Additional Architect Services Sample Clauses

Additional Architect Services. At DISTRICT's request, Architect may be asked to perform in-scope services not otherwise included in this Agreement, not included within the basic services listed in Exhibit "A" attached hereto, and/or not customarily furnished in accordance with generally accepted architectural practice. As used herein, "Additional Services" mean: (1) any work which is determined by DISTRICT to be necessary for the proper completion of the Project, but which the parties did not reasonably anticipate would be necessary for the Architect to perform at the execution of this Agreement; or (2) any work listed as Additional Services in Exhibit "A" attached hereto. Architect shall not perform, nor be compensated for, Additional Services without prior written authorization from DISTRICT and without an agreement between the DISTRICT and Architect as to the compensation to be paid for such services. DISTRICT shall pay Architect for any approved Additional Services, pursuant to the compensation provisions herein, so long as such services are not made necessary through the fault of Architect pursuant to the indemnification provision of this Agreement. Such Additional Services shall not include any redesign or revisions to drawings, specifications or other documents when such revisions are necessary in order to bring such documents into compliance with applicable laws, rules, regulations or codes of which Architect was aware or should have been aware pursuant to the laws and regulations provision of this Agreement above.
Sample 1Sample 2Sample 3See All (4)
AutoNDA by SimpleDocs
Additional Architect Services. Architect may be asked by District to perform services not otherwise included
Sample 1
Additional Architect Services 
Sample 1

Related to Additional Architect Services

  • PROJECT SERVICES Landlord shall furnish services as follows:

  • Architect/Engineer (A/E) means a person registered as an architect pursuant to Tex. Occ. Code Xxx., Chapter 1051, as a landscape architect pursuant to Tex. Occ. Code Xxx., Chapter 1052, a person licensed as a professional engineer pursuant to Tex. Occ. Code Xxx., Chapter 1001 and/or a firm employed by Owner or a design-build contractor to provide professional architectural or engineering services and to exercise overall responsibility for the design of a Project or a significant portion thereof, and to perform the contract administration responsibilities set forth in the Contract.

  • Engineering Services Definition: Engineering Services includes any service or creative work, the adequate performance of which requires education, training and experience in the application of special knowledge in consulting, investigating, evaluating, planning and designing, engineering principles. Engineering Services covered by the Xxxxxx Architect-Engineers Act (40 U.S.C. 1102) are not covered in the primary scope of OASIS SB. Examples: Service areas that are included under the Engineering Services discipline include, but are not limited to the following: 1. Systems Engineering 2. Advanced Technology Pilots and Trials 3. Alternative Energy Sources and Engineering 4. Configuration Management 5. Concept Development

  • Construction Services 3.1.1 Basic Construction Services. 3.1.2 Meetings and Schedule Updates.

  • Payment for Project Services As full consideration for the Services to be performed by Contractor, City agrees to pay Contractor as set forth in accordance with the bid and not to exceed fee of 240,751.30 for the project. A monthly progress payment in the amount of ninety-five percent (95%) of the value of the work completed may be made every thirty (30) days upon application by the Contractor and certification by the Project Manager that such work has been completed. Partial payments will be made once each month as the work satisfactorily progresses and after acceptance by the authorized City representative. The progress estimates shall be based upon materials in place, or on the job site and invoiced, and labor expended thereon. From the total of the amount ascertained will be deducted an amount equivalent to five percent (5%) of the whole, which five percent (5%) will be retained by the City until after completion of the entire Contract in an acceptable manner. Any time after fifty percent (50%) of the value of the work has been completed, the City will make any of the remaining partial payments in full. No such estimates or payments shall be required to be made, when, in the judgment of the City Project Manager, the work is not proceeding in accordance with the provision of the Contract, or when in his judgment the total value of the work done since last estimate amounts to less than Five Hundred Dollars ($500.00). The cost of materials conforming to the plans and specifications (materials being those which are required to be contained and incorporated in a finished contract bid item) delivered to the project and not at the time incorporated in the work, may also be included in the estimate for payment. No such estimate or payment shall be construed to be an acceptance of any defective work or improper material. The Contractor shall be responsible for, and shall not remove from the project any material that has been included in the estimate for payment. Final payment shall be made upon the Project Manager certifying that the Contractor has satisfactorily completed the work in conformity with the Contract Documents.

  • SCOPE OF ARCHITECT’S BASIC SERVICES 3.1 The Architect’s Basic Services consist of those described in this Article 3 and include usual and customary structural, mechanical, and electrical engineering services. Services not set forth in this Article 3 are Supplemental or Additional Services. § 3.1.1 The Architect shall manage the Architect’s services, research applicable design criteria, attend Project meetings, communicate with members of the Project team, and report progress to the Owner. § 3.1.2 The Architect shall coordinate its services with those services provided by the Owner and the Owner’s consultants. The Architect shall be entitled to rely on, and shall not be responsible for, the accuracy, completeness, and timeliness of, services and information furnished by the Owner and the Owner’s consultants. The Architect shall provide prompt written notice to the Owner if the Architect becomes aware of any error, omission, or inconsistency in such services or information. § 3.1.3 As soon as practicable after the date of this Agreement, the Architect shall submit for the Owner’s approval a schedule for the performance of the Architect’s services. The schedule initially shall include anticipated dates for the commencement of construction and for Substantial Completion of the Work as set forth in the Initial Information. The schedule shall include allowances for periods of time required for the Owner’s review, for the performance of the Owner’s consultants, and for approval of submissions by authorities having jurisdiction over the Project. Once approved by the Owner, time limits established by the schedule shall not, except for reasonable cause, be exceeded by the Architect or Owner. With the Owner’s approval, the Architect shall adjust the schedule, if necessary, as the Project proceeds until the commencement of construction. § 3.1.4 The Architect shall not be responsible for an Owner’s directive or substitution, or for the Owner’s acceptance of non-conforming Work, made or given without the Architect’s written approval. § 3.1.5 The Architect shall contact governmental authorities required to approve the Construction Documents and entities providing utility services to the Project. The Architect shall respond to applicable design requirements imposed by those authorities and entities. § 3.1.6 The Architect shall assist the Owner in connection with the Owner’s responsibility for filing documents required for the approval of governmental authorities having jurisdiction over the Project.

  • Professional Engineering and Architect’s Services Professional Engineering and Architect’s Services are not permitted to be provided under this Agreement. Texas statutes prohibit the procurement of Professional Engineering and Architect’s Services through a cooperative agreement.

  • Design Services The Engineer shall perform services during the schematic design phase, the design development phase, the contract documents phase, and the bidding period as hereinafter specified.

  • Information Systems Acquisition Development and Maintenance a. Client Data – Client Data will only be used by State Street for the purposes specified in this Agreement.

  • Contract Services The Provider Agency shall provide services to eligible persons in accordance with all specifications contained in this Contract.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!