Third Party Contractors Tenant shall obtain and deliver to Landlord, Third Party Contractor’s certificates of insurance and applicable endorsements at least seven (7) business days prior to the commencement of work in or about the Premises by any vendor or any other third-party contractor (collectively, a “Third Party Contractor”). All such insurance shall (a) name Landlord as an additional insured under such party’s liability policies as required by Section 10.3.1 above and this Section 10.6, (b) provide a waiver of subrogation in favor of Landlord under such Third Party Contractor’s commercial general liability insurance, (c) be primary and any insurance carried by Landlord shall be excess and non-contributing, and (d) comply with Landlord’s minimum insurance requirements.
Products 1.1. The information (including but not limited to the quantity, rated hashrate, unit price (“Unit Price”), total price for one item (“Total Price (One Item)”), total price for all the items (“Total Purchase Price”) of Products to be purchased by Party B from Party A is as follows (“Products”):
Distributors The Manager shall make or cause to be made such arrangements as are expedient for the distribution of Units, having regard to the requirements of Applicable Laws and applicable stock exchange rules and regulations respecting such distribution of Units in the jurisdiction or jurisdictions in which they are to be distributed. It is understood and agreed that: (i) the Manager or the Investment Manager may distribute Units itself in the offering jurisdictions in which it is registered, or is exempt from such registration, under applicable Securities Legislation; and (ii) the Manager will retain the services of the Underwriters pursuant to the Underwriting Agreement to assist it in the distribution of the Units in the offering jurisdictions.
Product The term “
Manufacture (a) Manufacturer shall only manufacture the specific number of Products as requested by Company and at no time shall manufacture excess goods or overruns. Manufacturer shall not sell any Products bearing the Trademarks to any third parties without the express written consent of Company.
Product Warranty; Product Liability (a) Except as set forth on Company Disclosure Schedule 4.23, the products produced, sold or delivered by the Company in conducting the Business have been in all material respects in conformity with all product specifications and all applicable Laws. To the Company’s Knowledge, the Company has no material Liability for damages in connection therewith or any other customer or product obligations not reserved against on the Balance Sheet.
Shipment If any of the Major Components associated with any Unit is not Shipped on or before (with the prior approval of the Buyer) the Scheduled Major Component Shipment Date set forth in Attachment 1 for reasons attributable to the Seller and not excused elsewhere in this Contract, the Seller shall pay as liquidated damages, and not as a penalty, a sum calculated in accordance with the table below for each Unit for each day of delay after the Scheduled Major Component Shipment Date as set forth in Attachment 1 until actual Shipment of the last Major Component for such Unit: Days after Scheduled Major Component Shipment Date Liquidated Damages (per day or partial day) *** *** *** *** *** *** Such liquidated damages, if any, shall be computed based on the date of Shipment of the last Major Component for a given Unit and such computations shall disregard any part of or accessory to the Major Component which may be shipped separately and arrive later unless such part of or accessory to the Major Component is necessary for the installation of the Major Component.
Subcontractors 1. FAS may without further consent on the part of the Investment Company at FAS’s own expense, subcontract for the performance of Administrative Services with a sub-contractor selected by FAS. FAS shall be as fully responsible to the Investment Company for the acts and omissions of any subcontractor as it is for its own acts and omissions.
Subcontractors and Unaffiliated Third Parties (a) The Escrow Agent may, without further consent of any party hereto, subcontract with (i) any of its affiliates, or (ii) unaffiliated subcontractors for such services as may be required from time to time (e.g., lost stockholder searches, escheatment, telephone and mailing services); provided, however, that the Escrow Agent (i) shall be fully responsible for the acts and omissions of its affiliate as it is for its own acts and omissions and (ii) shall not be liable for the acts and omissions of any subcontractor absent willful misconduct, bad faith or gross negligence of the Escrow Agent in the selection of such subcontractor (each as determined by a final, non-appealable judgment of a court of competent jurisdiction).
Distributor The Distributor represents and warrants that: (i) the Distributor is a limited partnership duly organized and in good standing under New York law; (ii) the Distributor is registered as a broker-dealer under federal and applicable state securities laws and is a member of the NASD; and (iii) the Distributor is registered as an investment adviser under federal securities laws.
