Client Obligations 3.1 The Client warrants and represents that:
3.1.1 it shall co-operate with Centaur as required for the proper performance of the Services;
3.1.2 it shall provide, for Centaur, its agents, subcontractors, consultants and employees, in a timely manner and at no charge, access to the Client's premises during normal office hours (being Monday – Friday 8am – 6pm), office accommodation, data and other facilities as is reasonably required by Centaur or any of them for the proper performance of the Services;
3.1.3 all information it has provided to Centaur in relation to the Services as at the date of the Order Form is accurate, complete and is not misleading and it shall provide, in a timely manner, such further information and Client Material as Centaur may require for the proper performance of the Services, and ensure that such information and Client Material is accurate, complete and not misleading;
3.1.4 it shall be responsible (at its own cost) for preparing and maintaining the relevant premises for the supply of the Services;
3.1.5 it shall inform Centaur of all health and safety rules and regulations and any other reasonable security requirements that apply at any of the Client's premises;
3.1.6 it shall only use the Services for internal business purposes and, without prejudice to the foregoing, shall not use the Services, the Deliverables or any Centaur Materials to develop a product or service that competes with any of the products or services provided by Centaur;
3.1.7 the Client Materials shall not infringe any third party rights, including any third party Intellectual Property Rights; and
3.1.8 it shall obtain and maintain all necessary licences and consents and comply with all relevant legislation in relation to the Services, before the date on which the Services are to start.
3.2 If Centaur's performance of its obligations under this Agreement is prevented or delayed by any act or omission of the Client, its agents, subcontractors, consultants or employees, Centaur shall not be liable for any costs, charges or losses sustained or incurred by the Client that arise directly or indirectly from such prevention or delay.
Surety Obligations No Borrower or Subsidiary is obligated as surety or indemnitor under any bond or other contract that assures payment or performance of any obligation of any Person, except as permitted hereunder.
Perform Obligations To perform promptly all of the obligations of Tenant set forth in this Lease; and to pay when due the Fixed Rent and Additional Rent and all charges, rates and other sums which by the terms of this Lease are to be paid by Tenant.
Obligations of DOE a. In express reliance on the covenants and representations in this Compromise Agreement and to avoid further expenditure of public resources, XXX agrees to accept Respondent’s payment pursuant to section III.2.a in full satisfaction of the penalty authorized by the Act.
x. XXX agrees to issue promptly an Adopting Order adopting this Agreement.
x. XXX agrees to terminate this enforcement action with prejudice upon Respondent’s completion of its Obligations in accordance with section III.2, above. If Respondent fails to complete its Obligations in accordance with section III.2, above, DOE may notify Respondent that the Agreement is null and void and may seek the maximum penalty in accordance with 10 C.F.R. § 429.120.
Obligations of the Contractor (i) Subject to and on the terms and conditions of this Agreement, the Contractor shall undertake the survey, investigation, design, engineering, procurement, construction, and maintenance of the Project Highway and observe, fulfil, comply with and perform all its obligations set out in this Agreement or arising hereunder.
(ii) The Contractor shall comply with all Applicable Laws and Applicable Permits (including renewals as required) in the performance of its obligations under this Agreement.
(iii) Subject to the provisions of Clauses 4.1 (i) and 4.1 (ii), the Contractor shall discharge its obligations in accordance with Good Industry Practice and as a reasonable and prudent person.
(iv) The Contractor shall remedy any and all loss, defects, or damage to the Project Highway from the Appointed Date until the end of the Construction Period at the Contractor’s cost, save and except to the extent that any such loss, defect, or damage shall have arisen from any wilful default or neglect of the Authority.
(v) The Contractor shall remedy any and all loss, defect or damage to the Project Highway during the Defects Liability Period at the Contractor’s cost to the extent that such loss, defect or damage shall have arisen out of the reasons specified in Clause 17.3.
(vi) The Contractor shall remedy any and all loss or damage to the Project Highway during the Maintenance Period at the Contractor’s cost, including those stated in Clause 14.1 (ii), save and except to the extent that any such loss or damage shall have arisen on account of any wilful default or neglect of the Authority or on account of a Force Majeure Event.
