Acceptance or Rejection. All Goods, Services, and Deliverables are subject to acceptance by the Court. The Court may reject any Goods, Services or Deliverables that (i) fail to meet applicable acceptance criteria, (ii) are not as warranted, or (iii) are performed or delivered late (without prior consent by the Court). If the Court rejects any Good, Service, or Deliverable (other than for late performance or delivery), Contractor shall modify such rejected Good, Service, or Deliverable at no expense to the Court to correct the relevant deficiencies and shall redeliver such Good, Service, or Deliverable to the Court within ten (10) business days after the Court’s rejection, unless otherwise agreed in writing by the Court. Thereafter, the parties shall repeat the process set forth in this section until the Court accepts such corrected Good, Service, or Deliverable. The Court may terminate that portion of this Agreement which relates to a rejected Good, Service, or Deliverable at no expense to the Court if the Court rejects that Good, Service, or Deliverable (i) for late performance or delivery, or (ii) on at least two (2) occasions for other deficiencies. Date submitted to the Court: 1) Submitted on time: [ ] yes [ ] no. If no, please note length of delay and reasons.
Appears in 6 contracts
Samples: Standard Agreement, Standard Agreement, Standard Agreement
Acceptance or Rejection. All Goods, Services, and Deliverables are subject to acceptance by the Court. The Court may reject any Goods, Services or Deliverables that (i) fail to meet applicable acceptance criteria, (ii) are not as warranted, or (iii) are performed or delivered late (without prior consent by the Court). If the Court rejects any Good, Service, or Deliverable (other than for late performance or delivery), Contractor shall modify such rejected Good, Service, or Deliverable at no expense to the Court to correct the relevant deficiencies and shall redeliver such Good, Service, or Deliverable to the Court within ten (10) business days after the Court’s rejection, unless otherwise agreed in writing by the Court. Thereafter, the parties shall repeat the process set forth in this section until the Court accepts such corrected Good, Service, or Deliverable. The Court may terminate that portion of this Agreement which relates to a rejected Good, Service, or Deliverable at no expense to the Court if the Court rejects that Good, Service, or Deliverable (i) for late performance or delivery, or (ii) on at least two (2) occasions for other deficiencies. Date submitted to the Court:
1) Submitted on time: [ ] yes [ ] no. If no, please note length of delay and reasons.
Appears in 5 contracts
Samples: Standard Agreement, Standard Agreement, Contractor Agreement
Acceptance or Rejection. All Goods, Services, and Deliverables are subject to acceptance by the Court. The Court may reject any Goods, Services or Deliverables that (i) fail to meet applicable acceptance criteria, (ii) are not as warranted, or (iii) are performed or delivered late (without prior consent by the Court). If the Court rejects any Good, Service, or Deliverable (other than for late performance or delivery), Contractor shall modify such rejected Good, Service, or Deliverable at no expense to the Court to correct the relevant deficiencies and shall redeliver such Good, Service, or Deliverable to the Court within ten (10) business days after the Court’s rejection, unless otherwise agreed in writing by the Court. Thereafter, the parties shall repeat the process set forth in this section until the Court accepts such corrected Good, Service, or Deliverable. The Court may terminate that portion of this Agreement which relates to a rejected Good, Service, or Deliverable at no expense to the Court if the Court rejects that Good, Service, or Deliverable (iDeliverable(i) for late performance or delivery, or (ii) on at least two (2) occasions for other deficiencies. Date submitted to the Court:
1) Submitted on time: [ ] yes [ ] no. If no, please note length of delay and reasons.
Appears in 1 contract
Samples: Standard Agreement
Acceptance or Rejection. All Goods, Services, and Deliverables are subject to acceptance by the Court. The Court may reject any Goods, Services or Deliverables that (i) fail to meet applicable acceptance criteria, (ii) are not as warranted, or (iii) are performed or delivered late (without prior consent by the Court). If the Court rejects any Good, Service, or Deliverable (other than for late performance or delivery), Contractor shall modify such rejected Good, Service, or Deliverable at no expense to the Court to correct the relevant deficiencies and shall redeliver such Good, Service, or Deliverable to the Court within ten (10) business days after the Court’s rejection, unless otherwise agreed in writing by the Court. Thereafter, the parties shall repeat the process set forth in this section until the Court accepts such corrected Good, Service, or Deliverable. The Court may terminate that portion of this Agreement which relates to a rejected Good, Service, or Deliverable at no expense to the Court if the Court rejects that Good, Service, or Deliverable (i) for late performance or delivery, or (ii) on at least two (2) occasions for other deficiencies. Description of Services or Deliverables provided by Contractor: _____________________________________ Date submitted to the Court:
1) Submitted on time: [ ] yes [ ] no. If no, please note length of delay and reasons._____________ The Services or Deliverables are:
Appears in 1 contract
Samples: Printing and Mailing Agreement
Acceptance or Rejection. All Goods, Services, and Deliverables are subject to acceptance by the Court. The Court may reject any Goods, Services or Deliverables that (i) fail to meet applicable acceptance criteria, (ii) are not as warranted, or (iii) are performed or delivered late (without prior consent by the Court). If the Court rejects any Good, Service, or Deliverable (other than for late performance or delivery), Contractor shall modify such rejected Good, Service, or Deliverable at no expense to the Court to correct the relevant deficiencies and shall redeliver such Good, Service, or Deliverable to the Court within ten (10) business days after the Court’s rejection, unless otherwise agreed in writing by the Court. Thereafter, the parties shall repeat the process set forth in this section until the Court accepts such corrected Good, Service, or Deliverable. The Court may terminate that portion of this Agreement which relates to a rejected Good, Service, or Deliverable at no expense to the Court if the Court rejects that Good, Service, or Deliverable (i) for late performance or delivery, or (ii) on at least two (2) occasions for other deficiencies. Date submitted to the Court:
1) Submitted on time: [ ] yes [ ] no. If no, please note length of delay and reasons.
Appears in 1 contract
Samples: Standard Agreement