By Licensor Licensor will indemnify and hold harmless Licensee and its and members, managers, directors, officers, shareholders, employees, agents, representatives and affiliates (collectively, the "Licensee Indemnified Parties"), on an After Tax Basis, from and against all claims, losses, damages (including loss of profits and consequential damages awarded to unrelated third parties, if any, but excluding loss of profits and consequential damages otherwise suffered by the Licensee Indemnified Parties), expenses, judgements, costs and liabilities (including reasonable attorneys' fees and costs) (collectively, "Losses") incurred by the Licensee Indemnified Parties arising from Licensor's breach of any obligation, representation or warranty contained in this Agreement. Notwithstanding the foregoing any claims for indemnification that any Licensee Indemnified Parties may have pursuant to this Section 7.2(a) will exclude claims based on information known by Lifford (or its Affiliates, including Bloomfield) as of the Funding Date whether or not such information formed the basis of the issues raised by Bloomfield during Due Diligence (as defined in the Operating Agreement) and whether or not asserted prior to the Walk Away Notice (as defined in the Operating Agreement) or thereafter. In the event of a dispute regarding a claim for indemnification, the Licensee Indemnified Party will have the burden of proof in establishing the validity and amount of the claim, and Licensor will have the burden of proof in establishing any defense to such claim, including but not limited to, a defense asserted by Licensor that Lifford (or its Affiliates) had knowledge of the requisite facts. Notwithstanding the foregoing, Licensor will not be obligated to provide indemnification where there is any admission of guilt by any Licensee Indemnified Party charged with violation of the law as to the content of any Company Program.
By Licensee Licensee shall defend, indemnify, and hold harmless Licensor, its Affiliates, sublicensees, the licensors under the Existing Licenses, and their respective shareholders, members, partners, officers, trustees, faculty, students, contractors, agents, and employees (individually, a “Licensor Indemnified Party” and, collectively, the “Licensor Indemnified Parties”) from and against any and all Third Party liability, loss, damage, action, claim, fee, cost, or expense (including attorneys’ fees) (individually, a “Third Party Liability” and, collectively, the “Third Party Liabilities”) suffered or incurred by the Licensor Indemnified Parties from claims of such Third Parties that result from or arise out of: […***…]; provided, however, that Licensee shall not be liable for claims based on any breach by Licensor of the representations, warranties, or obligations of this Agreement or the gross negligence or intentional misconduct of any of the Licensor Indemnified Parties. Without limiting the foregoing, Licensee must defend, indemnify, and hold harmless the Licensor Indemnified Parties from and against any Third Party Liabilities resulting from:
(a) any […***…] or other claim of any kind related to the […***…] by a Third Party of a […***…] by Licensee, its Affiliates, any Sublicensees, their respective assignees, or vendors;
(b) any claim by a Third Party that the […***…]; and
(c) […***…] conducted by or on behalf of Licensee, its Affiliates, any Sublicensees, their respective assignees, or vendors relating to the Licensed Technology or Licensed Products, including any claim by or on behalf of a […***…].
By Microsoft Microsoft will defend Customer against any third-party claim to the extent it alleges that a Product or Fix made available by Microsoft for a fee and used within the scope of the license granted under this agreement (unmodified from the form provided by Microsoft and not combined with anything else), misappropriates a trade secret or directly infringes a patent, copyright, trademark or other proprietary right of a third party. If Microsoft is unable to resolve a claim of infringement under commercially reasonable terms, it may, as its option, either: (1) modify or replace the Product or fix with a functional equivalent; or (2) terminate Customer’s license and refund any prepaid license fees (less depreciation on a five-year, straight-line basis) for perpetual licenses and any amount paid for Online Services for any usage period after the termination date. Microsoft will not be liable for any claims or damages due to Customer’s continued use of a Product or Fix after being notified to stop due to a third- party claim.
The Project The Project is the total construction of which the Work performed under the Contract Documents may be the whole or a part.
By Contractor Should the Contractor be liable for any payments to the State hereunder, interest, late payment charges and collection fee charges will be determined and assessed pursuant to Section 18 of the State Finance Law.
Cross Connection For a collocation arrangement, the facilities between the collocating Party’s equipment and the equipment or facilities of the housing Party (such as the housing Party’s digital signal cross connect, Main Distribution Frame, or other suitable frame or panel).
By Sellers Sellers covenant and agree to defend, indemnify and hold harmless Purchaser, its Affiliates and the officers, directors, employees, agents, advisers and representatives of each such Person (collectively, the "Purchaser Indemnitees") from and against, and pay or reimburse the Purchaser Indemnitees for, any and all claims, liabilities, obligations, losses, fines, costs, royalties, proceedings, deficiencies or damages (whether absolute, accrued, conditional or otherwise and whether or not resulting from third party claims), including out-of-pocket expenses and reasonable attorneys' and accountants' fees incurred in the investigation or defense of any of the same or in asserting any of their respective rights hereunder (collectively, "Losses"), resulting from or arising out of:
(i) any inaccuracy of any representation or warranty made by any Seller herein, or in any certificate delivered by an officer of any Seller pursuant hereto (a "Seller Certificate") or in any Collateral Agreement or in connection herewith or therewith;
(ii) any failure of any Seller to perform any covenant or agreement hereunder or under any Collateral Agreement or fulfill any other obligation in respect hereof or of any Collateral Agreement;
(iii) any and all Retained Liabilities or Retained Assets;
(iv) any and all Taxes (other than payroll Taxes) of any Seller and all Affiliates thereof relating to or arising out of the Business accruing, or with respect to any event or time period occurring, at or prior to Closing; and
(v) any and all liabilities in respect of employees of Seller or its Affiliates or Plans except to the extent assumed by Purchaser pursuant to Section 4.3. Cap on Sellers' Indemnification Obligations. Sellers' obligation to indemnify Purchaser Indemnitees pursuant to this Agreement, any Seller Certificate or any Collateral Agreement for breaches or inaccuracies of representations or warranties, and for breaches or failures to perform covenants or agreements or to fulfill any other obligations set forth in this Agreement (except for (x) the Seller Surviving Covenants, and (y) solely to the extent expressly contemplated by this Section 8.9(a), the Environmental Covenants (as defined in this Section 8.9(a))), in any Seller Certificate or in any Collateral Agreement, shall not exceed the amount of funds held in the Escrow Account at the time such claims
By Buyer Neither the board of directors of Buyer nor any committee thereof shall: (i) except as expressly permitted by this Section 7.2, withdraw, qualify or modify, or propose publicly to withdraw, qualify or modify, in a manner adverse to Target, the approval or recommendation of such board of directors or such committee of the Nasdaq Stockholder Approval or the Buyer Stockholder Approval; (ii) approve or recommend, or propose publicly to approve or recommend, any Acquisition Proposal; or (iii) cause Buyer to enter into any letter of intent, agreement in principle, acquisition agreement or other similar agreement (each, an “Acquisition Agreement”) related to any Acquisition Proposal. Notwithstanding the foregoing, in the event that, prior to the adoption and approval of the Buyer Stockholder Approval by the holders of Buyer Common Stock, the board of directors of Buyer determines in good faith, after it has received a Superior Offer and after consultation with outside counsel, and that the failure to consider such Superior Proposal would violate its fiduciary duties to Buyer stockholders under applicable Law, then the Buyer may (subject to this and the following sentences) inform the Target that it no longer believes that the Merger is advisable and no longer recommends approval and (subject to this and the following sentences) approve or recommend a Superior Proposal and in connection therewith withdraw or modify its approval or recommendation of the Buyer Stockholder Approval (a “Subsequent Determination”), but only at a time that is after the fifth (5th) Business Day following Target’s receipt of written notice advising them that the board of directors of Buyer has received a Superior Proposal, specifying the material terms and conditions of such Superior Proposal (and including a copy thereof with all accompanying documentation, if in writing), identifying the person making such Superior Proposal and stating that it intends to make a Subsequent Determination. Target shall have five (5) Business Days from the date of receiving such notice to submit to Buyer any changes to the terms and conditions of this Agreement as would enable Buyer to proceed with its recommendation to its stockholders without a Subsequent Determination; provided, that any such adjustment shall be at the discretion of the Parties at the time.
Marketing the Property In an effort to properly and efficiently market the Property, the Seller grants the following permissions to the Agency: (Initial ALL That Apply)
Construction of the Project Highway (i) The Contractor shall construct the Project Highway as specified in Schedule- B and Schedule-C, and in conformity with the Specifications and Standards set forth in Schedule-D. The Contractor shall be responsible for the correct positioning of all parts of the Works, and shall rectify any error in the positions, levels, dimensions or alignment of the Works. The [650th (six hundred and fiftieth) day] from the Appointed Date shall be the scheduled completion date (the “Scheduled Completion Date”) and the Contractor agrees and undertakes that the construction shall be completed on or before the Scheduled Completion Date, including any extension thereof.
(ii) The Contractor shall construct the Project Highway in accordance with the Project Completion Schedule set forth in Schedule-J. In the event that the Contractor fails to achieve any Project Milestone or the Scheduled Completion Date within a period of 30 (thirty) days from the date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, it shall pay Damages to the Authority of a sum calculated at the rate of 0.05% (zero point zero five percent) of the Contract Price for delay of each day reckoned from the date specified in Schedule –J and until such Project Milestone is achieved or the Project Highway is completed; provided that if the period for any or all Project Milestones or the Scheduled Completion Date is extended in accordance with the provisions of this Agreement, the dates set forth in Schedule-J shall be deemed to be modified accordingly and the provisions of this Agreement shall apply as if Schedule-J has been amended as above; provided further that in the event the Project Highway is completed within or before the Scheduled Completion Date including any Time Extension, applicable for that work or section, the Damages paid under this Clause 10.3 (ii) shall be refunded by the Authority to the Contractor, but without any interest thereon. The Parties agree that for determining achievement or delays in completion of the Project Milestones or the Project on the due date, the works affected due to delay in providing the site for which time extension has been granted beyond the Scheduled Completion Date will be excluded. For example on the due date to achieve the Project Milestone-I (i.e., Stage Payments of 10% (ten percent) of Contract Price on 180th (one hundred and eighty) day from the Appointed Date), if 5% (five percent) of the project length corresponding to the Project Milestone-I is not handed over or lately handed over resulting in the extension of completion of this 5% (five percent) length beyond Scheduled Completion Date, Stage Payment of 10% X 0.95 = 9.5% only is to be achieved by 180th (one hundred and eighty) day. For the avoidance of doubt, it is agreed that recovery of Damages under this Clause 10.3 (ii) shall be without prejudice to the rights of the Authority under this Agreement including the right of Termination thereof. The Parties further agree that Time Extension hereunder shall only be reckoned for and in respect of the affected Works as specified in Clause 10.5 (ii).
(iii) The Authority shall notify the Contractor of its decision to impose Damages in pursuance with the provisions of this Clause 10.3. Provided that no deduction on account of Damages shall be effected by the Authority without notifying the Contractor of its decision to impose the Damages, and taking into consideration the representation, if any, made by the Contractor within 20 (twenty) days of such notice. The Parties expressly agree that the total amount of Damages under Clause 10.3 (ii) shall not exceed 10% (ten percent) of the Contract Price. If the damages exceed 10% (ten percent) of the Contract Price, the Contractor shall be deemed to be in default of this agreement having no cure and the Authority shall be entitled to terminate this Agreement by issuing a Termination Notice in accordance with the provisions of Clause 23.1 (ii).
(iv) In the event that the Contractor fails to achieve the Project Completion within a period of 90 (ninety) days from the Schedule Completion Date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, the contractor shall be deemed to be ineligible for bidding any future projects of the Authority, both as the sole party or as one of the parties of Joint Venture/ Consortium during the period from Scheduled Completion Date to issuance of Completion Certificate. This restriction is applicable if the contract value of the delayed project is not less than Rs. 300 Crore.
