ACCEPTANCE AND REJECTION a. Buyer shall accept the Services or give Seller notice of rejection within a reasonable time after the date of delivery. No payment, prior test, inspection, passage of title, any failure or delay in performing any of the foregoing, or failure to discover any defect or other nonconformance shall relieve Seller of any obligations under this Contract or impair any rights or remedies of Buyer. b. If Seller delivers defective or non-conforming Services, Buyer may at its option and at Seller's expense: (i) require Seller to promptly reperform, correct or replace the Services; (ii) correct the Services; or (iii) obtain replacement Services from another source. Return to Seller of defective or non-conforming Services and redelivery to Buyer of corrected or replaced Services shall be at Seller's expense. c. Seller shall not redeliver corrected or rejected Services without disclosing the former rejection or requirement for correction. Seller shall disclose any corrective action taken. All repair, replacement and other correction and redelivery shall be completed as Buyer may reasonably direct.
Configuration Management The Contractor shall maintain a configuration management program, which shall provide for the administrative and functional systems necessary for configuration identification, control, status accounting and reporting, to ensure configuration identity with the UCEU and associated cables produced by the Contractor. The Contractor shall maintain a Contractor approved Configuration Management Plan that complies with ANSI/EIA-649 2011. Notwithstanding ANSI/EIA-649 2011, the Contractor’s configuration management program shall comply with the VLS Configuration Management Plans, TL130-AD-PLN-010-VLS, and shall comply with the following:
ACCEPTANCE STANDARDS Inspection and acceptance/rejection of products shall be made within thirty (30) days of receipt or upon completion of installation should that installation period extend beyond thirty
Network Interconnection Architecture Each Party will plan, design, construct and maintain the facilities within their respective systems as are necessary and proper for the provision of traffic covered by this Agreement. These facilities include but are not limited to, a sufficient number of trunks to the point of interconnection with the tandem company, and sufficient interoffice and interexchange facilities and trunks between its own central offices to adequately handle traffic between all central offices within the service areas at a P.01 grade of service or better. The provisioning and engineering of such services and facilities will comply with generally accepted industry methods and practices, and will observe the rules and regulations of the lawfully established tariffs applicable to the services provided.
Maintenance and Support Services If this Agreement is for IT goods or services, this section applies: Unless otherwise specified in this Agreement: The Contractor shall promptly provide the Court with all Upgrades, including without limitation: (i) all Upgrades generally made available by Contractor to its other customers; (ii) Upgrades as necessary so that the Work complies with the Specifications and Applicable Law (including changes in Applicable Law); (iii) Upgrades as necessary so that the Work operates under new versions or releases of the Court’s operating system or database platform; and (iv) all on-site services necessary for installation of Upgrades. Without limiting any other obligation of Contractor under this Agreement, Contractor represents and warrants that it will maintain services, equipment, software or any other part of the Work so that they operate in accordance with their Specifications and Documentation; and The Contractor shall respond to the Court within four (4) hours after the Court reports a Technical Support Incident (such hours all occurring during Standard M&S Hours) to Contractor. DELIVERY, ACCEPTANCE, AND PAYMENT Delivery. Contractor shall deliver to the Court the Deliverables in accordance with this Agreement, including the Statement of Work. Unless otherwise specified by this Agreement, Contractor will deliver all goods purchased by the Court “Free on Board Destination Freight Prepaid” to the Court at the address and location specified by the Court. Title to all goods purchased by the Court vests in the Court upon payment of the applicable purchase price. Contractor will bear the risk of loss for any Work being delivered until received by the Court at the proper location. All shipments by Contractor or its Subcontractors must include packing sheets identifying: this Agreement number, the Court’s purchase order number, item number, quantity and unit of measure, part number and description of the goods shipped, and appropriate evidence of inspection, if required. Goods for different Agreements shall be listed on separate packing sheets.
