Architect Engineer shall provide assistance to Owner through the commissioning consultant/agent for the purpose of advising and counseling Owner’s personnel in the usage, operation and maintenance of the building mechanical, electrical, and plumbing systems.
Selection of Architect/Construction Drawings Landlord shall retain, on behalf of Tenant, FPBA Architects (the “Architect”) to prepare the “Construction Drawings,” as that term is defined in this Section 3.1. Landlord shall retain, on behalf of Tenant, engineering consultants and/or design-build consultants designated by Landlord (the “Engineers”) to prepare all plans and engineering working drawings relating to the structural, mechanical, electrical, plumbing and HYAC work of the Improvements and any relevant components of the Landlord Work. The plans and drawings to be prepared by Architect and the Engineers hereunder shall be known collectively as the “Construction Drawings.” All Construction Drawings shall comply with the drawing format and specifications as determined by Landlord, and shall be subject to Landlord’s approval as more particularly set forth in Sections 3.2 and 3.3, below. Notwithstanding Landlord’s retention of the Architect and Engineers, Tenant shall be responsible for, and shall fully cooperate and coordinate in good faith with Landlord, the Architect and the Engineers to supply all of the necessary information within Tenant’s possession to allow the Architect and the Engineers to initially prepare and then complete, the Construction Drawings. Landlord hereby agrees (at no cost to Landlord) to cooperate, on a commercially reasonable basis, with Tenant to assist Tenant in the preparation of the Construction Drawings. Landlord’s review of the Construction Drawings applicable to the Improvements (as opposed to Landlord Work) and as set forth in this Section 3, shall be for its sole purpose and shall not imply Landlord’s review of the same, or obligate Landlord to review the same, for quality, design, Code compliance or other like matters. Accordingly, notwithstanding that any Improvement-related portions of such Construction Drawings are reviewed by Landlord, and notwithstanding any advice or assistance which may be rendered to Tenant by Landlord, Landlord shall have no liability whatsoever in connection therewith and shall not be responsible for any omissions or errors contained in such portions of the Construction Drawings, and Tenant’s waiver and indemnity set forth in this Lease shall specifically apply to such portions of the Construction Drawings.
Construction of Tenant Improvements Promptly following approval of the Final TI Working Drawings, Landlord shall apply for and use reasonable efforts to obtain the necessary permits and approvals to allow construction of Landlord’s TI Work. Upon receipt of such permits and approvals, Landlord shall, at Tenant’s expense (subject to the application of the Tenant Improvement Allowance provided in this Workletter, and subject to any other applicable provisions of the Lease or of this Workletter expressly making any specific item of expense or cost the responsibility of Landlord), diligently construct and complete Landlord’s TI Work substantially in accordance with the Approved TI Plans, subject to Unavoidable Delays and Tenant Delays (if any). Such construction shall be performed in a good and workmanlike manner and shall conform to all applicable governmental codes, laws and regulations in force at the time such work is completed. Without limiting the generality of the foregoing, Landlord shall be responsible for compliance of Landlord’s TI Work with the requirements of the Americans with Disabilities Act and all similar or related requirements pertaining to access by persons with disabilities, but nothing in this sentence shall be construed to make Landlord responsible for bearing the cost of any such compliance, to the extent the compliance work is reasonably attributable to or related to the particular nature or design of the Tenant Improvements or is for any other reason expressly made Tenant’s cost or responsibility under any applicable provision of the Lease or of this Workletter. Landlord shall have the right, in its sole discretion, to decide whether and to what extent to use union labor on or in connection with Landlord’s Work, and shall use the TI General Contractor to construct all of Landlord’s TI Work. Landlord and Tenant shall each have a right to approve all subcontractors engaged in connection with the construction of the Tenant Improvements and to review and approve all competitive bids for any elements of the Tenant Improvements, such approval in each instance not to be unreasonably withheld, conditioned or delayed by either party.
Neutral Construction Neither party hereto may rely on any drafts of this Agreement in any interpretation of the Agreement. Both parties to this Agreement have reviewed this Agreement and have participated in its drafting and, accordingly, neither party shall attempt to invoke the normal rule of construction to the effect that ambiguities are to be resolved against the drafting party in any interpretation of this Agreement.
Construction of Agreement The parties mutually acknowledge that they and their attorneys have participated in the preparation and negotiation of this Agreement. In cases of uncertainty this Agreement shall be construed without regard to which of the parties caused the uncertainty to exist.
