Common use of ARCHITECT’S RESPONSIBILITIES Clause in Contracts

ARCHITECT’S RESPONSIBILITIES. 3.1.1. The purpose of this Article is to provide the Contractor with information on the role and responsibilities of the Architect. This Article does not direct the Work of the Architect. The Architect’s Work is directed by the Architects’ Contract which is not a part of this Master Facilities Lease. 3.1.2. The Architect shall assist the District in administration of the Contract as described in the Contract Documents, and shall be one of the District's representatives during construction until the time that Final Tenant Improvement Payment is due the Contractor under the Contract Documents. The Architect shall advise and consult with the Construction Manager, Project Manager, and the Project Inspector with respect to the administration of the Contract and the Work. 3.1.3. The Architect is authorized to act on behalf of the District to the extent provided for in the Contract Documents; and shall have the responsibilities and powers established by law, including Title 24 of the California Code of Regulations. Nothing contained in the Contract Documents shall create any Contractual relationship between the Architect and the Contractor. 3.1.4. The Architect shall visit the Site weekly or at intervals appropriate to the stage of construction to become generally familiar with the progress and quality of the completed Work and to determine, in general, if the Work is being performed in a manner indicating that the Work, when completed, shall be in accordance with the Contract Documents. The Architect shall not be required to make exhaustive or continuous Site inspections to check quality or quantity of the Work. On the basis of Site observations as an Architect, the Architect shall keep the District informed of the progress of the Work, and shall endeavor to guard the District against defects and deficiencies in the Work. At the District’s sole discretion, the District may require more frequent site visits by the Architect to prevent Project delays. 3.1.5. The Architect and the Project Inspector are authorized to reject Work that is defective, unsafe, or does not conform to the requirements of the Contract Documents. Whenever the Architect or Project Inspector consider it necessary or advisable, for implementation of the intent of the Contract Documents, the Architect and the Project Inspector shall each have authority to require additional inspections or testing of the Work, whether such Work is fabricated, installed, or completed. 3.1.6. The Architect shall conduct observations to determine the date or dates of Substantial Completion and the date of Final Completion, shall receive and forward to the District, for the District's review and records, written warranties and related documents required by the Contract Documents and assembled by the Contractor, and shall verify that the Contractor has complied with all requirements of the Contract Documents and is entitled to receipt of Final Tenant Improvement Payment. 3.1.7. The Architect shall interpret and decide matters concerning the requirements of the Contract Documents on written request of either the District or the Contractor. The Architect's response to such requests shall be made with reasonable promptness and within the time limits agreed upon, if any, and in no event to exceed a five (5) working day period from receipt of the request. Interpretations and decisions of the Architect shall be consistent with the intent of and reasonably inferable from the Contract Documents and shall be in writing or in the form of Drawings. When making such interpretations and decisions, the Architect shall endeavor to secure faithful performance by both the District and the Contractor, shall not show partiality to either and shall not be liable for results of interpretations or decisions so rendered in good faith.

ARCHITECT’S RESPONSIBILITIES. 3.1.1Architect shall provide schematic drawing, to scale, based upon the contractor provided sketches of the proposed addition. The purpose proposed design consists of this Article is to provide the Contractor with information approximately 708 square feet on the role first floor, consisting of a new master bedroom suite, and responsibilities 724 square feet at the basement level, consisting of a new game room. After a Schematic Design Review Meeting with the Architectclient and contractor, Architect shall incorporate any necessary changes and comments into a final design for approval. This Article does not direct the Work of the ArchitectUpon client approval, Architect shall produce construction drawings including foundation plan, floor plans, elevations, and framing plans for permit. The Architect’s Work is directed by Architect shall provide architectural services for the Architects’ Contract which is not Project as described in this Agreement in a part of this Master Facilities Lease. 3.1.2manner consistent with locally accepted standards for professional skill and care. The Architect shall assist the District Owner in determining consulting services required for the Project. The Architect’s services include the following consulting services, if any: During the Design Phase, the Architect shall review the Owner’s scope of work, budget and schedule and reach an understanding with the Owner of the Project requirements. Based on the approved Project requirements, the Architect shall develop a design. Upon portion of this AIA® Document to another electronic file is prohibited and constitutes a violation of copyright laws as set forth in the footer of this document. the Owner’s approval of the design, the Architect shall prepare Construction Documents indicating requirements for construction of the Project and shall coordinate its services with any consulting services the Owner provides. The Architect shall assist the Owner in filing documents required for the approval of governmental authorities, in obtaining proposals and in awarding contracts for construction. During the Construction Phase, the Architect shall act as the Owner’s representative and provide administration of the Contract as between the Owner and Contractor. The extent of the Architect’s authority and responsibility during construction is described in AIA Document A105™–2007, Standard Form of Agreement Between Owner and Contractor for a Residential or Small Commercial Project. Generally, the Architect’s services during construction include interpreting the Contract Documents, reviewing the Contractor’s submittals, visiting the site, reviewing and shall be one of the District's representatives during construction until the time that Final Tenant Improvement Payment is due the Contractor under the Contract Documents. The Architect shall advise and consult with the Construction Manager, Project Managercertifying payments, and the Project Inspector with respect to the administration of the Contract and the rejecting nonconforming Work. 3.1.3. The Architect is authorized to act on behalf of the District to the extent provided for in the Contract Documents; and shall have the responsibilities and powers established by law, including Title 24 of the California Code of Regulations. Nothing contained in the Contract Documents shall create any Contractual relationship between the Architect and the Contractor. 3.1.4. The Architect shall visit the Site weekly or at intervals appropriate to the stage of construction to become generally familiar with the progress and quality of the completed Work and to determine, in general, if the Work is being performed in a manner indicating that the Work, when completed, shall be in accordance with the Contract Documents. The Architect shall not be required to make exhaustive or continuous Site inspections to check quality or quantity of the Work. On the basis of Site observations as an Architect, the Architect shall keep the District informed of the progress of the Work, and shall endeavor to guard the District against defects and deficiencies in the Work. At the District’s sole discretion, the District may require more frequent site visits by the Architect to prevent Project delays. 3.1.5. The Architect and the Project Inspector are authorized to reject Work that is defective, unsafe, or does not conform to the requirements of the Contract Documents. Whenever the Architect or Project Inspector consider it necessary or advisable, for implementation of the intent of the Contract Documents, the Architect and the Project Inspector shall each have authority to require additional inspections or testing of the Work, whether such Work is fabricated, installed, or completed. 3.1.6. The Architect shall conduct observations to determine the date or dates of Substantial Completion and the date of Final Completion, shall receive and forward to the District, for the District's review and records, written warranties and related documents required by the Contract Documents and assembled by the Contractor, and shall verify that the Contractor has complied with all requirements of the Contract Documents and is entitled to receipt of Final Tenant Improvement Payment. 3.1.7. The Architect shall interpret and decide matters concerning the requirements of the Contract Documents on written request of either the District or the Contractor. The Architect's response to such requests shall be made with reasonable promptness and within the time limits agreed upon, if any, and in no event to exceed a five (5) working day period from receipt of the request. Interpretations and decisions of the Architect shall be consistent with the intent of and reasonably inferable from the Contract Documents and shall be in writing or in the form of Drawings. When making such interpretations and decisions, the Architect shall endeavor to secure faithful performance by both the District and the Contractor, shall not show partiality to either and shall not be liable for results of interpretations or decisions so rendered in good faith.

ARCHITECT’S RESPONSIBILITIES. 3.1.1§ 2.1 The Architect shall provide professional services as set forth in this Agreement. The purpose of this Article Architect represents that it is properly licensed in the jurisdiction where the Project is located to provide the Contractor with information on the role and responsibilities of the Architect. This Article does not direct the Work of the Architect. The Architect’s Work is directed services required by the Architects’ Contract which is not a part of this Master Facilities LeaseAgreement, or shall cause such services to be performed by appropriately licensed design professionals. 3.1.2§ 2.2 The Architect shall perform its services consistent with the professional skill and care ordinarily provided by architects practicing in the same or similar locality under the same or similar circumstances. The Architect shall assist perform its services as expeditiously as is consistent with such professional skill and care and the District in administration orderly progress of the Contract Project. § 2.2.1 Architect hereby represents and agrees that the drawings, specifications and other documents prepared by it pursuant to this Agreement shall be reasonably complete, fully coordinated, and functional, except as described to any deficiencies which are due to causes beyond the control of the Architect, and that the Project, if constructed in accordance with the drawings, specifications and other documents, shall be structurally sound and a complete and properly functioning facility in accordance with the terms of this Agreement. Architect is responsible for assuring that its consultants perform their work strictly in accordance with the requirements of the Agreement. § 2.2.2 Architect shall be responsible for any errors or omissions in the Contract Documentsdrawings, and shall be one of the District's representatives during construction until the time that Final Tenant Improvement Payment is due the Contractor under the Contract Documentsspecifications or other documents. The Architect shall advise will correct, at no additional cost to the Owner, any and consult with all errors, omissions or inconsistencies in the Construction Managerdrawings, Project Manager, specifications and other documents relating to the Project Inspector with respect to over which the administration of the Contract and the Work. 3.1.3Architect had control. The Architect further agrees, at no additional cost, to render assistance to the Owner in resolving problems relating to Architect’s design or specified materials. § 2.2.3 Architect agrees that it is the responsibility of the Architect to make certain that, at the time the project is bid all drawings, specifications and other documents are in accordance with applicable laws, regulations, rules. § 2.2.4 As changes are made to the plans and specifications, changes to the plans and specifications of all disciplines affected will be made, fully coordinated by Architect and promptly issued and used for construction. § 2.3 The Architect shall identify a representative authorized to act on behalf of the District Architect with respect to the extent provided for in the Contract Documents; and shall have the responsibilities and powers established by law, including Title 24 of the California Code of Regulations. Nothing contained in the Contract Documents shall create any Contractual relationship between the Architect and the ContractorProject. 3.1.4. The Architect shall visit the Site weekly or at intervals appropriate to the stage of construction to become generally familiar § 2.4 Except with the progress Owner’s knowledge and quality of the completed Work and to determine, in general, if the Work is being performed in a manner indicating that the Work, when completed, shall be in accordance with the Contract Documents. The Architect shall not be required to make exhaustive or continuous Site inspections to check quality or quantity of the Work. On the basis of Site observations as an Architectconsent, the Architect shall keep not engage in any activity, or accept any employment, interest or contribution that would reasonably appear to compromise the District informed Architect’s professional judgment with respect to this Project. § 2.5 The Architect shall maintain the following insurance until termination of this Agreement. If any of the progress requirements set forth below are in addition to the types and limits the Architect normally maintains, the Owner shall pay the Architect as set forth in Section 11.9. § 2.5.1 Commercial General Liability with policy limits of not less than «one million dollars » ($ «1,000,000 » ) for each occurrence and «two million dollars damage. » ($ «2,000,000 » ) in the Workaggregate for bodily injury and property § 2.5.2 Automobile Liability covering vehicles owned, and shall endeavor to guard the District against defects and deficiencies in the Work. At the District’s sole discretionnon-owned vehicles used, the District may require more frequent site visits by the Architect to prevent Project delayswith policy limits of not less than «one million dollars » ($ «1,000,000 » ) per accident for bodily injury, death of any person, and property damage arising out of the ownership, maintenance and use of those motor vehicles, along with any other statutorily required automobile coverage. 3.1.5. § 2.5.3 The Architect may achieve the required limits and coverage for Commercial General Liability and Automobile Liability through a combination of primary and excess or umbrella liability insurance, provided such primary and excess or umbrella liability insurance policies result in the Project Inspector are authorized to reject Work that is defective, unsafe, same or does not conform to greater coverage as the requirements of the Contract Documents. Whenever the Architect or Project Inspector consider it necessary or advisable, for implementation of the intent of the Contract Documents, the Architect coverages required under Sections 2.5.1 and the Project Inspector shall each have authority to require additional inspections or testing of the Work, whether such Work is fabricated, installed, or completed. 3.1.6. The Architect shall conduct observations to determine the date or dates of Substantial Completion and the date of Final Completion, shall receive and forward to the District, for the District's review and records, written warranties and related documents required by the Contract Documents and assembled by the Contractor, and shall verify that the Contractor has complied with all requirements of the Contract Documents and is entitled to receipt of Final Tenant Improvement Payment. 3.1.7. The Architect shall interpret and decide matters concerning the requirements of the Contract Documents on written request of either the District or the Contractor. The Architect's response to such requests shall be made with reasonable promptness and within the time limits agreed upon, if any2.5.2, and in no event to exceed a five (5) working day period from receipt shall any excess or umbrella liability insurance provide narrower coverage than the primary policy. The excess policy shall not require the exhaustion of the request. Interpretations and decisions of underlying limits only through the Architect shall be consistent with actual payment by the intent of and reasonably inferable from the Contract Documents and shall be in writing or in the form of Drawings. When making such interpretations and decisions, the Architect shall endeavor to secure faithful performance by both the District and the Contractor, shall not show partiality to either and shall not be liable for results of interpretations or decisions so rendered in good faithunderlying insurers.

ARCHITECT’S RESPONSIBILITIES. 3.1.1Architect shall provide schematic drawing, to scale, based upon the contractor provided sketches of the proposed addition. The purpose proposed design consists of this Article is to provide the Contractor with information approximately 708 square feet on the role first floor, consisting of a new master bedroom suite, and responsibilities 724 square feet at the basement level, consisting of a new game room. After a Schematic Design Review Meeting with the Architectclient and contractor, Architect shall incorporate any necessary changes and comments into a final design for approval. This Article does not direct the Work of the ArchitectUpon client approval, Architect shall produce construction drawings including foundation plan, floor plans, elevations, and framing plans for permit. The Architect’s Work is directed by Architect shall provide architectural services for the Architects’ Contract which is not Project as described in this Agreement in a part of this Master Facilities Lease. 3.1.2manner consistent with locally accepted standards for professional skill and care. The Architect shall assist the District Owner in determining consulting services required for the Project. The Architect’s services include the following consulting services, if any: During the Design Phase, the Architect shall review the Owner’s scope of work, budget and schedule and reach an understanding with the Owner of the Project requirements. portion of this AIA® Document to another electronic file is prohibited and constitutes a violation of copyright laws as set forth in the footer of this document. Based on the approved Project requirements, the Architect shall develop a design. Upon the Owner’s approval of the design, the Architect shall prepare Construction Documents indicating requirements for construction of the Project and shall coordinate its services with any consulting services the Owner provides. The Architect shall assist the Owner in filing documents required for the approval of governmental authorities, in obtaining proposals and in awarding contracts for construction. During the Construction Phase, the Architect shall act as the Owner’s representative and provide administration of the Contract as between the Owner and Contractor. The extent of the Architect’s authority and responsibility during construction is described in AIA Document A105™–2007, Standard Form of Agreement Between Owner and Contractor for a Residential or Small Commercial Project. Generally, the Architect’s services during construction include interpreting the Contract Documents, reviewing the Contractor’s submittals, visiting the site, reviewing and shall be one of the District's representatives during construction until the time that Final Tenant Improvement Payment is due the Contractor under the Contract Documents. The Architect shall advise and consult with the Construction Manager, Project Managercertifying payments, and the Project Inspector with respect to the administration of the Contract and the rejecting nonconforming Work. 3.1.3. The Architect is authorized to act on behalf of the District to the extent provided for in the Contract Documents; and shall have the responsibilities and powers established by law, including Title 24 of the California Code of Regulations. Nothing contained in the Contract Documents shall create any Contractual relationship between the Architect and the Contractor. 3.1.4. The Architect shall visit the Site weekly or at intervals appropriate to the stage of construction to become generally familiar with the progress and quality of the completed Work and to determine, in general, if the Work is being performed in a manner indicating that the Work, when completed, shall be in accordance with the Contract Documents. The Architect shall not be required to make exhaustive or continuous Site inspections to check quality or quantity of the Work. On the basis of Site observations as an Architect, the Architect shall keep the District informed of the progress of the Work, and shall endeavor to guard the District against defects and deficiencies in the Work. At the District’s sole discretion, the District may require more frequent site visits by the Architect to prevent Project delays. 3.1.5. The Architect and the Project Inspector are authorized to reject Work that is defective, unsafe, or does not conform to the requirements of the Contract Documents. Whenever the Architect or Project Inspector consider it necessary or advisable, for implementation of the intent of the Contract Documents, the Architect and the Project Inspector shall each have authority to require additional inspections or testing of the Work, whether such Work is fabricated, installed, or completed. 3.1.6. The Architect shall conduct observations to determine the date or dates of Substantial Completion and the date of Final Completion, shall receive and forward to the District, for the District's review and records, written warranties and related documents required by the Contract Documents and assembled by the Contractor, and shall verify that the Contractor has complied with all requirements of the Contract Documents and is entitled to receipt of Final Tenant Improvement Payment. 3.1.7. The Architect shall interpret and decide matters concerning the requirements of the Contract Documents on written request of either the District or the Contractor. The Architect's response to such requests shall be made with reasonable promptness and within the time limits agreed upon, if any, and in no event to exceed a five (5) working day period from receipt of the request. Interpretations and decisions of the Architect shall be consistent with the intent of and reasonably inferable from the Contract Documents and shall be in writing or in the form of Drawings. When making such interpretations and decisions, the Architect shall endeavor to secure faithful performance by both the District and the Contractor, shall not show partiality to either and shall not be liable for results of interpretations or decisions so rendered in good faith.

