Construction of the Improvements Once development of the Property has commenced, the construction of the Improvements shall be pursued with due diligence and continuity, in a good and workmanlike manner, and in accordance with sound building and engineering practices, all applicable governmental requirements, and the Development Plan. Borrower shall not permit cessation of work for a period in excess of thirty (30) days during any period of time during which development on the Property is scheduled to be performed without the prior written consent of Lender, which may be given or withheld in Lender’s sole discretion, except for delays due to strikes, riots, acts of God, war, unavailability of labor or materials, governmental laws, regulations or restrictions and Borrower shall promptly notify Lender of any such delays; provided, however, that in no event shall work cease for a period in excess of sixty (60) days regardless of the cause. Borrower shall cause all materials supplied for, or intended to be utilized in, the development of any part of the Property, but not affixed to or incorporated into the Property, to be stored on the Property or at such other location as may be approved by Lender in writing, with adequate safeguards, as required by Lender, to prevent loss, theft, damage, or commingling with other materials or projects.
Alterations and Improvements Tenant shall have the right at any time throughout the term of this Lease and any extensions hereof, to make or cause to be made, any alterations, additions, or improvements, or install or cause to be installed any trade fixture, signs, floor covering, interior or exterior painting or lighting, plumbing fixtures, shades or awnings, as Tenant may deem necessary or suitable with Landlord’s prior written approval, which approval shall not be unreasonably withheld or delayed. Upon the expiration of the Initial Term of this Lease, Tenant shall have the option to remove such alterations, decorations, additions or improvements made by it, provided any damage to Premises resulting from such removal is repaired. Also, upon the expiration of the Initial Term of this Lease, Tenant if requested by Landlord shall remove any signs and repair any damages to the Premises resulting from such removal. During the term, Tenant shall not make any alterations, additions, improvements, non-cosmetic changes or other material changes to the Premises without the prior written approval of Landlord, which approval shall not be unreasonably withheld or delayed. Notwithstanding the foregoing, Tenant shall be permitted to make Minor Alterations (as defined below) without Landlord’s prior written consent. Minor Alterations, as used herein, shall be defined as any alterations, improvements, etc. made to the Premises (excluding the facade thereof) which do not affect the structure of the buildings, their systems or equipment. If Landlord approves any alterations, additions, improvements, etc., Landlord shall notify Tenant, in writing, along with Landlord’s approval notice, of whether Tenant shall, upon termination of this Lease, either: (i) remove any such alterations or additions and repair any damage to the Premises (or the buildings in which the Premises are located) occasioned by their installation or removal and restore the Premises to substantially the same condition as existed prior to the time when any such alterations or additions were made, or (ii) reimburse Landlord for the cost of removing such alterations or additions and the restoration of the Premises.
Condition of the Premises Tenant acknowledges that, except as expressly set forth in this Lease, neither Landlord nor any agent of Landlord has made any representation or warranty with respect to the condition of the Premises, the Building or the Property, or with respect to the suitability of the Premises, the Building or the Property for the conduct of Tenant’s business. Tenant acknowledges that Landlord shall have no obligation to alter, repair or otherwise prepare the Premises for Tenant’s occupancy or to pay for or construct any improvements to the Premises except as otherwise expressly set forth in this Lease or in the Work Letter attached hereto as Exhibit 3.1. Notwithstanding anything to the contrary contained herein, Landlord represents and warrants to Tenant that (a) upon the Commencement Date, the Building and the Premises will be in material compliance with all Applicable Laws (in each case, without regard for any of the Finish Work, Tenant’s particular use (as opposed to the Permitted Use, generally), or the obligations of any other tenants in the Building with respect to their tenant improvements); (b) Landlord has full power and authority to enter into this Lease and has obtained all consents and taken all actions necessary in connection therewith other than to the extent provided in Section 14.6, below; and (c) upon the Commencement Date, the Building systems provided by Landlord and serving the Premises including electrical, HVAC, plumbing and other utility systems shall be in good working order and condition. Subject to the foregoing and Landlord’s obligation to repair latent defects in the Base Building Work as expressly provided in Section 1.1 of Exhibit 3.1, Tenant’s execution of this Lease and taking of possession of the Premises shall conclusively establish that the Premises, the Building and the Property were at such time in good, sanitary and satisfactory condition and repair; provided, nothing in this sentence relieves Landlord of its obligations pursuant to Section 8.1, below.
