Adjustment for Occupancy Factor Sample Clauses

Adjustment for Occupancy Factor. Notwithstanding any other provision herein to the contrary, in the event the Building is not fully occupied during the Base Year or any calendar year during the term after the Base Year, an adjustment shall be made by Landlord in computing Operating Expenses for such year so that the Operating Expenses shall be computed for such year as though the Building had been fully occupied during such year. In addition, if any particular work or service includable in Operating Expenses is not furnished to a tenant who has undertaken to perform such work or service itself, Operating Expenses shall be deemed to be increased by an amount equal to the additional Operating Expenses which would have been incurred if Landlord had furnished such work or service to such tenant. The parties agree that statements in this Lease to the effect that Landlord is to perform certain of its obligations hereunder at its own or sole cost and expense shall not be interpreted as excluding any cost from Operating Expenses or Tax Expenses if such cost is an Operating Expense or Tax Expense pursuant to the terms of this Lease.
Sample 1Sample 2Sample 3See All (12)
AutoNDA by SimpleDocs
Adjustment for Occupancy Factor. Notwithstanding any other ------------------------------- provision herein to the contrary, in the event the Building is not fully occupied during the Base Year or any calendar year during the term after the Base Year, an adjustment shall be made by Landlord in computing Operating Expenses for the Base Year and such calendar year so that those Operating Expenses which vary based on levels of occupancy shall be computed for such year as though the Building had been fully occupied during such year. If any particular work or service includable in Operating Expenses is not furnished to a tenant who has undertaken to perform such work or service itself, Operating Expenses shall be deemed to be increased by an amount equal to the additional Operating Expenses which would have been incurred if Landlord had furnished such work or service to such tenant. In addition, for purposes of calculating the amounts due from Tenant pursuant to this Paragraph 7 for air conditioning costs and other Operating Expenses in connection with supplying air conditioning service, Tenant's Share shall be deemed to be 47.34%, which equals a fraction (expressed as a percentage), the numerator of which is the rentable square footage of the Premises, and the denominator of which is the total rentable square footage on the twelfth through sixteenth floors of the Building (agreed by the parties to be 131,368 rentable square feet). The parties agree that statements in this Lease to the effect that Landlord is to perform certain of its obligations hereunder at its own or sole cost and expense shall not be interpreted as excluding any cost from Operating Expenses or Tax Expenses if such cost is an Operating Expense or Tax Expense pursuant to the terms of this Lease.
Sample 1
Adjustment for Occupancy Factor. Notwithstanding any other provision herein to the contrary, in the event the Building is not at least ninety-five percent (95%) occupied during the Base Year or any calendar year during the term after the Base Year, an adjustment shall be made by Landlord in computing Operating Expenses for the Base Year and such calendar year so that those Operating Expenses which vary based on levels of occupancy shall be computed for such year as though the Building had been ninety-five percent (95%) occupied during such year. In addition, if any particular work or service includable in Operating Expenses is not furnished to a tenant who has undertaken to perform such work or service itself, Operating Expenses shall be deemed to be increased by an amount equal to the additional Operating Expenses which would have been incurred if Landlord had furnished such work or service to such tenant. The parties agree that statements in this Lease to the effect that Landlord is to perform certain of its obligations hereunder at its own or sole cost and expense shall not be interpreted as excluding any cost from Operating Expenses or Tax Expenses if such cost is an Operating Expense or Tax Expense pursuant to the terms of this Lease.
Sample 1
Adjustment for Occupancy Factor. Notwithstanding any other provision herein to the contrary, in the event the Building is not at least ninety-five percent (95%) occupied on average during the Base Year or any year of the term of this Lease, an adjustment shall be made by Landlord in computing Operating Expenses for such year so that the Operating Expenses shall be computed for such year as though the Building had been ninety-five percent (95%) occupied on average during such year. The parties agree that statements in this Lease to the effect that Landlord is to perform certain of its obligations hereunder at its own or sole cost and expense shall not be interpreted as excluding any cost from Operating Expenses or Tax Expenses if such cost is an Operating Expense or Tax Expense pursuant to the terms of this Lease.
Sample 1
Adjustment for Occupancy Factor. Notwithstanding any other provision herein to the contrary, in the event the Building is not fully occupied during the Base Year or any year of the term of this Lease, an adjustment shall be made by Landlord in computing Building Operating Costs for such year so that the Building Operating Costs shall be computed for such year as though the Building had been fully occupied during such year. To accomplish the foregoing, all variable components of Building Operating Costs for such calendar year (e.g., janitorial service, utilities, mechanical maintenance, but excluding expenses which do not vary with occupancy levels such as insurance and elevator maintenance) shall be "grossed-up", employing sound accounting and property management principles, to the amount such variable components would have been if the Building had been fully occupied during the entire calendar year and the adjusted amount of the variable components shall be used in determining Building Operating Costs for such calendar year.
Sample 1
Adjustment for Occupancy Factor. Notwithstanding any other ------------------------------- provision herein to the contrary, in the event the office area is not at least ninety-five percent (95%) occupied on average during the Base Year or any year of the Term of this Lease, an adjustment shall be made by Landlord in computing Operating Expenses for such year so that the Operating Expenses shall be computed for such year as though the office area had been ninety-five percent (95%) occupied on average during such year.
Sample 1