ARCHITECT’S RESPONSIBILITIES. 3.1.1§ 2.1 The Architect shall provide the professional services as set forth in this Agreement. The purpose of this Article Architect represents that it is properly licensed in the jurisdiction where the Project is located to provide the Contractor with information on services required by this Agreement, or shall cause such services to be performed by appropriately licensed design professionals. The Architect shall be and operate as an independent contractor in the role and responsibilities performance of the Architectservices and shall have control over and responsibility for all personnel performing the services. In no event shall the Architect be authorized on behalf of the Owner: to enter into any Contracts or undertakings; to waive any provisions of the Contract Documents; to receive contractual notice on behalf of the Owner; to execute any Certificate for Payment, Change Order or other document; to authorize any payments or accept or approve any documents, work, services, goods or materials which result in a change in the Contract Sum or Contract Time, without prior written approval of the Owner. This Article does not direct Agreement covers services provided by Architect and its consultants prior to the date hereof. § 2.2 The Architect shall perform its services consistent with the professional skill and care ordinarily provided by architects practicing in the same or similar locality under the same or similar circumstances. The Architect shall perform its services as expeditiously as is consistent with such professional skill and care and the orderly progress of the Project. The Architect will perform this Agreement and render decisions in a timely manner to avoid delay in the progress of the Project and the Work of the Architect. The Architect’s Work is directed by the Architects’ Contract which is not a part of this Master Facilities Lease. 3.1.2Contractor. The Architect shall assist work cooperatively to obtain for the District in administration Owner the improvements covered by the Owner’s program and scope of Work at the Contract as described in the Contract Documentslowest cost consistent with quality workmanship, materials, and shall be one of the District's representatives during construction until the time that Final Tenant Improvement Payment is due the Contractor under the Contract Documentsdurability. The Architect shall advise shall, at no cost to the Owner, promptly and consult satisfactorily correct any services Owner reasonably finds to be defective or not in conformity with the Construction Manager, Project Manager, and the Project Inspector with respect to the administration requirements of the Contract and the Workthis Agreement. 3.1.3. § 2.3 The Architect is Architect’s representative authorized to act on behalf of the District Architect with respect to the extent provided for Project is identified in the Contract Documents; and shall have the responsibilities and powers established by law, including Title 24 of the California Code of Regulations. Nothing contained in the Contract Documents shall create any Contractual relationship between the Architect and the Contractor. 3.1.4Section 1.1.10. The Architect shall visit the Site weekly or at intervals appropriate Architect's representative will devote all of his time as necessary to the stage of construction to become generally familiar Project as § 2.4 Except with the progress Owner’s knowledge and quality of the completed Work and to determine, in general, if the Work is being performed in a manner indicating that the Work, when completed, shall be in accordance with the Contract Documents. The Architect shall not be required to make exhaustive or continuous Site inspections to check quality or quantity of the Work. On the basis of Site observations as an Architectconsent, the Architect shall keep not engage in any activity, or accept any employment, interest or contribution that would reasonably appear to compromise the District informed of the progress of the Work, and shall endeavor Architect’s professional judgment with respect to guard the District against defects and deficiencies in the Work. At the District’s sole discretion, the District may require more frequent site visits by the Architect to prevent Project delaysthis Project. 3.1.5. The Architect and the Project Inspector are authorized to reject Work that is defective, unsafe, or does not conform to the requirements of the Contract Documents. Whenever the Architect or Project Inspector consider it necessary or advisable, for implementation of the intent of the Contract Documents, the Architect and the Project Inspector shall each have authority to require additional inspections or testing of the Work, whether such Work is fabricated, installed, or completed.§ 2.5 Insurance 3.1.6. § 2.5.1 The Architect shall conduct observations to determine procure and maintain at its expense during the date or dates of Substantial Completion and the date of Final Completion, shall receive and forward to the District, for the District's review and records, written warranties and related documents required by the Contract Documents and assembled by the Contractor, and shall verify that the Contractor has complied with all requirements performance of the Contract Documents Agreement and is entitled thereafter as required below the following insurance from one or more companies authorized to receipt of Final Tenant Improvement Payment. 3.1.7. The Architect shall interpret and decide matters concerning the requirements of the Contract Documents on written request of either the District or the Contractor. The Architect's response to such requests shall be made with reasonable promptness and within the time limits agreed upon, if any, and in no event to exceed a five (5) working day period from receipt of the request. Interpretations and decisions of the Architect shall be consistent with the intent of and reasonably inferable from the Contract Documents and shall be in writing or do business in the form State of Drawings. When making such interpretations and decisions, Oregon with a policyholder’s rating of not less than A-­IX in the Architect shall endeavor to secure faithful performance by both the District and the Contractor, shall not show partiality to either and shall not be liable for results most recent edition of interpretations or decisions so rendered in good faithBest’s Rating Guide.

ARCHITECT’S RESPONSIBILITIES. 3.1.1§ 2.1 The Architect shall provide professional services as set forth in this Agreement. The purpose of this Article Architect represents that it is properly licensed in the jurisdiction where the Project is located to provide the Contractor services required by this Agreement, or shall cause such services to be performed by appropriately licensed design professionals. § 2.2 The Architect shall perform its services consistent with information on the role professional skill and responsibilities care ordinarily provided by architects practicing in the same or similar locality under the same or similar circumstances. The Architect shall perform its services as expeditiously as is consistent with such professional skill and care and the orderly progress of the Project.The Architect shall submit for the Owner’s approval a schedule for the performance of the Architect. This Article does not direct the Work of the Architect’s services. The Architect’s Work services shall be performed as diligently and expeditiously as is directed consistent with the professional skill and care ordinarily provided by Architects under the Architects’ Contract same or similar circumstances and the orderly progress of the Project, taking into account the agreed upon schedule which is not a part of this Master Facilities Lease.initially shall be consistent with the time periods established in Exhibit D. 3.1.2. § 2.3 The Architect shall assist the District in administration of the Contract as described in the Contract Documents, and shall be one of the District's representatives during construction until the time that Final Tenant Improvement Payment is due the Contractor under the Contract Documents. The Architect shall advise and consult with the Construction Manager, Project Manager, and the Project Inspector with respect to the administration of the Contract and the Work. 3.1.3. The Architect is identify a representative authorized to act on behalf of the District Architect with respect to the extent provided for in Project. § 2.4 Except with the Contract Documents; Owner’s knowledge and shall have the responsibilities and powers established by lawconsent, including Title 24 of the California Code of Regulations. Nothing contained in the Contract Documents shall create any Contractual relationship between the Architect and shall not engage in any activity, or accept any employment, interest or contribution that would reasonably appear to compromise the ContractorArchitect’s professional judgment with respect to this Project. 3.1.4§ 2.5 The Architect shall review laws, codes, and regulations applicable to the Architect’s services. The Architect shall visit prepare the Site weekly or at intervals appropriate design of the Project to meet the stage of construction to become generally familiar requirements imposed by governmental authorities having jurisdiction over the Project. § 2.6 The Architect shall perform all architectural and design services with the progress professional skill and quality care ordinarily provided by architects practicing in the State of Georgia under the completed Work and to determine, in general, if the Work is being performed in a manner indicating that the Work, when completed, shall be in accordance with the Contract Documentssame or similar circumstances. The Architect shall not be required responsible for the Architect’s negligent and other wrongful acts and omissions. It is the intent to make exhaustive have a very deliberate design review process with Owner, Architect and Contractor to sign off after each phase of service and thus minimizing the potential for subjective opinions regarding overall design details. § 2.7 The Architect and its consultants, subcontractors, and agents shall promptly, upon notice or continuous Site inspections to check quality or quantity of the Work. On the basis of Site observations as an Architectdiscovery, the Architect shall keep the District informed of the progress during any phase of the Work, and shall endeavor to guard the District against defects and deficiencies make necessary revisions or corrections of errors, ambiguities or omissions in the Work. At the District’s sole discretion, the District may require more frequent site visits by the Architect to prevent Project delaysdrawings and specifications without additional compensation. 3.1.5. The Architect and the Project Inspector are authorized to reject Work that is defective, unsafe, or does not conform to the requirements of the Contract Documents. Whenever the Architect or Project Inspector consider it necessary or advisable, for implementation of the intent of the Contract Documents, the Architect and the Project Inspector shall each have authority to require additional inspections or testing of the Work, whether such Work is fabricated, installed, or completed. 3.1.6. The Architect shall conduct observations to determine the date or dates of Substantial Completion and the date of Final Completion, shall receive and forward to the District, for the District's review and records, written warranties and related documents required by the Contract Documents and assembled by the Contractor, and shall verify that the Contractor has complied with all requirements of the Contract Documents and is entitled to receipt of Final Tenant Improvement Payment. 3.1.7. The Architect shall interpret and decide matters concerning the requirements of the Contract Documents on written request of either the District or the Contractor. The Architect's response to such requests shall be made with reasonable promptness and within the time limits agreed upon, if any, and in no event to exceed a five (5) working day period from receipt of the request. Interpretations and decisions of the Architect shall be consistent with the intent of and reasonably inferable from the Contract Documents and shall be in writing or in the form of Drawings. When making such interpretations and decisions, the Architect shall endeavor to secure faithful performance by both the District and the Contractor, shall not show partiality to either and shall not be liable for results of interpretations or decisions so rendered in good faith.

ARCHITECT’S RESPONSIBILITIES. 3.1.11.1.1 The Architect's services consist of those services performed by the Architect, Architect's employees and Architect's subconsultants as enumerated in Articles 2 and 3 of this Agreement and any other services included in Article 12. 1.1.2 The Architect's services shall be performed as expeditiously as is consistent with professional skill and care and the orderly progress of the Work. The purpose Architect shall adhere to the in Article 6 of the Supplemental Conditions. The schedule includes allowances for periods of time required for the Owner's review and for approval of submissions by authorities having jurisdiction over the Project. The schedule, shall not be extended by the Architect without prior notice and written approval of the Owner. 1.1.3 The Architect and its subconsultants, subconsultants, agents, employees and officers shall promptly, upon notice or discovery, during any phase of the Project, make necessary revisions or corrections of errors, ambiguities or omissions in the drawings and specifications without additional compensation or expense to the Owner. 1.1.4 The Architect shall comply with written directives, memoranda, and "The Supplemental Conditions and Procedures for Architects and Engineers", dated, September 3, 1997, Revised October 23, 1999, as issued by the Owner, is hereby made a part of, and incorporated into, the terms of this Article Agreement. If there are any conflicts between "The Standard Form of Agreement Between Owner and Architect" and "The Supplemental Conditions and Procedures for Architects and Engineers", the Owner-Architect Agreement prevails. 1.1.5 It is understood between the parties that, under conditions where the Owner deems it beneficial to provide the Contractor project, the Architect may be working in coordination and cooperation with information on other Consultants who will be employed independently by the role Owner and responsibilities responsible to the Owner for their work and the performance of their respective agreements with the ArchitectOwner. This Article does The Architect and its Consultants shall cooperate with the Owner and other Consultants in a manner to assure that the Project is not direct adversely affected and that the Work of the Architect. The Architect’s Work 's portion of the Project is directed by the Architects’ Contract which is not a part of this Master Facilities Leasecarried out expeditiously. 3.1.2. 1.1.6 The Architect shall assist the District in administration of the prepare all Project Documents (Bidding Documents and Contract as described in the Contract Modification Documents, and shall be one of the District's representatives during construction until the time that Final Tenant Improvement Payment is due the Contractor under the Contract Documents. The Architect shall advise and consult with the Construction Manager, Project Manager, and the Project Inspector with respect to the administration of the Contract and the Work. 3.1.3. The Architect is authorized to act on behalf of the District to the extent provided for in the Contract Documents; and shall have the responsibilities and powers established by law, including Title 24 of the California Code of Regulations. Nothing contained in the Contract Documents shall create any Contractual relationship between the Architect and the Contractor. 3.1.4. The Architect shall visit the Site weekly or at intervals appropriate to the stage of construction to become generally familiar with the progress and quality of the completed Work and to determine, in general, if the Work is being performed in a manner indicating that the Work, when completed, shall be ) in accordance with the Contract Documentsrequirements stated in Department of Education's, Florida Administrative Code (FAC), Florida Building Code (FBC) in effect at the time of the execution of this Agreement and/or document review, as well as any changes in the code during the term of this Agreement and "The Supplemental Conditions and Procedures for Architects and Engineers". The Architect shall not be required to make exhaustive or continuous Site inspections to check quality or quantity format of the Work. On documents shall be according to the basis latest version of Site observations as an the District Master Specifications. 1.1.7 The Architect's and Engineer’s Project Documents shall include, but are not limited to, the Architect shall keep the District informed preparation of the progress of the Work, drawings and shall endeavor to guard the District against defects and deficiencies in the Work. At the District’s sole discretion, the District may require more frequent site visits by the Architect to prevent Project delays. 3.1.5. The Architect and the Project Inspector are authorized to reject Work that is defective, unsafe, or does not conform to the requirements of the Contract Documents. Whenever the Architect or Project Inspector consider it necessary or advisable, for implementation of the intent of the Contract Documents, the Architect and the Project Inspector shall each have authority to require additional inspections or testing of the Work, whether such Work is fabricated, installed, or completed. 3.1.6. The Architect shall conduct observations to determine the date or dates of Substantial Completion and the date of Final Completion, shall receive and forward to the Districtspecifications, for the District's review and records, written warranties and related documents required by the Contract Documents and assembled by the Contractor, and shall verify that the Contractor has complied with all requirements following elements of the Contract Documents and is entitled to receipt of Final Tenant Improvement Payment. 3.1.7. The Architect shall interpret and decide matters concerning the requirements of the Contract Documents on written request of either the District or the Contractor. The Architect's response to such requests shall be made with reasonable promptness and within the time limits agreed upon, if any, and in no event to exceed a five Project: (5a) working day period from receipt of the request. Interpretations and decisions of the Architect shall be consistent with the intent of and reasonably inferable from the Contract Documents and shall be in writing or in the form of Drawings. When making such interpretations and decisions, the Architect shall endeavor to secure faithful performance by both the District and the Contractor, shall not show partiality to either and shall not be liable for results of interpretations or decisions so rendered in good faith.Architectural -

ARCHITECT’S RESPONSIBILITIES. 3.1.1§ 2.1 The Architect shall provide professional services as set forth in this Agreement. The purpose of this Article Architect represents that it is properly licensed in the jurisdiction where the Project is located to provide the Contractor with information on the role and responsibilities of the Architect. This Article does not direct the Work of the Architect. The Architect’s Work is directed services required by the Architects’ Contract which is not a part of this Master Facilities LeaseAgreement, or shall cause such services to be performed by appropriately licensed design professionals. 3.1.2§ 2.2 The Architect shall perform its services consistent with the professional skill and care ordinarily provided by architects practicing in the same or similar locality under the same or similar circumstances. The Architect shall assist perform its services as expeditiously as is consistent with such professional skill and care and the District in administration orderly progress of the Contract as described in the Contract Documents, and shall be one of the District's representatives during construction until the time that Final Tenant Improvement Payment is due the Contractor under the Contract DocumentsProject. The Architect shall advise and consult with satisfy the Construction Manager, Project Manager, and requirements for the lawful practice of architecture in the state where the Project Inspector with respect to the administration of the Contract and the Workis located. 