Condition of the Property THE LESSEE ACKNOWLEDGES AND AGREES THAT IT IS LEASING THE PROPERTY "AS IS" WITHOUT REPRESENTATION, WARRANTY OR COVENANT (EXPRESS OR IMPLIED) BY THE LESSOR AND SUBJECT TO (A) THE EXISTING STATE OF TITLE, (B) THE RIGHTS OF ANY PARTIES IN POSSESSION THEREOF, (C) ANY STATE OF FACTS WHICH AN ACCURATE SURVEY OR PHYSICAL INSPECTION MIGHT SHOW, AND (D) VIOLATIONS OF REQUIREMENTS OF LAW WHICH MAY EXIST ON THE DATE HEREOF OR ON THE ACQUISITION DATE. THE LESSOR HAS NOT MADE AND SHALL NOT BE DEEMED TO HAVE MADE ANY REPRESENTATION, WARRANTY OR COVENANT (EXPRESS OR IMPLIED) AND SHALL NOT BE DEEMED TO HAVE ANY LIABILITY WHATSOEVER AS TO THE TITLE (OTHER THAN FOR LESSOR LIENS), VALUE, HABITABILITY, USE, CONDITION, DESIGN, OPERATION, OR FITNESS FOR USE OF THE PROPERTY (OR ANY PART THEREOF), OR ANY OTHER REPRESENTATION, WARRANTY OR COVENANT WHATSOEVER, EXPRESS OR IMPLIED, WITH RESPECT TO THE PROPERTY (OR ANY PART THEREOF) AND THE LESSOR SHALL NOT BE LIABLE FOR ANY LATENT, HIDDEN, OR PATENT DEFECT THEREIN (OTHER THAN FOR LESSOR LIENS) OR THE FAILURE OF THE PROPERTY, OR ANY PART THEREOF, TO COMPLY WITH ANY REQUIREMENT OF LAW.
Use of the Property Borrower will use, or cause to be used, the Property for such use as is permitted pursuant to applicable Legal Requirements including, without limitation, under the certificate of occupancy applicable to the Property, and which is required by the Loan Documents. Borrower shall not suffer or permit the Property or any portion thereof to be used by the public, any tenant, or any Person not subject to a Lease, in a manner as is reasonably likely to impair Borrower’s title to the Property, or in such manner as may give rise to a claim or claims of adverse usage or adverse possession by the public, or of implied dedication of the Property or any part thereof.
Alterations, Additions, and Improvements Subject to the provisions of this Article IV, Lessee may make any alterations, additions, improvements or other changes to the Premises and the Relevant Assets as may be necessary or useful in connection with the operation of the Relevant Assets (collectively, the “Additional Improvements”). If such Additional Improvements require alterations, additions or improvements to the Premises or any of the Shared Access Facilities, Lessee shall notify Lessor in writing in advance and the parties shall negotiate in good faith any increase to the fees paid by Lessee under the Site Services Agreement by Lessee or otherwise provide for reimbursement of any material increase in cost (if any) to Lessor under the Site Services Agreement that results from any modifications to the Premises or the Shared Access Facilities necessary to accommodate the Additional Improvements, or as otherwise mutually agreed by the parties. Any alteration, addition, improvement or other change to the Premises, Relevant Assets or Additional Improvements (and, if agreed by Lessee and Lessor, to the Shared Access Facilities) by Lessee shall be made in a good and workmanlike manner and in accordance with all applicable Laws. The Relevant Assets and all Additional Improvements shall remain the property of Lessee and shall be removed by Lessee within one (1) year after termination of this Lease (provided that such can be removed by Lessee without unreasonable damage or harm to the Premises) or, at Lessee’s option exercisable by notice to Lessor, surrendered to Lessor upon the termination of this Lease. Lessee shall not have the right or power to create or permit any lien of any kind or character on the Premises by reason of repair or construction or other work. In the event any such lien is filed against the Premises, Lessee shall cause such lien to be discharged or bonded within thirty (30) days of the date of filing thereof.
TENANT'S USE OF THE PREMISES In consideration of the agreements contained herein, Landlord hereby leases the Premises to Tenant, and Tenant hereby leases the Premises from Landlord, for the Term and upon the terms and conditions hereinafter provided. The Premises are leased subject to, and Tenant agrees not to violate, all present and future covenants, conditions and restrictions of record which affect the Land, all of such documents collectively referred to as the "Restrictions". As an appurtenance to the Premises, Tenant shall have the general and nonexclusive right, together with Landlord and the other tenants of the Project and their respective agents, to use the Common Area subject to the terms and conditions of this Lease. Tenant shall use the Premises solely for the purpose set forth in Tenant's Use Clause as designated in Article 2.n and for no other purpose. Tenant shall not use or occupy the Premises in violation of law or any covenant, condition or restriction affecting the Building or Project or the certificate of occupancy issued for the Building or Project, and shall, upon notice from Landlord, immediately discontinue any use of the Premises which is declared by any governmental authority having jurisdiction to be a violation of law or the certificate of occupancy. Tenant, at Tenant's own cost and expense, shall comply with all laws, ordinances, regulations, rules and/or any directions of any governmental agencies or authorities having jurisdiction which shall by reason of the nature of Tenant's use or occupancy of the Promises, impose any duty upon Tenant or Landlord with respect to the Premises or its use or occupation. A judgment of any court of competent jurisdiction or the admission by Tenant in any action or proceeding against Tenant that Tenant has violated any such laws, ordinances, regulations, rules and/or directions in the use of the Premises shall be deemed to be a conclusive determination of that fact as between Landlord and Tenant. Tenant shall not do or permit to be done anything which will invalidate or increase the cost of any fire, extended coverage or other insurance policy covering the Building or Project and/or property located therein, and shall comply with all rules, orders, regulations, requirements and recommendations of the Board of Fire Insurance underwriters or any other organization performing a similar function. Tenant shall promptly upon demand reimburse Landlord for any additional premium charged for such policy by reason of Tenant's failure to comply with the provisions of this Article. Tenant shall not do or permit anything to be done in or about the Premises which will in any way obstruct or interfere with the rights of other tenants or occupants of the Building or Project, or injure or annoy them, or use or allow the Premises to be used for any improper, immoral, unlawful or objectionable purpose, nor shall Tenant cause, maintain or permit any nuisance in, on or about the Premises. Tenant shall not commit or suffer to be committed any waste in or upon the Premises. Tenant acknowledges that Tenant assumes all responsibility regarding the Occupational Safety Health Act, the legal use and adaptability of the Premises and the compliance thereof with all applicable laws and regulations in effect during the form of this Lease.