(vii) The Contractor shall, at its own cost and expense, in addition to and not in derogation of its obligations elsewhere set out in this Agreement:
(a) make, or cause to be made, necessary applications to the relevant Government Instrumentalities with such particulars and details as may be required for obtaining Applicable Permits set forth in Schedule-F and obtain and keep in force and effect such Applicable Permits in conformity with the Applicable Laws;
(b) procure, as required, the appropriate proprietary rights, licences, agreements and permissions for Materials, methods, processes and systems used or incorporated into the Project Highway;
(c) make reasonable efforts to maintain harmony and good industrial relations among the personnel employed byit or its Sub-contractors in connection with the performance of its obligations under this Agreement;
(d) ensure and procure that its Sub-contractors comply with all Applicable Permits and Applicable Laws in the performance by them of any of the Contractor’s obligations under this Agreement;
(e) not do or omit to do any act, deed or thing which may in any manner violate any provisions of this Agreement;
(f) support, cooperate with and facilitate the Authority in the implementation and operation of the Project in accordance with the provisions of this Agreement;
(g) ensure that the Contractor and its Sub-contractors comply with the safety and welfare measures for labour in accordance with the Applicable Laws and Good Industry Practice;
(h) keep, on Site, a copy of this Agreement, publications named in this Agreement, the Drawings, Documents relating to the Project, and Change of Scope orders and other communications given under this Agreement. The Authority’s Engineer and its authorised personnel shall have the right of access to all these documents at all reasonable times;
(i) cooperate with other contractors employed by the Authority and personnel of any public authority; and
(j) not interfere unnecessarily or improperly with the convenience of the public, or the access to and use and occupation of all roads and footpaths, irrespective of whether they are public or in the possession of the Authority or of others.
(viii) The Contractor shall undertake all necessary superintendence to plan, arrange, direct, manage, inspect and test the Works. The Contractor shall provide all necessary superintendence of the Works for the proper fulfilling of the Contractor's obligations under the Agreement. Such superintendence shall be given by competent person having adequate knowledge of the operations to be carried out (including the methods and techniques required, the hazards likely to be encountered and methods of preventing accidents) for the satisfactory and safe execution of the Works.
(ix) The Contractor shall obtain and maintain a project related bank account operational at site where all transactions related to the payment of work will be done. The Contractor shall submit a monthly account statement and a detailed report on utilization of funds transferred to this project related bank account to Authority’s Engineer. Notwithstanding anything contrary to this agreement, the authority, in the interest and to ensure timely completion of the work, reserves the right to audit such bank accounts to ensure that there is no diversion of funds from this project specific account to any other project being implemented by the Contractor.
(x) The Contractor shall provide the documents of the Contractor specified in the Agreement, and all Contractors' personnel; Goods, consumables and other things and services, whether of a temporary or permanent nature, required in and for the execution, completion of Works and remedying defects.
(xi) The Contractor shall perform the Works in conformity with the Project requirements and other requirements and standards prescribed under or pursuant to the Agreement.
(xii) The Contractor shall carry out such work incidental and contingent to the original Scope of the Project to comply with Good Industry Practices.
(xiii) The Contractor shall maintain required staff and necessary Contractor’s equipment and materials within the reach of the Site during the Defects Liability Period so that any defects arising are promptly attended.
Obligations of Contractor 5.01 CONTRACTOR agrees to perform all Services in accordance with the terms and conditions of this Agreement and the Proposal. In the event that the terms of the Proposal shall conflict with the terms of this Agreement or contain additional terms that purport to bind the CITY other than the Services to be rendered and the price for the Services, the terms of this Agreement shall govern and said additional or conflicting terms shall be of no force or effect.
5.02 Except as otherwise agreed by the parties, CONTRACTOR will supply all personnel, materials and equipment required to perform the Services. CONTRACTOR shall provide its own offices, telephones, vehicles and computers and set its own work hours. CONTRACTOR will determine the method, details, and means of performing the Services under this Agreement.