Related to Adjustment for Occupancy Factor

  • Early Occupancy If Tenant occupies the Property prior to the Commencement Date, Tenant's occupancy of the Property shall be subject to all of the provisions of this Lease. Early occupancy of the Property shall not advance the expiration date of this Lease. Tenant shall pay Base Rent and all other charges specified in this Lease for the early occupancy period.

  • RENTAL ADJUSTMENT The lesser of (i) 2%, or (ii) 1.25 times the change in the Price Index, as described in Section 4.02.

  • Ready for Occupancy For purposes of Section 1.3.2 of this Agreement, the Premises shall be deemed “Ready for Occupancy” upon the substantial completion of the Tenant Improvement Work. Subject to Section 4.2 below, the Tenant Improvement Work shall be deemed to be “substantially complete” upon the completion of the Tenant Improvement Work pursuant to the Approved Construction Drawings (as reasonably determined by Landlord), with the exception of any details of construction, mechanical adjustment or any other similar matter the non-completion of which does not materially interfere with Tenant’s use of the Premises.

  • PARTIAL OCCUPANCY OR USE 9.9.1 The Owner may occupy or use any completed or partially completed portion of the Work at any stage when such portion is designated by separate agreement with the Contractor, provided such occupancy or use is consented to by the insurer as required under Paragraph 11.3.1.5, the surety, and authorized by public authorities having jurisdiction over the Project. Such partial occupancy or use may commence whether or not the portion is substantially complete, provided the Owner and Contractor have accepted in writing the responsibilities assigned to each of them for payments, retainage, if any, security, maintenance, heat, utilities, damage to the Work and insurance, and have agreed in writing concerning the period for correction of the Work and commencement of warranties required by the Contract Documents. When the Contractor considers a portion substantially complete, the Contractor shall prepare and submit a list to the Architect as provided under Paragraph 9.8.2. Consent of the Contractor to partial occupancy or use shall not be unreasonably withheld. 9.9.2 Immediately prior to partial occupancy or use, the Owner, Contractor and Architect shall jointly inspect the area to be occupied or portion of the Work to be used in order to determine and record the condition of the Work. 9.9.3 Partial occupancy or use of a portion or portions of the Work shall not constitute acceptance of Work not complying with the requirements of the Contract Documents.

  • Maximum Occupancy No more than two (2) guests per one (1) resident (who is present) are permitted in a student room/suite/apartment at any given time unless otherwise approved by the University (Residential Life).