The Architect ENGINEER shall prepare for the State a revised accounting of how the Project responds to LEED criteria.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Architect/Engineer (A/E) means a person registered as an architect pursuant to Tex. Occ. Code Xxx., Chapter 1051, as a landscape architect pursuant to Tex. Occ. Code Xxx., Chapter 1052, a person licensed as a professional engineer pursuant to Tex. Occ. Code Xxx., Chapter 1001 and/or a firm employed by Owner or a design-build contractor to provide professional architectural or engineering services and to exercise overall responsibility for the design of a Project or a significant portion thereof, and to perform the contract administration responsibilities set forth in the Contract.
SUPERVISION AND CONSTRUCTION PROCEDURES 4.3.1 The Contractor shall supervise and direct the Work, using his / her best skill and attention. The Contractor shall be solely responsible for all construction means, methods, techniques, sequences and procedures and for coordinating all portions of the Work under the Contract. All aspects of the Project shall be subject to the inspection and approval of the State. Contractor guarantees to repair, replace, re-execute or otherwise correct any defect in workmanship, materials, or the like that fails to conform to the requirements of this Contract or that appears during the progress of the Work or within one year of final acceptance by the State. 4.3.2 The Contractor shall be responsible to the State for the acts and omissions of his / her employees, Subcontractors and their agents and employees, and other persons performing any of the Work under a contract with the Contractor. 4.3.3 The Contractor shall not be relieved from his / her obligations to perform the Work in accordance with the Contract Documents either by the activities or duties of the Architect in his / her administration of the Contract, or by inspections, tests or approvals required or performed under Paragraph 7.7 by persons other than the Contractor. 4.3.4 The Contractor shall acquaint himself (herself / itself) with the limits of the property or right- of-way of the State and shall not trespass on other property. The Contractor shall adequately protect the project, adjacent property and the public, and shall be responsible for any damage or injury due to the Contractor’s act or neglect, and shall save the State harmless in respect thereto. 4.3.5 All work shall be done in such a manner as not to interfere with the State’s operating functions. Contractor and his employees shall familiarize themselves and comply with all rules and regulations applicable to the project. 4.3.6 The Contractor shall keep the premises free from liens arising out of or from the Project. Contractor shall obtain and submit waivers of liens with a request for a progress or final payment.
Construction of the Tenant Improvements (a) Tenant shall construct and install the Tenant Improvements in a good and workmanlike manner, in compliance with all Laws and in accordance with this Exhibit B. Tenant’s proposed architect/engineer, general contractor, and fire protection, plumbing, HVAC and electrical subcontractors are subject to Landlord’s prior approval. Promptly following the selection and approval of the architect/engineer, Tenant shall forward to said architect/engineer (and copy Landlord on the transmittal) Landlord’s building standards heretofore delivered to Tenant, and Tenant shall cause said architect/engineer to comply with said building standards. Promptly following the selection and approval of the general contractor, Tenant shall forward to said general contractor (and copy Landlord on the transmittal) Landlord’s fire protection, plumbing, HVAC and electrical specifications and Landlord’s rules of conduct, all of which have been delivered to Tenant prior to the date of this Lease, and Tenant shall cause said general contractor to comply with said specifications and rules of conduct. At Landlord’s request, Tenant shall coordinate a meeting among Landlord (who will reasonably make its representative available for such meeting), Tenant and Tenant’s general contractor to discuss the Building systems and other matters related to the construction of the Tenant Improvements. (b) Promptly following the date hereof, Tenant shall prepare and submit to Landlord a set of permittable construction drawings (the “CDs”), based on the preliminary plans attached hereto as Exhibit B-2 and made a part hereof (the “Preliminary Plans”), covering all work to be performed by Tenant in constructing the Tenant Improvements. Tenant shall have no right to make any Tenant Improvements that would materially alter the exterior appearance of the Building or the Building systems without Landlord’s prior approval. Landlord shall have fifteen (15) days after receipt of the CDs in which to review the CDs and in which to give Tenant written notice of its approval of the CDs or its requested changes to the CDs in reasonably sufficient detail so as to allow Tenant to make the requested changes (provided that Landlord shall not be permitted to request a change that is inconsistent with the Preliminary Plans). If Landlord requests any changes to the CDs, Tenant shall make such changes and shall, within fifteen (15) days of its receipt of Landlord’s requested changes (if any), submit the revised portion of the CDs to Landlord. Landlord shall have five (5) business days after receipt of the revised CDs in which to review said revised CDs and in which to give to Tenant written notice of its approval of the revised CDs or its requested changes thereto. This process shall continue until such time, if at all, that Landlord approves the CDs in accordance with this Section 2. Tenant shall at all times in its preparation of the CDs, and of any revisions thereto, act reasonably and in good faith. Landlord shall at all times in its review of the CDs, and any revisions thereto, act reasonably and in good faith.