5.03 CONTRACTOR shall keep CITY informed as to the progress of the Services by means of regular and frequent consultations. Additionally, when requested by CITY, CONTRACTOR shall prepare written status reports.
5.04 CONTRACTOR is responsible for paying, when due, all income and other taxes, fees and withholding, including withholding state and federal taxes, social security, unemployment and worker’s compensation, incurred as a result of the compensation paid under this Agreement. XXXXXXXXXX agrees to indemnify, defend and hold harmless CITY for any claims, costs, losses, fees, penalties, interest, or damages suffered by CITY resulting from CONTRACTOR’s failure to comply with this provision.
5.05 In the event CONTRACTOR is required to prepare plans, drawings, specifications and/or estimates, the same shall be furnished in conformance with local, state and federal laws, rules and regulations.
5.06 CONTRACTOR represents that it possesses all required licenses necessary or applicable to the performance of Services under this Agreement and the Proposal and shall obtain and keep in full force and effect all permits and approvals required to perform the Services herein. In the event CITY is required to obtain an approval or permit from another governmental entity, CONTRACTOR shall provide all necessary supporting documents to be filed with such entity.
5.07 CONTRACTOR shall be solely responsible for obtaining Employment Eligibility Verification information from CONTRACTOR’s employees, in compliance with the Immigration Reform and Control Act of 1986, Pub. L. 99-603 (8 U.S.C. 1324a), and shall ensure that CONTRACTOR’s employees are eligible to work in the United States.
5.08 In the event that CONTRACTOR employs, contracts with, or otherwise utilizes any CalPERS retirees in completing any of the Services performed hereunder, such instances shall be disclosed in advance to the CITY and shall be subject to the CITY’s advance written approval.
5.09 Drug-free Workplace Certification. By signing this Agreement, the CONTRACTOR hereby certifies under penalty of perjury under the laws of the State of California that the CONTRACTOR will comply with the requirements of the Drug-Free Workplace Act of 1990 (Government Code, Section 8350 et seq.) and will provide a drug- free workplace.
5.10 CONTRACTOR shall comply with all applicable local, state and federal laws, rules, regulations, entitlements and/or permits applicable to, or governing the Services authorized hereunder.
Joint Obligations A. The University and the student share the responsibility for ensuring the quality of life within the residence halls, their maintenance, furnishings and facilities, and for a physical environment secure from fire and other hazards. The University will work with students to promote effective security of persons and property in the residence halls.
Parties Obligations The Parties’ obligations under this Agreement will continue notwithstanding the existence of a Material Change.
Valid Obligations The execution, delivery and performance of the Loan Documents have been duly authorized by all necessary corporate action and each represents a legal, valid and binding obligation of Borrower and is fully enforceable according to its terms, except as limited by laws relating to the enforcement of creditors' rights.
Obligations Guaranteed Subject to the provisions of this Article 2, the Guarantor hereby unconditionally guarantees (a) to each Holder of a Security authenticated and delivered by the Trustee or Authenticating Agent, (i) the full and prompt payment of the principal of, and premium, if any, and interest on, and any Redemption Price with respect to, such Security, when, where and as the same shall become due and payable, whether at the stated maturity thereof, by acceleration, call for redemption or otherwise in accordance with the terms of such Security and the Indenture and (ii) the full and prompt payment of interest on the overdue principal and interest, if any, on such Security, at the rate specified in such Security and to the extent lawful and (b) to the Trustee the full and prompt payment upon written demand therefor of all amounts due to it in accordance with the terms of the Indenture (collectively the “Guaranteed Obligation”). If for any reason the Company shall fail punctually to pay any such Guaranteed Obligation, the Guarantor hereby agrees to cause any such Guaranteed Obligation to be made punctually when, where and as the same shall become due and payable, whether at the stated maturity thereof, by acceleration, call for redemption or otherwise. All payments by the Guarantor hereunder shall be paid in lawful money of the United States of America. This Guarantee is unsecured and ranks equally in right of payment with all of the Guarantor’s existing and future senior indebtedness.
