Acceptance Test Cutover Date
Acceptance Test Cutover Date Sample Clauses
Related to Acceptance Test Cutover Date
Acceptance Tests 11.1 If the Contract provides acceptance tests for Goods and/or the result of Services after their completion and/or delivery to the Purchaser, the acceptance shall only be considered as definitive when such tests have demonstrated the compliance of the Goods and/or the result of the Services to the requirements in the Contract. 11.2 Where the Contract provides for an acceptance procedure in the presence of both parties, at the successful completion of such procedure, the Purchaser shall issue the Supplier with an acceptance certificate which shall authorise the Supplier to invoice the Purchaser for any payment due on such acceptance. 11.3 The Purchaser shall at its discretion be entitled to issue and acceptancecertificate with reserves. The Supplier shall be obliged to remedy any non-conformities within the period set out in the acceptance certificate. Any payment which would otherwise have been due on acceptance may be withheld by the Purchaser in whole or part until the non- conformities underlying the reserves have been remedied.
Acceptance Testing At the time of installation of a LIS trunk group, and at no additional charge, acceptance tests will be performed to ensure that the service is operational and meets the applicable technical parameters.
Acceptance Date The date the Department accepts a Deliverable or System in accordance with Section 7 below shall be deemed the Acceptance Date for each Deliverable or System.
Acceptance Period For all Services provided under this Agreement, Vendor grants to Citizens a thirty (30) calendar day acceptance period ("Acceptance Period") commencing on the date completed Services are delivered to Citizens. Citizens shall have the right to reject the Services, in whole or in part, during the Acceptance Period for Vendor’s failure to meet the specifications associated with the delivered Services, with such determination to be made in Citizens’ reasonable judgment. At the end of the Acceptance Period, if Citizens has not rejected the Services, the Services shall be deemed to be accepted by Citizens; provided, however, that Citizens’ acceptance of the Services shall not be deemed a waiver of any of Citizens’ warranty rights as expressly provided in this Agreement.
Final Completion Date Final Completion for the Work as defined in Article 6.1.3 of the General Conditions to the Continuing Contract for Construction Management shall be achieved by October 31, 2024.
Post-Commercial Operation Date Testing and Modifications Each Party shall at its own expense perform routine inspection and testing of its facilities and equipment in accordance with Good Utility Practice as may be necessary to ensure the continued interconnection of the Large Generating Facility with the Participating TO’s Transmission System in a safe and reliable manner. Each Party shall have the right, upon advance written notice, to require reasonable additional testing of the other Party’s facilities, at the requesting Party’s expense, as may be in accordance with Good Utility Practice.
Acceptance; Rejection A holder of Notes may accept the offer to prepay made pursuant to this Section 8.3 by causing a notice of such acceptance to be delivered to the Company not later than 15 days after receipt by such holder of the most recent offer of prepayment. A failure by a holder of Notes to respond to an offer to prepay made pursuant to this Section 8.3 shall be deemed to constitute a rejection of such offer by such holder.
Commercial Operation Date Testing and Modifications Prior to the Commercial Operation Date, the Connecting Transmission Owner shall test the Connecting Transmission Owner’s Attachment Facilities (including required control technologies and protection systems) and System Upgrade Facilities and System Deliverability Upgrades and Developer shall test the Large Generating Facility and the Developer’s Attachment Facilities to ensure their safe and reliable operation. Similar testing may be required after initial operation. Developer and Connecting Transmission Owner shall each make any modifications to its facilities that are found to be necessary as a result of such testing. Developer shall bear the cost of all such testing and modifications. Developer shall generate test energy at the Large Generating Facility only if it has arranged for the injection of such test energy in accordance with NYISO procedures.
Performance Testing (a) All performance tests of the Project, including any Initial Performance Test required in Section 2 of Appendix VIII, will be performed in accordance with the test procedures set forth in Appendix VIII (“Performance Test”), including additional procedures and protocols related to Performance Testing as mutually agreed between Buyer and Seller (“Test Procedures”). Seller shall bear all costs and receive all revenues, if applicable, associated with all Performance Tests. (b) After the Initial Delivery Date and during the Delivery Term, Buyer will have the right to conduct a Performance Test (“Buyer Performance Test”) no more than once a calendar year to demonstrate whether the Project is capable of delivering the Distribution Services at the Contract Capacity. Within 30 calendar days following a Buyer Performance Test, Seller will have the right to retest the Project with a Performance Test (“Seller Retest”). For the avoidance of doubt, the results of any Seller Retest will supersede the results of the preceding Buyer Performance Test. (i) If a Buyer Performance Test or, if a corresponding Seller Retest has occurred, a Seller Retest demonstrates the Project is capable of delivering Distribution Services at or above ninety-nine percent (99%) of the Initial Contract Capacity, the Contract Capacity will remain the Initial Contract Capacity; (ii) If a Buyer Performance Test or, if a corresponding Seller Retest has occurred, a Seller Retest demonstrates the Project is capable of delivering Distribution Services at more than or equal to eighty-five (85%) of the Initial Contract Capacity, but less than ninety-nine percent (99%) of the Initial Contract Capacity (“Testing Band”), the Contract Capacity will be automatically adjusted (upwards or downwards) to the capacity commensurate with the amount of Distribution Services the Project delivered during the Performance Test within the Testing Band. (iii) If a Buyer Performance Test or, if a corresponding Seller Retest has occurred, a Seller Retest demonstrates the Project is not capable of delivering Distribution Services of at least eighty-five percent (85%) of the Initial Contract Capacity, an Event of Default shall occur in accordance with Section 7.1(a)(viii).
Delivery; Acceptance of Premises; Commencement Date Landlord shall use reasonable efforts to deliver the Premises to Tenant on or before the Target Commencement Date, with Landlord’s Work Substantially Completed (“Delivery” or “Deliver”). If Landlord fails to timely Deliver the Premises, Landlord shall not be liable to Tenant for any loss or damage resulting therefrom, and this Lease shall not be void or voidable except as provided herein. If Landlord does not Deliver the Premises within 45 days of the Target Commencement Date for any reason other than Force Majeure delays and Tenant Delays, this Lease may be terminated by Tenant by written notice to Landlord, and if so terminated by Tenant: (a) the Security Deposit, or any balance thereof (i.e., after deducting therefrom all amounts to which Landlord is entitled under the provisions of this Lease), shall be returned to Tenant, and (b) neither Landlord nor Tenant shall have any further rights, duties or obligations under this Lease, except with respect to provisions which expressly survive termination of this Lease. As used herein, the terms “Landlord’s Work,” “Tenant Delays” and “Substantially Completed” shall have the meanings set forth for such terms in the Work Letter. If Tenant does not elect to void this Lease within 10 business days of the lapse of such 45 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect. Notwithstanding anything to the contrary contained herein, if Tenant does not terminate this Lease pursuant to the immediately preceding sentence, Base Rent shall be abated 1 day for each day after such 45 day period (as extended by Force Majeure delays and Tenant Delays) that the Premises are not Delivered to Tenant.
