ARBITRATION BY ARCHITECTS Sample Clauses

ARBITRATION BY ARCHITECTS. Whenever there is a disagreement between the parties with respect to construction by Landlord of Tenant’s Work, such disagreement shall be definitively determined by the following procedure: Each of Landlord and Tenant shall appoint one (1) architect, such two (2) architects will then (within five (5) business days of their appointment) appoint a third architect licensed in the Commonwealth of Massachusetts with not less than ten (10) years experience. Each architect shall establish within ten (10) days of their appointment the matter in dispute. In case of any dispute with respect to dollar amounts or lengths of time or dates such as the date of Substantial Completion, the dollar amount or length of time or date shall be the average of the two (2) closest determinations by the three (3) architects, with the determination of the architect which was not closest to another architects’ determination excluded from such calculation. In case of any dispute not involving dollar amounts or lengths of time or dates (i.e. the approval of plans) the determination by at least two (2) of the three (3) architects shall be required in order to resolve the matter in dispute. Landlord and Tenant shall each bear the cost of the architect selected by them respectively and shall share equally the cost of the third architect. During such arbitration period, the parties agree to cooperate with one another so as to proceed with construction and with their respective obligations hereunder in a timely manner. Each determination under this Section 3.5 shall be binding upon Landlord and Tenant.
Sample 1Sample 2Sample 3See All (6)
AutoNDA by SimpleDocs
ARBITRATION BY ARCHITECTS. Whenever there is a disagreement between the parties with respect to construction by Landlord of Landlord's Work or Tenant's Work, such disagreement shall be definitively determined by the following procedure: Each of Landlord and Tenant shall appoint one (1) independent architect (which such architect may be Landlord's Architect and Tenant's Architect referenced in Section 3.1 above), such two (2) architects will then (within five (5) days of their appointment) appoint a third independent architect licensed in the Commonwealth of Massachusetts with not less than fifteen (15) years experience. Each architect shall establish within ten (10) days of their appointment the matter in dispute. In case of any dispute with respect to dollar amounts or lengths of time or dates such as the date of Substantial Completion, the dollar amount or length of time or date shall be the average of the two closest determinations by the three (3) architects, with the determination of the architect which was not closest to another architect's determination excluded from such calculation. In case of any dispute not involving dollar amounts or lengths of time or dates (i.e. the approval of plans) the determination by at least two (2) of the three (3) architects shall be required in order to resolve the matter in dispute. Landlord and Tenant shall each bear the cost of the architect selected by them respectively and shall share equally the cost of the third architect. During such arbitration period, the parties agree to cooperate with one another so as to proceed with construction and with their respective obligations hereunder in a timely manner. Each determination under this Section 3.6 shall be binding upon Landlord and Tenant.
Sample 1Sample 2
ARBITRATION BY ARCHITECTS. Whenever there is a disagreement between the parties with respect to construction by Landlord of Landlord's Work or Tenant's Work, such disagreement shall be definitively determined by the following procedure: Each of Landlord and Tenant shall appoint one (1) independent architect (which such architect may be Landlord's Architect and Tenant's Architect referenced in section 3.1 above), such two (2) architects will then (within five (5) days of their appointment) appoint a third independent architect licensed in the Commonwealth of Massachusetts with not less than ten (10) years experience. Each architect shall establish within ten (10) days of their appointment the matter in dispute. In case of any dispute with respect to
Sample 1Sample 2
ARBITRATION BY ARCHITECTS. 27 9.7 Warranty of Landlord's Work and Tenant's Work.......................................................27
Sample 1
ARBITRATION BY ARCHITECTS. Whenever there is a disagreement between the parties with respect to construction by Landlord of Landlord’s Work, and such disagreement is not resolved by the parties within a period of twenty (20) days, each party acting reasonably and in good faith, then such disagreement shall be definitively determined by the following procedure: Each of Landlord and Tenant shall appoint one (1) independent architect, no later than seven (7) days after the expiration of the twenty (20) day period, such two (2) architects will then (within five (5) days of their appointment) appoint a third independent architect licensed in the Commonwealth of Massachusetts with not less than ten (10) years experience. Each architect shall render a decision to Landlord, Tenant and the other architects within ten (10) days of their appointment regarding the matter in dispute. In case of any dispute with respect to dollar amounts or lengths of time or dates, the dollar amount or length of time or date shall be the average of the two closest determinations by the three (3) architects, with the determination of the architect which was not closest to another architects’ determination excluded from such calculation. In case of any dispute not involving dollar amounts or lengths of time or dates (i.e. the approval of plans) the determination by at least two (2) of the three (3) architects shall be required in order to resolve the matter in dispute. Landlord and Tenant shall each bear the cost of the architect selected by them respectively and shall share equally the cost of the third architect. During such arbitration period, the parties agree to cooperate with one another so as to proceed with construction and with their respective obligations hereunder in a timely manner. Each architect appointed shall be provided a copy of this section of the Lease and agrees to be bound by the same. Each determination under this Section 3.6 shall be binding upon Landlord and Tenant.
Sample 1
ARBITRATION BY ARCHITECTS. Whenever there is a disagreement between the parties with respect to construction by Landlord of the Base Building Work or the Building Upgrades, except as otherwise expressly set forth herein, such disagreement shall be definitively determined by the following procedure: Each of Landlord and Tenant shall appoint one (1) independent architect, such two (2) architects will then (within five (5) days of their appointment) appoint a third independent architect licensed in the Commonwealth of Massachusetts with not less than ten (10) years experience.
Sample 1
ARBITRATION BY ARCHITECTS. Whenever there is a disagreement between the parties with respect to construction by Landlord of Landlord's Work or Tenant's Work, such disagreement shall be definitively determined by the following procedure: Each of Landlord and Tenant shall appoint one (1) independent architect, such two (2) architects will then (within five (5) days of their appointment) appoint a third independent architect licensed in the Commonwealth of Massachusetts with not less than ten (10) years experience. Each architect shall establish within ten (10) days of their appointment the matter in dispute. In case of any dispute with respect to dollar amounts or lengths of time or dates such as the date of Substantial Completion, the dollar amount or length of time or date shall be the average of the two closest determinations by the three (3) architects, with the determination of the architect which was not closest to another architect's determination excluded from such calculation. In case of any dispute not involving dollar amounts or lengths of time or dates (i.e. the approval of plans) the determination by at least two (2) of the three (3) architects shall be required in order to resolve the matter in dispute. Landlord and Tenant shall each bear the cost of the architect selected by them respectively and shall share equally the cost of the third architect. During such arbitration period, the parties agree to cooperate with one another so as to proceed with construction and with their respective obligations hereunder in a timely manner. Each determination under this Section 3.6 shall be binding upon Landlord and Tenant.
Sample 1
AutoNDA by SimpleDocs
ARBITRATION BY ARCHITECTS. 9 3.6 WARRANTY OF LANDLORD’S WORK...................................................................... 10 3.7 INSURANCE – ................................................................................................................ 11
Sample 1

Related to ARBITRATION BY ARCHITECTS

  • Mediation and Arbitration of Disputes An Addendum requiring the Mediation and/or the Arbitration of all disputes between the Parties and/or Brokers arising out of this Lease ¨ is x is not attached to this Lease. LESSOR AND LESSEE HAVE CAREFULLY READ AND REVIEWED THIS LEASE AND EACH TERM AND PROVISION CONTAINED HEREIN, AND BY THE EXECUTION OF THIS LEASE SHOW THEIR INFORMED AND VOLUNTARY CONSENT THERETO. THE PARTIES HEREBY AGREE THAT, AT THE TIME THIS LEASE IS EXECUTED, THE TERMS OF THIS LEASE ARE COMMERCIALLY REASONABLE AND EFFECTUATE THE INTENT AND PURPOSE OF LESSOR AND LESSEE WITH RESPECT TO THE PREMISES. ATTENTION: NO REPRESENTATION OR RECOMMENDATION IS MADE BY THE AMERICAN INDUSTRIAL REAL ESTATE ASSOCIATION OR BY ANY BROKER AS TO THE LEGAL SUFFICIENCY, LEGAL EFFECT, OR TAX CONSEQUENCES OF THIS LEASE OR THE TRANSACTION TO WHICH IT RELATES. THE PARTIES ARE URGED TO:

  • Mediation and Arbitration Any controversy, dispute or claim arising out of or relating to this Agreement or the performance, enforcement, breach, termination or validity thereof, including the determination of the scope of this Agreement to arbitrate, shall first be submitted to non-binding mediation and shall thereafter be determined by final binding arbitration, and not litigation, the agreed venue for mediation and arbitration being in Houston, Texas. The mediation process shall be administered by a mutually acceptable mediator selected in accordance with the Commercial Mediation Rules of the American Arbitration Association (“AAA”). If any dispute remains unresolved between the parties after the mediation process has been completed, either party may then submit any such unresolved dispute to final and binding arbitration pursuant to the Commercial Arbitration rules of AAA, with all matters related to the enforceability of this arbitration agreement and any award rendered pursuant to this agreement to be governed by the Federal Arbitration Act, 9 U.S.C. Section 1-16. The Arbitration Tribunal shall be formed of three (3) arbitrators each of which shall have at least five (5) years’ experience in hotel operation, management, ownership or leasing, one (1) to be appointed by each party and the third (3rd) to be appointed by the American Arbitration Association. The arbitration panel may require and facilitate such discovery as it shall determine is appropriate in the circumstances, taking into account the needs of the parties and the desirability of making discovery expeditious and cost-effective. The arbitration panel shall be empowered to subpoena non-party and party witnesses for deposition and hearing to the full extent provided under the AAA Rules and the Federal Arbitration Act (or the applicable state arbitration statute if the arbitration panel is appointed pursuant to a petition filed in state court). The arbitration panel may also direct the production of documents and other information and the advance identification of witnesses to be called and documents to be admitted. The arbitration panel may issue orders to protect the confidentiality of proprietary information, trade secrets and other sensitive information before it is required to be disclosed in discovery. In addition to monetary damages, or in lieu thereof, the arbitration panel shall have the power to grant all equitable relief (both by way of interim relief and as a part of its final award) as may be granted by any court in the state where the Hotel is located. Monetary damage liability shall be limited to actual damages; the parties hereby waive the right to claim and/or receive punitive damages or exemplary relief. The arbitration panel shall determine whether and to what extent any party is a prevailing party and shall award attorneys’ fees and expenses associated with the arbitration proceeding to the “prevailing party, if any. All proceedings shall be reported by a certified shorthand court reporter and written transcripts of the proceedings shall be prepared and made available to the parties. The fees of the arbitration panel, together with all costs and expenses incurred in conducting the arbitration (but excluding the parties’ respective attorney, witness and related costs and expenses) shall be borne by the party against whom the arbitral award is made and shall be a (the) component of the arbitral award. The arbitration shall take place in Orlando, Florida, and shall be conducted in the English language. The arbitration award shall be final and binding upon the parties hereto and subject to no appeal. Arbitration expenses shall not be an expense in determining House Profit. Judgment upon the award rendered maybe entered into any court having jurisdiction, or applications may be made to such court for an order of enforcement.

  • Arbitration; Other Disputes In the event of any dispute or controversy arising under or in connection with this Agreement, the parties shall first promptly try in good faith to settle such dispute or controversy by mediation under the applicable rules of the American Arbitration Association before resorting to arbitration. In the event such dispute or controversy remains unresolved in whole or in part for a period of thirty (30) days after it arises, the parties will settle any remaining dispute or controversy exclusively by arbitration in Boston, Massachusetts, in accordance with the rules of the American Arbitration Association then in effect. Judgment may be entered on the arbitrator’s award in any court having jurisdiction. Notwithstanding the above, the Company shall be entitled to seek a restraining order or injunction in any court of competent jurisdiction to prevent any continuation of any violation of Paragraph 4 or 5 hereof.