  • Base Rent Adjustment The Base Rent payable hereunder shall be adjusted upward from time to time in accordance with the following provisions: (a) Tenant shall pay to Landlord as an adjustment to Rent, an amount equal to the excess (the “Excess”) from time to time of total annual Operating Expenses per square foot of Rentable Area of the Premises, as Grossed-Up, over and above the Expense Stop. The Excess shall be obtained by multiplying (i) the difference between the annual Operating Expense per square foot of Rentable Area in the Premises and the Expense Stop, by (ii) the total Rentable Area of the Premises as set forth in Section 1.15. Such amount shall be paid in advance in monthly installments on the same dates as Base Rent is due and payable hereunder based on Landlord’s notice delivered to Tenant from time to time setting forth Landlord’s good faith estimate of the Operating Expenses for the current calendar year. Landlord shall have the right to adjust such amount no more than once a year to reflect any changes in Landlord’s estimate of Operating Expenses. (b) By April 1 of each calendar year during the Lease Term, or as soon thereafter as practicable, Landlord shall furnish to Tenant a statement (“Actual Statement”) of Landlord’s annual Operating Expenses, as Grossed-Up, for the previous calendar year. If for any calendar year the amounts collected from Tenant for the prior year, as a result of Landlord’s estimate of Operating Expenses, exceeds the amount of the Excess actually due during such prior year, then Landlord shall refund to Tenant any overpayment (or at Landlord’s option, apply such amount against Rent due or to become due hereunder). Likewise, Tenant shall pay to Landlord, on demand, any underpayment with respect to the prior year. (c) In the event of any good faith dispute as to the amount of the Excess as set forth in the statement of actual Operating Expenses, Tenant shall have the right, no more frequently than once per calendar year, after reasonable notice to Landlord and at reasonable times, to inspect and photocopy Landlord’s Operating Expenses records at Landlord’s offices. If, after such inspection and photocopy, Tenant continues, in good faith, to dispute the amount of the Excess as set forth in said statement, Tenant shall be entitled not later than one (1) year following Tenant’s receipt of an Actual Statement to retain a national, independent, certified public accountant who is not contracted on a contingency fee basis and is mutually acceptable to Landlord and Tenant to audit Landlord’s Operating Expenses records with respect to the calendar year covered by Actual Statement to determine the proper amount of the Excess. Landlord shall be entitled to review the results of such audit promptly after completion of same. If such audit proves that Landlord has overcharged Tenant, then within fifteen (15) days after the results of the audit are made available to Landlord, Landlord shall credit Tenant the amount of such overcharge toward the payments of Base Rent and Additional Rent next coming due under this Lease. If the results of such audit prove that Landlord has undercharged Tenant, then within fifteen (15) days after the results of the audit are made available to Tenant, Tenant shall pay to Landlord the amount of any such undercharge. Tenant agrees to pay the cost of such audit, provided that Landlord shall reimburse Tenant the amount of such cost if the results of such audit prove that Landlord’s determination of the Excess (as set forth in the Actual Statement) was in error by more than six percent (6%). If Tenant does not request an audit in accordance with the provisions of this Section 6(c) within one (1) year after Tenant’s receipt of an Actual Statement, such Actual Statement shall be conclusively binding upon Tenant. Landlord shall be required to maintain records of all Operating Expenses for three (3) years following the issuance of the Operating Expense statement for such Operating Expenses. The payment by Tenant of any amounts pursuant to this Article shall not preclude Tenant from questioning the correctness of any such statement.

  • Cost Share Federal and provincial governments support AgriInsurance programs by paying all administration expenses and sharing premium costs with the Insured.

  • Rent Adjustment Basic Assumptions Incorrect. Except to the extent that doing so would cause Lessor to recognize income other than "rents from real property" as defined in Section 856(d) of the Code, notwithstanding anything herein (other than Article 19) to the contrary, if (i) the facts and circumstances underlying the documented, basic assumptions upon which both Lessor and Lessee have relied in determining the Base Rent, the Suite Revenue Breakpoint, and the Percentage Rent payable hereunder become materially incorrect solely as a result of (A) a decision to re-brand the Hotel that is made after the Commencement Date, (B) the scope or cost of substantial renovations or other capital improvements to the Hotel, or (C) the implementation of any other hotel repositioning strategies (that were not planned as of the Commencement Date) resulting in significant disruption of the operations of the Hotel (collectively, a "Repositioning"), and (ii) Lessor and Lessee so agree in writing, then Lessor and Lessee shall, in good faith, negotiate modifications to the Base Rent, Suite Revenue Breakpoint and Percentage Rent to adjust (i.e., increase, decrease or reallocate among revenue categories) such Base Rent, Suite Revenue Breakpoint and Percentage Rent to reflect such change in basic assumptions for the affected periods, using the same methodology and other basic assumptions as were initially utilized in determining the Base Rent, Suite Revenue Breakpoint and Percentage Rent hereunder. If Lessor and Lessee are unable to agree, within thirty (30) days after the date of written certification from either Lessee or Lessor to the other party that a good faith dispute exists, as to the existence of the occurrence of a Repositioning or the adjustments to be made to the amounts or percentages for the Base Rent, Suite Revenue Breakpoint and Percentage Rent hereunder as a result of any repositioning, the dispute may be submitted by either party to arbitration under Section 25.2 hereof for resolution (during which period Lessee shall continue to pay Base Rent and Percentage Rent as required under Section 3.1 of this Lease); provided, however, that for purposes of applying the procedures in Section 25.3 to such arbitration, the target deadline therein for concluding the arbitration shall be shortened from ninety (90) days to thirty (30) days.

  • Base Year The period beginning on 1 April of one year and ending on 31 March of the following year.

  • Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!