Condition of the Leased Property Lessee acknowledges receipt and delivery of possession of the Leased Property. Lessee has examined and otherwise has knowledge of the condition of the Leased Property and has found the same to be satisfactory for its purposes hereunder. Lessee is leasing the Leased Property “as is” in its present condition. Lessee waives any claim or action against Lessor in respect of the condition of the Leased Property. LESSOR MAKES NO WARRANTY OR REPRESENTATION, EXPRESS OR IMPLIED, IN RESPECT OF THE LEASED PROPERTY, OR ANY PART THEREOF, EITHER AS TO ITS FITNESS FOR USE, DESIGN OR CONDITION FOR ANY PARTICULAR USE OR PURPOSE OR OTHERWISE, AS TO THE QUALITY OF THE MATERIAL OR WORKMANSHIP THEREIN, LATENT OR PATENT, IT BEING AGREED THAT ALL SUCH RISKS ARE TO BE BORNE BY LESSEE. LESSEE ACKNOWLEDGES THAT THE LEASED PROPERTY HAS BEEN INSPECTED BY LESSEE AND IS SATISFACTORY TO IT. Provided, however, to the extent permitted by law, Lessor hereby assigns to Lessee all of Lessor’s rights to proceed against any predecessor in title (other than any Affiliate of Lessee, which conveyed the Property to Lessor) for breaches of warranties or representations or for latent defects in the Leased Property. Lessor shall fully cooperate with Lessee in the prosecution of any such claim, in Lessor’s or Lessee’s name, all at Lessee’s sole cost and expense. Lessee hereby agrees to indemnify, defend and hold harmless Lessor from and against any claims, obligations and liabilities against or incurred by Lessor in connection with such cooperation.
Operation of the Property Between June 1, 1998 and the Closing Date, Seller shall (a) lease, operate, manage and enter into contracts with respect to the Property, in the same manner done by Seller prior to the date hereof (provided, however, that without the prior consent of Purchaser, which as to (i) and (ii) shall not be unreasonably delayed, conditioned or withheld, (i) Seller shall not enter into any Service Contract that cannot be terminated with thirty (30) days notice or materially modify any existing Service Contracts to be assumed by Purchaser at Closing, and (ii) after June 1, 1998, Seller shall not materially modify or terminate any existing Tenant Lease or grant any material consents under any existing Tenant Lease (except as otherwise required pursuant to the terms and conditions of such Tenant Lease), or enter into any new Tenant Lease, and (iii) Seller shall not apply any then unapplied Deposits (as reflected on the Rent Roll delivered by Seller to Purchaser pursuant to Schedule 5.3(vii) hereof) under Tenant Leases); and (b) advise Purchaser of the commencement of any litigation, condemnation or other judicial or administrative proceedings affecting the Property of which Seller has current actual knowledge. Notwithstanding anything to the contrary set forth in this Contract, Purchaser acknowledges that after June 1, 1998 and prior to Closing, Seller will enter into contracts for the completion of Tenant improvements under Tenant Leases entered into after June 1, 1998 pursuant to the terms of Section 12.1 hereof (collectively, the "Tenant Finish Contracts"). Purchaser and Seller agree that at Closing, Purchaser shall assume the obligations of Seller under all such Tenant Finish Contracts including, without limitation, the obligations to pay any costs and expenses charged with respect to construction of improvements in the space subject to such Tenant Leases. At Closing, Purchaser shall execute and deliver to the Seller an Assignment, Assumption and Indemnity Agreement in the form attached hereto as Exhibit H and made a part hereof for all purposes.
Construction of the Tenant Improvements Landlord shall construct the Tenant Improvements in accordance with this exhibit and the construction contract to be executed by Landlord and its contractor(s). The construction contract for constructing the Tenant Improvements and the contractor(s) to perform the work shall be approved and/or selected, as the case may be, by Landlord at its sole and absolute discretion without the consent of Tenant.
