Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.
Additional Requirements for Sleeping Rooms The Contractor shall provide departing Attendees a secured area for storing belongings.
Unbundled Sub-Loop Distribution Voice Grade (USLD-VG) is a copper sub- loop facility from the cross-box in the field up to and including the point of demarcation at the End User’s premises and may have load coils.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
SERVICE REQUIREMENTS FOR REFERRED CLIENTS A. Agent agrees to respond to any communications from a Referred Client within two (2) hours after receipt if such communication is received between 9:00am to 5:00pm local time. For communications received outside of these hours, Agent agrees to respond by 10:00am the next day. B. Agent agrees to update XXXX.xxx with status updates within 48 hours after initial communication with a Referred Client and upon every significant status change until closing or abandoned. Updates shall be made by Agent via email to xxxxxxxxxxxx@xxxx.xxx. C. Vacations or extended absences shall be reported, with length of pause, to XXXX.xxx via email to D. Agent will not add Referred Client to any email list or calling list without the express permission of Referred Client. E. Agent agrees XXXX.xxx has the right to survey the Referred Client at any time. F. If Agent is contacted by a Referred Client that Agent is unwilling or unable to assist, Agent shall direct such Referred Client back to XXXX.xxx for assistance and notify XXXX.xxx at xxxxxxxxxxxx@xxxx.xxx. G. Agent agrees that XXXX.xxx has no obligation to provide Agent with any number of referrals and that prospective clients are free to select the agent they wish to work with for any particular real estate transaction.
Please see the current Washtenaw Community College catalog for up-to-date program requirements Conditions & Requirements
Switching and Tagging Rules Each Party shall provide the other Parties a copy of its switching and tagging rules that are applicable to the other Parties’ activities. Such switching and tagging rules shall be developed on a non-discriminatory basis. The Parties shall comply with applicable switching and tagging rules, as amended from time to time, in obtaining clearances for work or for switching operations on equipment.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Certification of Meeting or Exceeding Tobacco-Free Workplace Policy Minimum Standards A. Grantee certifies that it has adopted and enforces a Tobacco-Free Workplace Policy that meets or exceeds all of the following minimum standards of: i. Prohibiting the use of all forms of tobacco products, including but not limited to cigarettes, cigars, pipes, water pipes (hookah), bidis, kreteks, electronic cigarettes, smokeless tobacco, snuff and chewing tobacco; ii. Designating the property to which this Policy applies as a "designated area,” which must at least comprise all buildings and structures where activities funded under this Grant Agreement are taking place, as well as Grantee owned, leased, or controlled sidewalks, parking lots, walkways, and attached parking structures immediately adjacent to this designated area; iii. Applying to all employees and visitors in this designated area; and iv. Providing for or referring its employees to tobacco use cessation services. B. If Grantee cannot meet these minimum standards, it must obtain a waiver from the System Agency.
ADJUSTMENT OF THE DISTRIBUTOR’S ALLOCABLE PORTION AND EACH SUCCESSOR DISTRIBUTOR’S ALLOCABLE PORTION The parties to the Distribution Agreement recognize that, if the terms of any distributor’s contract, any distribution plan, any prospectus, the FINRA Conduct Rules or any other applicable law change so as to disproportionately reduce, in a manner inconsistent with the intent of this Distribution Agreement, the amount of the Distributor’s Allocable Portion or any Successor Distributor’s Allocable Portion had no such change occurred, the definitions of the Distributor’s Allocable Portion and/or the Successor Distributor’s Allocable Portion in respect of the Class C shares relating to a Fund shall be adjusted by agreement among the relevant parties; provided, however, if the Distributor, the Successor Distributor and the Fund cannot agree within thirty (30) days after the date of any such change in applicable laws or in any distributor’s contract, distribution plan, prospectus or the FINRA Conduct Rules, they shall submit the question to arbitration in accordance with the commercial arbitration rules of the American Arbitration Association and the decision reached by the arbitrator shall be final and binding on each of them. The following relates solely to Class 529-C shares. The Distributor’s Allocable Portion of Distribution Fees and CDSCs in respect of Class 529-C shares shall be 100% until such time as the Distributor shall cease to serve as exclusive distributor of Class 529-C shares; thereafter, collections that constitute CDSCs and Distribution Fees relating to Class 529-C shares shall be allocated among the Distributor and any successor distributor (“Successor Distributor”) in accordance with this Schedule. At such time as the Distributor’s Allocable Portion of the Distribution Fees equals zero, the Successor Distributor shall become the Distributor for purposes of this Allocation Schedule. Defined terms used in this Schedule and not otherwise defined herein shall have the meanings assigned to them in the Principal Underwriting Agreement (the “Distribution Agreement”), of which this Schedule is a part. As used herein the following terms shall have the meanings indicated:
