shows that construction stakes are to be set by Forest Service after clearing, Contractor shall submit to Forest Service a written schedule for clearing, construction staking, and construction that will provide Forest Service a reasonable period for setting construc- tion stakes. Time for setting construction stakes may be modified by written agreement.‌ SAMPLE If Forest Service performs construction staking for Specified Roads, timing of such staking shall permit Contractor’s clearing and other construction activity to proceed without hindrance or delay, provided Contrac- tor’s construction activity is reasonably consistent with needs identified in Contractor’s Operating Schedule or amendments thereto.‌ Should Forest Service be unable to perform con- struction staking in such reasonable period, upon writ- ten agreement, Contractor shall assume the responsi- bility for construction staking for agreed upon portions of Specified Roads. In such event, Contracting Officer shall revise:‌‌‌‌

212 Construction Staking. Contractor shall avoid careless or negligent damage to construc- tion stakes, flags, or marks. If such damage occurs, Contractor shall be required to replace stakes neces- sary to construction. Contractor’s replacement staking shall be approved by Forest Service. Alternatively, upon Contractor’s request, Contracting Officer may agree to perform such work under B4.218.‌‌ B4.218. SAMPLE When A7 shows that construction stakes are to be set by Forest Service after clearing, Contractor shall submit to Forest Service a written schedule for clearing, construction staking, and construction that will provide Forest Service a reasonable period for setting construc- tion stakes. Time for setting construction stakes may be modified by written agreement.‌ agreement. If Forest Service performs construction staking for Specified Roads, timing of such staking shall permit Contractor’s clearing and other construction activity to proceed without hindrance or delay, provided Contrac- tor’s construction activity is reasonably consistent with needs identified in Contractor’s Operating Schedule or amendments thereto.‌ thereto. Should Forest Service be unable to perform con- struction staking in such reasonable period, upon writ- ten agreement, Contractor shall assume the responsi- bility for construction staking for agreed upon portions of Specified Roads. In such event, Contracting Officer shall revise:‌‌‌‌revise: