Breach on the Part of Supplier
Breach on the Part of Supplier Sample Clauses
Related to Breach on the Part of Supplier
Responsibility For Damages Or Injury The County its elected and appointed officials, officers, employees, agents and those special districts and agencies which County’s Board of Supervisors acts as the governing Board (“County Indemnitees”) shall not be answerable or accountable in any manner: for any loss or damage that may happen to the Project or any part thereof; for any loss or damage to any of the materials or other things used or employed in performing the Project; for injury to or death of any person either workers or the public; or for damage to property from any cause which might have been prevented by the Contractor, or his workers, or anyone employed by him. The Contractor shall be responsible for any liability imposed by law and for injuries to or death of any person or damage to property resulting from defects or obstructions or from any cause whatsoever during the progress of the Project or at any time before its completion and final acceptance. The Contractor shall indemnify, defend with counsel approved in writing by County and save harmless the County Indemnitees from all claims, suits or actions of every name, kind and description, brought for, or on account of, injuries to or death of any person or damage to property resulting from the construction of the Project or by or in consequence of any negligence in guarding the Project; use of improper materials in construction of the Project; or by or on account of any act or omission by the Contractor or his agents during the progress of the Work or at any time before the completion and final acceptance of the Project. In addition to any remedy authorized by law, so much of the money due the Contractor under and by virtue of the Contract as shall be considered necessary by the County may be retained by it until disposition has been made of such suits or claims for damages as aforesaid. If judgment is entered against Contractor and County by a court of competent jurisdiction because of the concurrent active negligence of County and County Indemnitees, Contractor and County agree that liability will be apportioned as determined by the court. Neither Party shall request a jury apportionment. Notwithstanding anything stated above, nothing contained herein shall relieve Contractor of any insurance requirements of obligations created elsewhere in this Contract.
Damages for breach of maintenance obligations 17.8.1 In the event that the Concessionaire fails to repair or rectify any defect or deficiency set forth in the Maintenance Requirements within the period specified therein, it shall be deemed to be in breach of this Agreement and the Authority shall be entitled to recover Damages, to be calculated and paid for each day of delay until the breach is cured, at the higher of (a) 0.5% (zero point five per cent) of Performance Guarantee, and (b) 0.1% (zero point one per cent) of the cost of such repair or rectification as estimated by the Independent Engineer. Recovery of such Damages shall be without prejudice to the rights of the Authority under this Agreement, including the right of Termination thereof.
Termination on Breach of Obligations of Confidentiality The Authority may terminate this Framework Agreement by serving notice on the Supplier in writing with effect from the date specified in such notice where the Supplier fails to comply with Clauses 19.1 to 19.5 (Confidentiality).
Confidentiality of processing MailChimp shall ensure that any person who is authorized by MailChimp to process Customer Data (including its staff, agents and subcontractors) shall be under an appropriate obligation of confidentiality (whether a contractual or statutory duty).
Assignment Liability Indemnity Force Majeure Consequential Damages and Default Notwithstanding any other provision of this Agreement, the liability, indemnification and insurance provisions of the Transmission Operating Agreement (“TOA”) or other applicable operating agreements shall apply to the relationship between the System Operator and the Interconnection Transmission Owner and the liability, indemnification and insurance provisions of the Tariff apply to the relationship between the System Operator and the Interconnection Customer and between the Interconnecting Transmission Owner and the Interconnection Customer.
Breach of Covenants If the Company breaches any of the covenants set forth in this Section 4, and in addition to any other remedies available to the Buyer pursuant to this Agreement, it will be considered an event of default under Section 3.4 of the Note.
Breach of Obligations The Parties acknowledge that a breach of any of the obligations contained herein would result in injuries. The Parties further acknowledge that the amount of the liquidated damages or the method of calculating the liquidated damages specified in this Agreement is a genuine and reasonable pre-estimate of the damages that may be suffered by the non-defaulting party in each case specified under this Agreement.
Breach of Covenant The Borrower breaches any material covenant or other term or condition of the Subscription Agreement or this Note in any material respect and such breach, if subject to cure, continues for a period of ten (10) business days after written notice to the Borrower from the Holder.
No Breach of Obligations The Developer shall not be considered to be in breach of its obligations under this Agreement nor shall it incur or suffer any liability if and to the extent performance of any of its obligations under this Agreement is affected by or on account of any of the following:
Breach of Confidentiality Contractor acknowledges that there can be no adequate remedy at law for any breach of Contractor’s obligations hereunder, that any such breach will likely result in irreparable harm, and therefore, that upon any breach or threatened breach of the confidentiality obligations, the Court shall be entitled to appropriate equitable relief, without the requirement of posting a bond, in addition to its other remedies at law. INDEMNIFICATION