  • Arbitration Clause All disputes arising under this agreement shall be governed by and interpreted in accordance with the laws of New York, without regard to principles of conflict of laws. The parties to this agreement will submit all disputes arising under this agreement to arbitration in New York City, New York before a single arbitrator of the American Arbitration Association (“AAA”). The arbitrator shall be selected by application of the rules of the AAA, or by mutual agreement of the parties, except that such arbitrator shall be an attorney admitted to practice law New York. No party to this agreement will challenge the jurisdiction or venue provisions as provided in this section. No party to this agreement will challenge the jurisdiction or venue provisions as provided in this section. Nothing contained herein shall prevent the party from obtaining an injunction.

  • Settlement by Arbitration Any claim or controversy that arises out of or relates to this agreement, or the breach of it, shall be settled by arbitration in accordance with the rules of the American Arbitration Association. Judgment upon the award rendered may be entered in any court with jurisdiction.

  • GOVERNING LAW; DISPUTES SUBMITTED TO ARBITRATION All disputes arising under this agreement shall be governed by and interpreted in accordance with the laws of the Commonwealth of Massachusetts, without regard to principles of conflict of laws. The parties to this agreement will submit all disputes arising under this agreement to arbitration in Boston, Massachusetts before a single arbitrator of the American Arbitration Association (“AAA”). The arbitrator shall be selected by application of the rules of the AAA, or by mutual agreement of the parties, except that such arbitrator shall be an attorney admitted to practice law in the Commonwealth of Massachusetts. No party to this agreement will challenge the jurisdiction or venue provisions as provided in this section. No party to this agreement will challenge the jurisdiction or venue provisions as provided in this section. Nothing contained herein shall prevent the party from obtaining an injunction.

  • Mediation of Disputes The parties shall endeavor in good faith to settle within 90 days any controversy or claim arising out of or relating to this Agreement or the breach thereof through mediation with JAMS, Endispute or similar organizations. If the controversy or claim is not resolved within 90 days, the parties shall be free to pursue other legal remedies in law or equity.

  • Submission to Arbitration The Respondent Party may agree to the Claimant Party’s proposal of arbitration by responding in writing within ten (10) Business Days following receipt of such proposal. Within five (5) Business Days following receipt of the Respondent Party’s agreement to arbitrate, the Claimant Party may submit the Dispute Item to the American Arbitration Association (“AAA”) for arbitration. No Dispute Item may be submitted for arbitration without the consent of both parties.

  • Arbitration of Disputes Any controversy or claim arising out of or relating to this Agreement or the breach thereof or otherwise arising out of the Executive’s employment or the termination of that employment (including, without limitation, any claims of unlawful employment discrimination whether based on age or otherwise) shall, to the fullest extent permitted by law, be settled by arbitration in any forum and form agreed upon by the parties or, in the absence of such an agreement, under the auspices of the American Arbitration Association (“AAA”) in Boston, Massachusetts in accordance with the Employment Dispute Resolution Rules of the AAA, including, but not limited to, the rules and procedures applicable to the selection of arbitrators. In the event that any person or entity other than the Executive or the Company may be a party with regard to any such controversy or claim, such controversy or claim shall be submitted to arbitration subject to such other person or entity’s agreement. Judgment upon the award rendered by the arbitrator may be entered in any court having jurisdiction thereof. This Section 8 shall be specifically enforceable. Notwithstanding the foregoing, this Section 8 shall not preclude either party from pursuing a court action for the sole purpose of obtaining a temporary restraining order or a preliminary injunction in circumstances in which such relief is appropriate; provided that any other relief shall be pursued through an arbitration proceeding pursuant to this Section 8.

  • Expedited Arbitration A. Notwithstanding the provisions of the Arbitration Article, in the event an amount in dispute hereunder $1,000,000 or less, the parties will submit to an expedited arbitration process with the use of a single arbitrator. The arbitrator will be chosen in accordance with the procedures for selecting an arbitrator in force on the date the arbitration is demanded, established by the XXXX Reinsurance and Insurance Arbitration Society – U.S. (XXXXX).

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!