SCOPE OF ARCHITECT’S BASIC SERVICES 3.1 The Architect’s Basic Services consist of those described in this Article 3 and include usual and customary structural, mechanical, and electrical engineering services. Services not set forth in this Article 3 are Supplemental or Additional Services. § 3.1.1 The Architect shall manage the Architect’s services, research applicable design criteria, attend Project meetings, communicate with members of the Project team, and report progress to the Owner. § 3.1.2 The Architect shall coordinate its services with those services provided by the Owner and the Owner’s consultants. The Architect shall be entitled to rely on, and shall not be responsible for, the accuracy, completeness, and timeliness of, services and information furnished by the Owner and the Owner’s consultants. The Architect shall provide prompt written notice to the Owner if the Architect becomes aware of any error, omission, or inconsistency in such services or information. § 3.1.3 As soon as practicable after the date of this Agreement, the Architect shall submit for the Owner’s approval a schedule for the performance of the Architect’s services. The schedule initially shall include anticipated dates for the commencement of construction and for Substantial Completion of the Work as set forth in the Initial Information. The schedule shall include allowances for periods of time required for the Owner’s review, for the performance of the Owner’s consultants, and for approval of submissions by authorities having jurisdiction over the Project. Once approved by the Owner, time limits established by the schedule shall not, except for reasonable cause, be exceeded by the Architect or Owner. With the Owner’s approval, the Architect shall adjust the schedule, if necessary, as the Project proceeds until the commencement of construction. § 3.1.4 The Architect shall not be responsible for an Owner’s directive or substitution, or for the Owner’s acceptance of non-conforming Work, made or given without the Architect’s written approval. § 3.1.5 The Architect shall contact governmental authorities required to approve the Construction Documents and entities providing utility services to the Project. The Architect shall respond to applicable design requirements imposed by those authorities and entities. § 3.1.6 The Architect shall assist the Owner in connection with the Owner’s responsibility for filing documents required for the approval of governmental authorities having jurisdiction over the Project.
Contract Monitoring The criminal background checks required by this rule shall be national in scope, and must be conducted at least once every three (3) years. Contractor shall make the criminal background checks required by Paragraph IV.G.1 available for inspection and copying by DRS personnel upon request of DRS.
Acceptance; Rejection A holder of Notes may accept the offer to prepay made pursuant to this Section 8.3 by causing a notice of such acceptance to be delivered to the Company not later than 15 days after receipt by such holder of the most recent offer of prepayment. A failure by a holder of Notes to respond to an offer to prepay made pursuant to this Section 8.3 shall be deemed to constitute a rejection of such offer by such holder.
Design Services The Engineer shall perform services during the schematic design phase, the design development phase, the contract documents phase, and the bidding period as hereinafter specified.
Quality Management Grantee will: 1. comply with quality management requirements as directed by the System Agency. 2. develop and implement a Quality Management Plan (QMP) that conforms with 25 TAC § 448.504 and make the QMP available to System Agency upon request. The QMP must be developed no later than the end of the first quarter of the Contract term. 3. update and revise the QMP each biennium or sooner, if necessary. Xxxxxxx’s governing body will review and approve the initial QMP, within the first quarter of the Contract term, and each updated and revised QMP thereafter. The QMP must describe Xxxxxxx’s methods to measure, assess, and improve - i. Implementation of evidence-based practices, programs and research-based approaches to service delivery; ii. Client/participant satisfaction with the services provided by Xxxxxxx; iii. Service capacity and access to services; iv. Client/participant continuum of care; and v. Accuracy of data reported to the state. 4. participate in continuous quality improvement (CQI) activities as defined and scheduled by the state including, but not limited to data verification, performing self-reviews; submitting self-review results and supporting documentation for the state’s desk reviews; and participating in the state’s onsite or desk reviews. 5. submit plan of improvement or corrective action plan and supporting documentation as requested by System Agency. 6. participate in and actively pursue CQI activities that support performance and outcomes improvement. 7. respond to consultation recommendations by System Agency, which may include, but are not limited to the following: i. Staff training; ii. Self-monitoring activities guided by System Agency, including use of quality management tools to self-identify compliance issues; and iii. Monitoring of performance reports in the System Agency electronic clinical management system.
