Actual possession of the Assets. All of Seller's books and records and the executed originals of all lease agreements, service contracts, warranties, maintenance agreements and other documents affecting the Assets.
Actual possession of the Assets Sample Clauses
Related to Actual possession of the Assets
Possession of the Property The Parties hereby agree that the exclusive possession of the Property shall be delivered by the Seller to the Buyer on
POSSESSION OF THE APARTMENT PLOT 8.1 Schedule for possession of the said Apartment: The Promoter agrees and understands that timely delivery of possession of the Apartment to the Allottee and the Common Areas to the Association of the Allottees , is the essence of the Agreement. Provided that the Promoter shall be entitled to reasonable extension of time as agreed by and between the Allottee and the Promoter for giving possession of the Apartment on the aforesaid date and the same shall not include the period of extension given by the Authority for registration. The Promoter, based on the approved plans and specifications, assures to hand over possession of the Apartment on …………,with a grace period of twelve months (Completion date) in case the Promoter fails to complete the Project. unless there is a delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity or order, rule, notification of the Government and/or other public or competent authority/court and/or caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the Apartment, Provided that such Force Majeure conditions are not of a nature which make it impossible for the contract to be implemented. Promoter will be entitled to give block-wise and phase-wise possession upon obtaining the Completion Certificate/ Partial Completion Certificate of a building block or a particular phase as the case may be irrespective of the fact that construction of other Blocks and/or other phases and/or provision of facilities may be incomplete. The Allottee agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee the entire amount received by the Promoter from the allotment within 45 days from that date.After refund of the money paid by the Allottee, the Allottee agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement. It is clarified that all amounts collected as taxes, charges, levies, cess, assessments and impositions and deposited with the appropriate authorities concerned shall not be returned by the Promoter and the Allottee shall be free to approach the authorities concerned for refund of such taxes, charges, levies, cess, assessments and impositions. 8.2 The right of the Allottee shall remain restricted to the respective Apartment and the properties appurtenant thereto and the Allottee shall have no right, title or interest nor shall claim any right, title or interest of any kind whatsoever over and in respect of any other Apartment or space and/or any other portions of the Project or Complex. 8.3 The Promoter has provided to the Allottee a time schedule for construction progress based on the milestones on which payment is due. The dates provided are only tentative and for the purpose of dealing with contractors and will also make efforts to complete various stages as per the time schedule upto completion of the Project including the provisions of civic infrastructure like water, electricity, sanitation and all other above mentioned internal/external development works but the Promoter knows there will definitely be delays in the timelines provided but the Promoter assures the Allottee that the Project will be completed within the ‘Completion date’ provided in Clause 8.1 above.
POSSESSION OF THE APARTMENT/PLOT 7.1 Schedule for possession of the said [Apartment/Plot] - The Promoter agrees and understands that timely delivery of possession of the [Apartment/Plot] to the allottee and the common areas to the association of allottees or the competent authority, as the case may be, is the essence of the Agreement. The Promoter assures to hand over possession of the [Apartment/Plot] along with ready and complete common areas with all specifications, amenities and facilities of the project in place on , unless there is delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the [Apartment/Plot], provided that such Force Majeure conditions are not of a nature which make it impossible for the contract to be implemented. The Allottee agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee the entire amount received by the Promoter from the allotment within 60 days from that date. The promoter shall intimate the allottee about such termination at least thirty days prior to such termination. After refund of the money paid by the Allottee, the Allottee agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement.
POSSESSION OF PREMISES Tenant shall not be entitled to possession of the premises designated for lease until the security deposit and first month’s rent (or prorated portion thereof), less any applicable promotional discount, is paid in full and the premises designated for lease is vacated by the prior tenant.
Possession of Property Possession of the Property free and clear of all uses and encroachments, except the Permitted Exceptions, shall be delivered to Purchaser at closing.
Possession and Use Contractor may possess, use and reproduce Confidential Information solely for the Purpose. Contractor shall not use the Confidential Information for any other purpose.
Possession of Collateral Agent and Secured Parties appoint each Lender as agent (for the benefit of Secured Parties) for the purpose of perfecting Liens in any Collateral held or controlled by such Lender, to the extent such Liens are perfected by possession or control. If any Lender obtains possession or control of any Collateral, it shall notify Agent thereof and, promptly upon Agent’s request, deliver such Collateral to Agent or otherwise deal with it in accordance with Agent’s instructions.
Documents, Records and Funds in Possession of the Servicer to be Held for the Trustee The Servicer shall transmit to the Trustee or, at the direction of the Trustee, the Custodian as required by this Agreement all documents and instruments in respect of a Mortgage Loan coming into the possession of the Servicer from time to time and shall account fully to the Trustee for any funds received by the Servicer or which otherwise are collected by the Servicer as Liquidation Proceeds or Insurance Proceeds in respect of any Mortgage Loan. The documents constituting the Servicing File shall be held by the Servicer as custodian and bailee for the Trustee. All Mortgage Files and funds collected or held by, or under the control of, the Servicer in respect of any Mortgage Loans, whether from the collection of principal and interest payments or from Liquidation Proceeds, including but not limited to, any funds on deposit in the Servicer Custodial Account, shall be held by the Servicer for and on behalf of the Trustee and shall be and remain the sole and exclusive property of the Trustee, subject to the applicable provisions of this Agreement. The Servicer also agrees that it shall not knowingly create, incur or subject any Mortgage File or any funds that are deposited in the Servicer Custodial Account, Certificate Account or any Escrow Account, or any funds that otherwise are or may become due or payable to the Trustee for the benefit of the Certificateholders, to any claim, lien, security interest, judgment, levy, writ of attachment or other encumbrance created by the Servicer, or assert by legal action or otherwise any claim or right of setoff against any Mortgage File or any funds collected on, or in connection with, a Mortgage Loan, except, however, that the Servicer shall be entitled to set off against and deduct from any such funds any amounts that are properly due and payable to the Servicer under this Agreement.
Location of the Collateral Except in the ordinary course of Grantor’s business, Grantor agrees to keep the Collateral (or to the extent the Collateral consists of intangible property such as accounts or general intangibles, the records concerning the Collateral) at Grantor’s address shown above or at such other locations as are acceptable to Lender. Upon Lender’s request, Grantor will deliver to Lender in form satisfactory to Lender a schedule of real properties and Collateral locations relating to Grantor’s operations, including without limitation the following: (1) all real property Grantor owns or is purchasing; (2) all real property Grantor is renting or leasing; (3) all storage facilities Grantor owns, rents, leases, or uses; and (4) all other properties where Collateral is or may be located.
Operation of the Property Between June 1, 1998 and the Closing Date, Seller shall (a) lease, operate, manage and enter into contracts with respect to the Property, in the same manner done by Seller prior to the date hereof (provided, however, that without the prior consent of Purchaser, which as to (i) and (ii) shall not be unreasonably delayed, conditioned or withheld, (i) Seller shall not enter into any Service Contract that cannot be terminated with thirty (30) days notice or materially modify any existing Service Contracts to be assumed by Purchaser at Closing, and (ii) after June 1, 1998, Seller shall not materially modify or terminate any existing Tenant Lease or grant any material consents under any existing Tenant Lease (except as otherwise required pursuant to the terms and conditions of such Tenant Lease), or enter into any new Tenant Lease, and (iii) Seller shall not apply any then unapplied Deposits (as reflected on the Rent Roll delivered by Seller to Purchaser pursuant to Schedule 5.3(vii) hereof) under Tenant Leases); and (b) advise Purchaser of the commencement of any litigation, condemnation or other judicial or administrative proceedings affecting the Property of which Seller has current actual knowledge. Notwithstanding anything to the contrary set forth in this Contract, Purchaser acknowledges that after June 1, 1998 and prior to Closing, Seller will enter into contracts for the completion of Tenant improvements under Tenant Leases entered into after June 1, 1998 pursuant to the terms of Section 12.1 hereof (collectively, the "Tenant Finish Contracts"). Purchaser and Seller agree that at Closing, Purchaser shall assume the obligations of Seller under all such Tenant Finish Contracts including, without limitation, the obligations to pay any costs and expenses charged with respect to construction of improvements in the space subject to such Tenant Leases. At Closing, Purchaser shall execute and deliver to the Seller an Assignment, Assumption and Indemnity Agreement in the form attached hereto as Exhibit H and made a part hereof for all purposes.