3.1.3. § 2.3 The Architect is shall identify a representative authorized to act on behalf of the District Architect with respect to the extent provided for Project. The representative shall be a Principal in Charge. § 2.4 Except with the Contract Documents; Owner’s knowledge and consent, the Architect shall have not engage in any activity, or accept any employment, interest or contribution that would reasonably appear to compromise the responsibilities and powers established by law, including Title 24 Architect’s professional judgment with respect to this Project. § 2.5 The Architect shall maintain the following insurance until termination of this Agreement. If any of the California Code of Regulations. Nothing contained requirements set forth below are in addition to the Contract Documents shall create any Contractual relationship between types and limits the Architect and normally maintains, the Contractor. 3.1.4Owner shall pay the Architect as set forth in Section 11.9. The Architect shall visit the Site weekly or at intervals appropriate furnish to the stage Owner annually, unless otherwise requested, during the active terms of construction this Agreement, a certificate from an Insurance Carrier authorized to become generally familiar with do business in the progress and quality location of the completed Work Project indicating: 1) the existence of the insurance required under this section; 2) the amount of deductible; and to determine, in general, if 3) the Work is being performed in a manner indicating that the Work, when completed, shall be in accordance with the Contract Documentsamount of coverage of such insurance. The Architect shall not be required to make exhaustive or continuous Site inspections to check quality or quantity submit a Certificate of Insurance covering the Professional Liability Insurance requirement for one year beyond the Substantial Completion Date of the WorkProject. On During any period in which the basis Architect is not in compliance with the terms of Site observations as an this Article, no compensation will be paid by the Owner to the Architect. It is agreed that the Architect will indemnify and hold harmless the Owner, its officers, its employees and its Designated Representative from any claim or liability of any type, including, without limitation, loss of use, reasonable counsel fees and defense costs, resulting from the Architect’s negligence or that of its employees or subcontractors, in the performance of work under this contract. In the event that the Architect is requested and refuses to honor the indemnity provisions hereunder, then, in addition to all other obligations, and upon adjudication of the Architect’s liability for indemnification, the Architect shall keep pay the District informed cost of bringing any such action, including attorney’s fees, to the progress Owner. § 2.5.1 Commercial General Liability with policy limits of the Work, not less than « » ($ « » ) for each occurrence and shall endeavor to guard the District against defects and deficiencies « » ($ « » ) in the Work. At the District’s sole discretion, the District may require more frequent site visits by the Architect to prevent Project delaysaggregate for bodily injury and property damage. 3.1.5. The Architect and the Project Inspector are authorized to reject Work that is defective, unsafe, or does not conform to the requirements of the Contract Documents. Whenever the Architect or Project Inspector consider it necessary or advisable, for implementation of the intent of the Contract Documents, the Architect and the Project Inspector shall each have authority to require additional inspections or testing of the Work, whether such Work is fabricated, installed, or completed. 3.1.6. § 2.5.1.1 The Architect shall conduct observations secure and maintain at its sole cost and expense, adequate General Liability Insurance to determine protect the date or dates of Substantial Completion Owner and the date of Final Completion, shall receive and forward to the District, for the District's review and records, written warranties and related documents required by the Contract Documents and assembled by the Contractor, and shall verify that the Contractor has complied with all requirements its employees against claims arising out of the Contract Documents Architect’s services during the design and is entitled to receipt construction of Final Tenant Improvement Payment. 3.1.7the Project for damages in law or equity for property damage and personal injury, including wrongful death. The Architect shall interpret and decide matters concerning the requirements of the Contract Documents on written request of either the District or the Contractor. The Architect's response to such requests Owner shall be made with reasonable promptness named as an additional insured in the policy and within the time limits agreed upon, if any, and in no event to exceed a five (5) working day period from receipt of the request. Interpretations and decisions of the Architect shall be consistent with the intent of and reasonably inferable from the Contract Documents and shall be in writing or in the form of Drawings. When making such interpretations and decisions, the Architect shall endeavor to secure faithful performance by both the District and the Contractor, shall not show partiality to either and shall not be liable for results of interpretations or decisions so rendered in good faith.submit a

ARCHITECT’S RESPONSIBILITIES. 3.1.1§ 2.1 The Architect shall provide professional services as set forth in this Agreement. The purpose of this Article Architect represents that it is properly licensed in the jurisdiction where the Project is located to provide the Contractor with information on the role and responsibilities of the Architect. This Article does not direct the Work of the Architect. The Architect’s Work is directed services required by the Architects’ Contract which is not a part of this Master Facilities LeaseAgreement, or shall cause such services to be performed by appropriately licensed design professionals. 3.1.2§ 2.2 The Architect shall perform its services consistent with the professional skill, care and duty ordinarily provided and owing to owners by architects practicing in the same or similar locality under the same or similar circumstances. The Architect shall assist perform its services as expeditiously as is consistent with such professional skill and care and the District in administration orderly progress of the Contract as described in the Contract Documents, and shall be one of the District's representatives during construction until the time that Final Tenant Improvement Payment is due the Contractor under the Contract DocumentsProject. The Architect shall advise be responsible, at its own expense, for all drawings, specifications, sketches, site visits, shop drawing/submittal reviews and consult any other services required to respond to or resolve issues with the Construction Manager, Project Manager, and the Project Inspector with respect or changes to the administration of bid/Contract Documents caused by the Contract and the WorkArchitect’s negligent errors or omissions. 3.1.3. § 2.3 The Architect is shall identify a representative authorized to act on behalf of the District Architect with respect to the extent provided for in Project. § 2.4 Except with the Contract Documents; Owner’s knowledge and shall have the responsibilities and powers established by lawconsent, including Title 24 of the California Code of Regulations. Nothing contained in the Contract Documents shall create any Contractual relationship between the Architect and shall not engage in any activity, or accept any employment, interest or contribution that would reasonably appear to compromise the ContractorArchitect’s professional judgment with respect to this Project. 3.1.4. § 2.5 The Architect shall visit indemnify, hold harmless and, at the Site weekly Owner’s option, defend the Owner, its officers, agents and employees, from third party claims for loss, cost, damage, liability, and/or injury to or at intervals appropriate death of a person, including the agents and employees of the Architect, or loss of or damage to property, resulting directly or indirectly from the Architect’s negligent performance pursuant to this Agreement, or by any negligent omission to perform some duty imposed by law or this Agreement upon the Architect, its officers, agents and employees. The foregoing § 2.6 The Architect shall maintain insurance until termination of this Agreement pursuant to the stage Architect’s Approved Certificate of construction to become generally familiar with the progress and quality Insurance, attached hereto as Exhibit B-1. If any of the completed Work requirements set forth therein are in addition to the types and to determinelimits the Architect normally maintains, in general, if the Work is being performed in a manner indicating that the Work, when completed, shall be in accordance with the Contract Documents. The Architect Owner shall not be required to make exhaustive or continuous Site inspections to check quality or quantity of the Work. On the basis of Site observations as an Architect, pay the Architect shall keep the District informed of the progress of the Work, and shall endeavor to guard the District against defects and deficiencies as set forth in the Work. At the District’s sole discretion, the District may require more frequent site visits by the Architect to prevent Project delaysSection 11.9. 3.1.5. The Architect and the Project Inspector are authorized to reject Work that is defective, unsafe, or does not conform to the requirements of the Contract Documents. Whenever the Architect or Project Inspector consider it necessary or advisable, for implementation of the intent of the Contract Documents, the Architect and the Project Inspector shall each have authority to require additional inspections or testing of the Work, whether such Work is fabricated, installed, or completed. 3.1.6. § 2.6.1 The Architect shall conduct observations to determine the date or dates provide certificates of Substantial Completion and the date of Final Completion, shall receive and forward insurance to the District, for the District's review and records, written warranties and related documents required by the Contract Documents and assembled by the Contractor, and shall verify Owner that the Contractor has complied evidence compliance with all requirements of the Contract Documents and is entitled to receipt of Final Tenant Improvement Payment. 3.1.7. The Architect shall interpret and decide matters concerning the requirements of the Contract Documents on written request of either the District or the Contractor. The Architect's response to such requests shall be made with reasonable promptness and within the time limits agreed upon, if any, and in no event to exceed a five (5) working day period from receipt of the request. Interpretations and decisions of the Architect shall be consistent with the intent of and reasonably inferable from the Contract Documents and shall be in writing or in the form of Drawings. When making such interpretations and decisions, the Architect shall endeavor to secure faithful performance by both the District and the Contractor, shall not show partiality to either and shall not be liable for results of interpretations or decisions so rendered in good faiththis Section 2.6.

ARCHITECT’S RESPONSIBILITIES. 3.1.1§ 2.1 The Architect shall provide the professional services as set forth in this Agreement. In providing its services for the Project, the Architect shall at all times exercise not less than the standard of professional care customarily exercised by nationally-recognized architecture firms practicing in the State of Texas performing services similar to those required by this Agreement and for the Project. The purpose services and deliverables provided by the Architect shall comply with all laws, codes, statutes, ordinances, orders, rules and regulations of this Article all federal, state, county and local governmental agencies having jurisdiction over the Project and the Project’s design and construction (“Laws”). § 2.2 The Architect shall perform its services as expeditiously as is consistent with such professional skill and care and the orderly progress of the Project and in conformance with the Architect’s Schedule as modified from time to provide time in coordination with the Contractor with information on overall Project Schedule. Architect shall not be liable for any Project delay except to the role and responsibilities extent such delay is caused by the breach of contract or other legal duty, negligence or negligent misrepresentation of the Architect. This Article does not direct the Work of the Architect. The Architect’s Work is directed by the Architects’ Contract which is not a part of this Master Facilities Lease. 3.1.2§ 2.3 The Architect shall provide its services in conjunction with the services of a Construction Manager. The Architect shall assist not be responsible for actions taken by the District in administration Construction Manager except to the extent such actions are caused by the breach of contract or other legal duty, negligence or negligent misrepresentation of the Contract as described in the Contract Documents, and shall be one of the District's representatives during construction until the time that Final Tenant Improvement Payment is due the Contractor under the Contract Documents. Architect. § 2.4 The Architect shall advise and consult with the Construction Manager, Project Manager, and the Project Inspector with respect to the administration of the Contract and the Work. 3.1.3. The Architect is identify a representative authorized to act on behalf of the District Architect with respect to the extent Project. § 2.5 Except with the Owner’s knowledge and prior written consent, the Architect shall not engage in any activity, or accept any employment, interest or contribution that would reasonably appear to compromise the Architect’s professional judgment with respect to this Project. § 2.6 The Architect is responsible for the overall coordination and management of the entire Project design including, without limitation, any elements of the Project design provided for by or through the Owner or Construction Manager. imitation, the Architect’s ollo The Architect shall provide its services in cooperation with the Contract Documents; services provided by Owner and Owner’s consultants and contractors including, without limitation, the Program Manager and Construction Manager (collectively, “Owner’s consultants and contractors”) and shall have the responsibilities coordinate its services with those services provided by Owner and powers established by law, including Title 24 of the California Code of Regulations. Nothing contained in the Contract Documents shall create any Contractual relationship between the Architect Owner’s consultants and the Contractor. 3.1.4contractors. The Architect shall visit be entitled to rely on the Site weekly or at intervals appropriate accuracy and completeness of services and information furnished by Owner and Owner’s consultants and contractors except to the stage of construction extent Architect knew or should have known such information was incomplete or in error. The Architect shall provide prompt written notice to become generally familiar with the progress Owner and quality of the completed Work and to determine, in general, Program Manager if the Work is being performed in a manner indicating that the WorkArchitect becomes aware of any error, when completed, shall be in accordance with the Contract Documentsomi such services or information. The Architect shall not be required held responsible for Owner’s cons work, services, conduct or finished product except to make exhaustive or continuous Site inspections to check quality or quantity the extent of the Work. On the basis of Site observations as an Architect, the Architect shall keep the District informed of the progress of the Work, and shall endeavor to guard the District against defects and deficiencies in the Work. At the District’s sole discretion, the District may require more frequent site visits a Loss caused by the neg misrepresentation or breach of contract or other legal duty by Architect including, without l duty to prevent Project delayscoordinate and manage the overall design. 3.1.5. The Architect and the Project Inspector are authorized to reject Work that is defective, unsafe, or does not conform to the requirements of the Contract Documents. Whenever the Architect or Project Inspector consider it necessary or advisable, for implementation of the intent of the Contract Documents, the Architect and the Project Inspector shall each have authority to require additional inspections or testing of the Work, whether such Work is fabricated, installed, or completed. 3.1.6. The Architect shall conduct observations to determine the date or dates of Substantial Completion and the date of Final Completion, shall receive and forward to the District, for the District's review and records, written warranties and related documents required by the Contract Documents and assembled by the Contractor, and shall verify that the Contractor has complied with all requirements of the Contract Documents and is entitled to receipt of Final Tenant Improvement Payment. 3.1.7. The Architect shall interpret and decide matters concerning the requirements of the Contract Documents on written request of either the District or the Contractor. The Architect's response to such requests shall be made with reasonable promptness and within the time limits agreed upon, if any, and in no event to exceed a five (5) working day period from receipt of the request. Interpretations and decisions of the Architect shall be consistent with the intent of and reasonably inferable from the Contract Documents and shall be in writing or in the form of Drawings. When making such interpretations and decisions, the Architect shall endeavor to secure faithful performance by both the District and the Contractor, shall not show partiality to either and shall not be liable for results of interpretations or decisions so rendered in good faith.

ARCHITECT’S RESPONSIBILITIES. 3.1.1§ 2.1 The Architect shall provide professional services as set forth in this Agreement. The purpose of this Article Architect represents that it is properly licensed in the jurisdiction where the Project is located to provide the Contractor with information on the role and responsibilities of the Architect. This Article does not direct the Work of the Architect. The Architect’s Work is directed services required by the Architects’ Contract which is not a part of this Master Facilities LeaseAgreement or shall cause such services to be performed by appropriately licensed design professionals. 3.1.2§ 2.2 The Architect shall perform its services consistent with the professional skill and care ordinarily provided by architects practicing in the same or similar locality under the same or similar circumstances. The Architect shall assist perform its services as expeditiously as is consistent with such professional skill and care and the District in administration orderly progress of the Contract Project. § 2.3 The Architect shall provide its services in conjunction with the services of a Construction Manager as described in AIA Document C132™–2019, Standard Form of Agreement Between Owner and Construction Manager as Adviser, as amended by the Contract Documents, and shall be one of the District's representatives during construction until the time that Final Tenant Improvement Payment is due the Contractor under the Contract Documentsparties. The Architect shall advise and consult with not be responsible for actions taken by the Construction Manager. All references to AIA Document C132-2019, Project Standard Form of Agreement between Owner and Construction Manager, and shall mean such Standard Form of Agreement as it may be modified by the Project Inspector with respect to the administration of the Contract and the Work.Owner and 3.1.3. § 2.4 The Architect is shall identify a representative authorized to act on behalf of the District Architect with respect to the extent provided for in Project. If at any time during the Contract Documents; Project any such representative becomes unacceptable to the Owner (on any lawful basis), the Architect will replace him/her with another representative who is mutually acceptable to the Owner and shall have Architect. The members of the Architect’s design Team working on this Project, along with their responsibilities and powers established by law, including Title 24 of the California Code of Regulations. Nothing contained qualifications are set out in the Contract Documents shall create any Contractual relationship between the Architect and the Contractor.an attached Exhibit D. 3.1.4. The Architect shall visit the Site weekly or at intervals appropriate to the stage of construction to become generally familiar § 2.5 Except with the progress Owner’s knowledge and quality of the completed Work and to determine, in general, if the Work is being performed in a manner indicating that the Work, when completed, shall be in accordance with the Contract Documents. The Architect shall not be required to make exhaustive or continuous Site inspections to check quality or quantity of the Work. On the basis of Site observations as an Architectconsent, the Architect shall keep not engage in any activity, or accept any employment, interest or contribution that would reasonably appear to compromise the District informed Architect’s professional judgment with respect to this Project. § 2.6 The Architect shall maintain the following insurance for the duration of this Agreement and shall maintain Products and Completed Operations insurance coverage in effect for a period of two (2) years after Final Completion of the progress of the Work, and shall endeavor Work to guard the District against defects and deficiencies in the Work. At the District’s sole discretion, the District may require more frequent site visits by the Architect to prevent Project delays. 3.1.5. The Architect and the Project Inspector are authorized to reject Work that is defective, unsafe, or does not conform to the requirements of be performed under the Contract Documents. Whenever the Architect or Project Inspector consider it necessary or advisable, for implementation of the intent of the Contract Documents, the Architect and the Project Inspector shall each have authority to require additional inspections or testing of the Work, whether such Work is fabricated, installed, or completed. 3.1.6. The Architect shall conduct observations to determine the date or dates of Substantial Completion and the date of Final Completion, shall receive and forward to the District, for the District's review and records, written warranties and related documents required by the Contract Documents and assembled by the Contractor, and shall verify that the Contractor has complied with all requirements of the Contract Documents and is entitled to receipt of Final Tenant Improvement Payment. 3.1.7. The Architect shall interpret and decide matters concerning the requirements of the Contract Documents on written request of either the District or the Contractor. The Architect's response to such requests shall be made with reasonable promptness and within the time limits agreed upon, if any, and in no event to exceed a five (5) working day period from receipt of the request. Interpretations and decisions of the Architect shall be consistent with the intent of and reasonably inferable from the Contract Documents and shall be in writing or in the form of Drawings. When making such interpretations and decisions, the Architect shall endeavor to secure faithful performance by both the District and the Contractor, shall not show partiality to either and shall not be liable for results of interpretations or decisions so rendered in good faith.