Indemnified Person If an Indemnified Person is entitled to indemnification under this Section 14 as a result of a claim by a third party, and the indemnifying Interconnection Party fails, after notice and reasonable opportunity to proceed under Section 14.2 of this Appendix 2, to assume the defense of such claim, such Indemnified Person may at the expense of the indemnifying Interconnection Party contest, settle or consent to the entry of any judgment with respect to, or pay in full, such claim.
Indemnified Party If a Party is entitled to indemnification under this Article 18 as a result of a claim by a third party, and the indemnifying Party fails, after notice and reasonable opportunity to proceed under Article 18.1.3, to assume the defense of such claim, such Indemnified Party may at the expense of the Indemnifying Party contest, settle or consent to the entry of any judgment with respect to, or pay in full, such claim.
Indemnifying Party If an Indemnifying Party is obligated to indemnify and hold any Indemnified Party harmless under this Article 18, the amount owing to the Indemnified Party shall be the amount of such Indemnified Party’s actual Loss, net of any insurance or other recovery.
Other Covered Persons Other than the Placement Agent, the Company is not aware of any person (other than any Issuer Covered Person) that has been or will be paid (directly or indirectly) remuneration for solicitation of purchasers in connection with the sale of any Securities.
Indemnification; Exoneration (a) In addition to amounts payable as elsewhere provided in this Article 3, the Borrower hereby agrees to protect, indemnify, pay and save harmless the Administrative Agent, each Issuing Bank and each Revolving Lender from and against any and all liabilities and costs which the Administrative Agent, such Issuing Bank or such Revolving Lender may incur or be subject to as a consequence, direct or indirect, of (i) the issuance of any Letter of Credit other than, in the case of such Issuing Bank, as a result of its gross negligence or willful misconduct, as determined by the final judgment of a court of competent jurisdiction, or (ii) the failure of such Issuing Bank to honor a drawing under a Letter of Credit as a result of any act or omission, whether rightful or wrongful, of any present or future de jure or de facto Governmental Authority (all such acts or omissions herein called “Governmental Acts”).
(b) As among the Borrower, the Revolving Lenders, the Administrative Agent and each Issuing Bank, the Borrower assumes all risks of the acts and omissions of, or misuse of such Letter of Credit by, the beneficiary of any Letters of Credit. In furtherance and not in limitation of the foregoing, subject to the provisions of the Letter of Credit applications and Letter of Credit reimbursement agreements executed by the Borrower at the time of request for any Letter of Credit, neither the Administrative Agent, any Issuing Bank nor any Revolving Lender shall be responsible (in the absence of gross negligence or willful misconduct in connection therewith, as determined by the final judgment of a court of competent jurisdiction): (i) for the form, validity, sufficiency, accuracy, genuineness or legal effect of any document submitted by any party in connection with the application for and issuance of the Letters of Credit, even if it should in fact prove to be in any or all respects invalid, insufficient, inaccurate, fraudulent or forged; (ii) for the validity or sufficiency of any instrument transferring or assigning or purporting to transfer or assign a Letter of Credit or the rights or benefits thereunder or proceeds thereof, in whole or in part, which may prove to be invalid or ineffective for any reason; (iii) for failure of the beneficiary of a Letter of Credit to comply duly with conditions required in order to draw upon such Letter of Credit; (iv) for errors, omissions, interruptions or delays in transmission or delivery of any messages, by mail, cable, telegraph, telex, or other similar form of teletransmission or otherwise; (v) for errors in interpretation of technical trade terms; (vi) for any loss or delay in the transmission or otherwise of any document required in order to make a drawing under any Letter of Credit or of the proceeds thereof; (vii) for the misapplication by the beneficiary of a Letter of Credit of the proceeds of any drawing under such Letter of Credit; and (viii) for any consequences arising from causes beyond the control of the Administrative Agent, the Issuing Banks and the Revolving Lenders, including, without limitation, any Governmental Acts. None of the above shall affect, impair, or prevent the vesting of any Issuing Bank’s rights or powers under this Section 3.10.
(c) In furtherance and extension and not in limitation of the specific provisions hereinabove set forth, any action taken or omitted by any Issuing Bank under or in connection with the Letters of Credit or any related certificates shall not, in the absence of gross negligence or willful misconduct, as determined by the final judgment of a court of competent jurisdiction, put such Issuing Bank, the Administrative Agent or any Revolving Lender under any resulting liability to the Borrower or relieve the Borrower of any of its obligations hereunder to any such Person.
(d) Without prejudice to the survival of any other agreement of the Borrower hereunder, the agreements and obligations of the Borrower contained in this Section 3.10 shall survive the payment in full of principal and interest hereunder, the termination of the Letters of Credit and the termination of this Agreement.
Indemnify and Hold Harmless The Trust shall be the policy holder of any insurance plan or health care coverage plan offered by and through the Trust. As the policy holder, the Trust shall indemnify and hold harmless from liability the Employer from any claims by beneficiaries, health care providers, vendors, insurance carriers or home care workers covered under this Agreement.
Indemnification of the Company and the Selling Stockholders The Underwriter agrees to indemnify and hold harmless the Company, its directors, its officers who signed the Registration Statement and each person, if any, who controls the Company within the meaning of Section 15 of the Securities Act or Section 20 of the Exchange Act and each of the Selling Stockholders to the same extent as the indemnity set forth in paragraph (a) above, but only with respect to any losses, claims, damages or liabilities that arise out of, or are based upon, any untrue statement or omission or alleged untrue statement or omission made in reliance upon and in conformity with any information relating to the Underwriter furnished to the Company in writing by the Underwriter expressly for use in the Registration Statement, the Prospectus (or any amendment or supplement thereto), any Issuer Free Writing Prospectus or any Pricing Disclosure Package, it being understood and agreed upon that the only such information furnished by the Underwriter consists of the following information in the Prospectus furnished on behalf of the Underwriter: the concession figure appearing in the sixth paragraph and the information concerning short selling and purchasing contained in the eleventh and twelfth paragraphs under the caption “Underwriting” (collectively, the “Underwriter Information”).
Indemnification/Hold Harmless As a separate and independent covenant from CONTRACTOR’s obligations under Section 22 hereof, CONTRACTOR shall indemnify, protect, defend with counsel acceptable to the CITY, and hold CITY and CITY’s officers, employees, agents, and volunteers harmless and free from any and all claims, liabilities, or expenses, including attorney’s fees, arising out of or relating to any negligent act, negligent omission, or wrongful conduct, or any loss, damage, or injury (including, but not limited to, death or other injury that is sustained from any communicable disease), related in any way to CONTRACTOR’s performance of its services pursuant to this Agreement. In the event CITY and/or any of CITY’s officers, employees, agents, or volunteers are named in any lawsuit, or should any claim be made against it or any of them by lawsuit or otherwise arising out of or relating to such negligent act, negligent omission, wrongful conduct, or any loss, damage, or injury (including, but not limited to, death or other injury that is sustained from any communicable disease), CONTRACTOR shall indemnify them for any judgment rendered against them for such negligent act, negligent omission, wrongful act, or any loss, damage, or injury (including, but not limited to, death or other injury that is sustained from any communicable disease), any sums paid out in settlement or otherwise, and all costs incurred by them in their defense, including but not limited to attorney’s fees. XXXXXXXXXX also understands and agrees that it is being employed to perform the services provided for by this Agreement because of CONTRACTOR’s professed expertise and experience in performing such services. In addition, CONTRACTOR understands and agrees that while CITY or CITY’s officers, employees, agents, or volunteers may elect to do so, they have no duty to review, inspect, monitor, or supervise the work performed by CONTRACTOR pursuant to this Agreement except as otherwise expressly provided for by this Agreement. As a consequence, CONTRACTOR waives any right of contribution against CITY or any of CITY’s officers, employees, agents, or volunteers arising out of such failure to inspect, review, monitor, or supervise the work performed by CONTRACTOR pursuant to this Agreement. CONTRACTOR’s obligations under this Section of the Agreement shall survive the termination of the Agreement.
Defense by Indemnifying Party In connection with any claim giving rise to indemnity hereunder resulting from or arising out of any claim or legal proceeding by a Person who is not a party to this Agreement, the Indemnifying Party at its sole cost and expense may, upon written notice to the Indemnified Party, assume the defense of any such claim or legal proceeding (i) if it acknowledges to the Indemnified Party in writing its obligations to indemnify the Indemnified Party with respect to all elements of such claim (subject to any limitations on such liability contained in this Agreement) and (ii) if it provides assurances, reasonably satisfactory to the Indemnified Party, that it will be financially able to satisfy such claims in full if the same are decided adversely. If the Indemnifying Party assumes the defense of any such claim or legal proceeding, it may use counsel of its choice to prosecute such defense, subject to the approval of such counsel by the Indemnified Party, which approval shall not be unreasonably withheld or delayed. The Indemnified Party shall be entitled to participate in (but not control) the defense of any such action, with its counsel and at its own expense; provided, however, that if the Indemnified Party, in its sole discretion, determines that there exists a conflict of interest between the Indemnifying Party (or any constituent party thereof) and the Indemnified Party, the Indemnified Party (or any constituent party thereof) shall have the right to engage separate counsel, the reasonable costs and expenses of which shall be paid by the Indemnified Party. If the Indemnifying Party assumes the defense of any such claim or legal proceeding, the Indemnifying Party shall take all steps necessary to pursue the resolution thereof in a prompt and diligent manner. The Indemnifying Party shall be entitled to consent to a settlement of, or the stipulation of any judgment arising from, any such claim or legal proceeding, with the consent of the Indemnified Party, which consent shall not be unreasonably withheld or delayed; provided, however, that no such consent shall be required from the Indemnified Party if (i) the Indemnifying Party pays or causes to be paid all Losses arising out of such settlement or judgment concurrently with the effectiveness thereof (as well as all other Losses theretofore incurred by the Indemnified Party which then remain unpaid or unreimbursed), (ii) in the case of a settlement, the settlement is conditioned upon a complete release by the claimant of the Indemnified Party and (iii) such settlement or judgment does not require the encumbrance of any asset of the Indemnified Party or impose any restriction upon its conduct of business.
Indemnification Etc 55 9.1 Survival of Representations, Etc.............................................................. 55 9.2
