Assumption of Cypress Construction Loan and Cypress Receivables Loan Sample Clauses

Open Split View

Download

Share

Cite

Assumption of Cypress Construction Loan and Cypress Receivables Loan 

Sample 1

Save

Copy

Related to Assumption of Cypress Construction Loan and Cypress Receivables Loan

• Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

• Compliance of Agreement, Loan Documents and Borrowing with Laws, Etc The execution, delivery and performance by each Credit Party of the Loan Documents to which each such Person is a party, in accordance with their respective terms, the Extensions of Credit hereunder and the transactions contemplated hereby or thereby do not and will not, by the passage of time, the giving of notice or otherwise, (a) require any Governmental Approval or violate any Applicable Law relating to any Credit Party where the failure to obtain such Governmental Approval or such violation could reasonably be expected to have a Material Adverse Effect, (b) conflict with, result in a breach of or constitute a default under the articles of incorporation, bylaws or other organizational documents of any Credit Party, (c) conflict with, result in a breach of or constitute a default under any indenture, agreement or other instrument to which such Person is a party or by which any of its properties may be bound or any Governmental Approval relating to such Person, which could, individually or in the aggregate, reasonably be expected to have a Material Adverse Effect, (d) result in or require the creation or imposition of any Lien upon or with respect to any property now owned or hereafter acquired by such Person other than Permitted Liens or (e) require any consent or authorization of, filing with, or other act in respect of, an arbitrator or Governmental Authority and no consent of any other Person is required in connection with the execution, delivery, performance, validity or enforceability of this Agreement, other than (i) consents, authorizations, filings or other acts or consents previously obtained or for which the failure to obtain or make could not, individually or in the aggregate, reasonably be expected to have a Material Adverse Effect and (ii) consents or filings under the UCC or other security filings.

• No Construction Loans No Mortgage Loan was made in connection with (i) the construction or rehabilitation of a Mortgage Property or (ii) facilitating the trade-in or exchange of a Mortgaged Property other than a construction-to-permanent loan which has converted to a permanent Mortgage Loan;

• Execution of Credit Agreement; Loan Documents The Administrative Agent shall have received (i) counterparts of this Agreement, executed by a Responsible Officer of each Loan Party and a duly authorized officer of each Lender, (ii) for the account of each Lender requesting a Note, a Note executed by a Responsible Officer of the Borrower, (iii) counterparts of the Security Agreement and each other Collateral Document, executed by a Responsible Officer of the applicable Loan Parties and a duly authorized officer of each other Person party thereto, as applicable and (iv) counterparts of any other Loan Document, executed by a Responsible Officer of the applicable Loan Party and a duly authorized officer of each other Person party thereto.

• Investments, Loans, Advances, Guarantees and Acquisitions Borrower will not, and will not permit any of its Subsidiaries to, acquire or form any new Subsidiaries after the Closing Date, acquire, form or suffer to exist any new Affiliates after the Closing Date, purchase, hold or acquire (including pursuant to any merger, other than a merger permitted by Section 5.4) any Stock, evidences of indebtedness or other securities (including any option, warrant or other right to acquire any of the foregoing) of, make or permit to exist any loans or advances to, guarantee any obligations of, or make or permit to exist any investment or any other interest in, any other Person, or purchase or otherwise acquire (in one transaction or a series of transactions (including pursuant to any merger)) any assets of any other Person constituting a business unit, except: (a) Permitted Investments; (b) investments existing on the date as of the last financial statement furnished to the Bank as set forth on Annex 2; (c) Investments consisting of extensions of credit in the nature of accounts receivable arising from the grant of trade credit in the ordinary course of business; (d) loans and advances to officers, directors and employees of Borrower or any Subsidiary in the ordinary course of the business of the Borrower and its Subsidiaries as presently conducted in compliance with all applicable laws (including, to the extent applicable, the Sxxxxxxx-Xxxxx Act of 2002, as amended) in an aggregate principal amount not to exceed $5,000 at any time outstanding; and (e) investments made by Borrower in the equity securities of any Domestic Subsidiary and made by any Domestic Subsidiary in the equity securities of any other Domestic Subsidiary provided that (i) any such equity securities owned by Borrower or any Domestic Subsidiary shall become Collateral pursuant to this Agreement.

• Audit Rights Period for Construction-Related Accounts and Records Accounts and records related to the design, engineering, procurement, and construction of Connecting Transmission Owner’s Attachment Facilities and System Upgrade Facilities and System Deliverability Upgrades shall be subject to audit for a period of twenty-four months following Connecting Transmission Owner’s issuance of a final invoice in accordance with Article 12.2 of this Agreement.

• No Responsibility for Advances, Creditworthiness, Collateral, Recitals, Etc [Intentionally Omitted. See Sections 7.03 and 7.04 of the Credit Agreement for these provisions.]

• Collateral Protection Expenses Preservation of Collateral (a) If an Event of Default shall have occurred and be continuing, the Agent may discharge taxes and other encumbrances at any time levied or placed on any of the Collateral, make repairs thereto and pay any necessary filing fees. Each Grantor agrees to reimburse the Agent on demand for any and all expenditures so made. The Agent shall have no obligation to any Grantor to make any such expenditures, nor shall the making thereof relieve any Grantor of any default. (b) Anything herein to the contrary notwithstanding, each Grantor shall remain liable under each contract or agreement comprised in the Collateral to be observed or performed by such Grantor thereunder. The Agent shall not have any obligation or liability under any such contract or agreement by reason of or arising out of this Agreement or the receipt by the Agent of any payment relating to any of the Collateral, nor shall the Agent be obligated in any manner to perform any of the obligations of any Grantor under or pursuant to any such contract or agreement, to make inquiry as to the nature or sufficiency of any payment received by the Agent in respect of the Collateral or as to the sufficiency of any performance by any party under any such contract or agreement, to present or file any claim, to take any action to enforce any performance or to collect the payment of any amounts which may have been assigned to the Agent or to which the Agent may be entitled at any time or times. The Agent’s sole duty with respect to the custody, safe keeping and physical preservation of the Collateral in its possession, under Sections 9-207 and 9-208 of the UCC or otherwise, shall be to deal with such Collateral in the same manner as the Agent deals with similar property for its own account. (c) Each Grantor shall, to the extent reasonably necessary to preserve and maintain the Intellectual Property Collateral and the interest of the Agent therein, diligently pursue legal or other action to enforce the Intellectual Property Collateral and any licenses thereof.

• Continuing Effect of Credit Agreement This Amendment shall not constitute a waiver, amendment or modification of any other provision of the Credit Agreement not expressly referred to herein and shall not be construed as a waiver or consent to any further or future action on the part of the Borrowers that would require a waiver or consent of the Lenders or the Administrative Agent. Except as expressly amended or modified herein, the provisions of the Credit Agreement are and shall remain in full force and effect.

• Incorporation of Credit Agreement The provisions contained in Sections 11.9 and 11.13 of the Credit Agreement are incorporated herein by reference to the same extent as if reproduced herein in their entirety, except with reference to this Amendment rather than the Credit Agreement.