Carried Forward R. Section No. 1 Bill No. 1 Preliminaries There is a possibility that certain works related to tenant installation/user requirements may have to be delayed and may consequently not be executed prior to practical completion Should the contractor be instructed to do so he shall execute this work under the conditions pertaining to this agreement on the basis that a separate amount for preliminaries appurtenant to this work (if applicable) is agreed to between the contractor and the principal agent and on condition that instruction to proceed with such work is given to him within a period of three (3) calendar months after the date of practical completion of the works The employer reserves the right to omit such work without compensation to the contractor for loss of profit or any other loss which the contractor may suffer as a result of such omission ? All costs incurred by the contractor in the preparation of claims shall be borne by the contractor. This provision shall not preclude an adjudicator or an arbitrator appointed in terms of this agreement [30.6 & 7] from making a determination on costs The contractor shall review, assess and adjudicate any claims received by him from any subcontractor and thereafter submit same to the principal agent with a recommendation in order to assist the principal agent in adjudicating the claim [26.6] F:............................. V:............................ T:............................ Item 27 Clause 27.0 - Recovery of expense and/or loss F:............................. V:............................ T:............................ Item 28 Clause 28.0 - Suspension by the contractor Section No. 1 Bill No. 1 Preliminaries F:............................. V:............................ T:............................ 29 Clause 29.0 - Termination Item F:............................. V:............................ T:............................ Item 30 Clause 30.0 - Dispute resolution F:............................. V:............................ T:............................ Item
Appears in 2 contracts
Samples: Building Agreement, Building Agreement
Carried Forward R. Section No. 1 Preliminaries and General Bill No. 1 Preliminaries There and General Where prices are submitted by the contractor or subcontractor during the progress of the works in respect of contract instructions or in regard to a claim under the terms of the agreement and notwithstanding the fact that such prices may be used in an interim payment certificate, there is a possibility that certain works related to tenant installation/user requirements may have to be delayed and may consequently not be executed prior to practical completion no presumption of acceptance. Should the contractor be instructed to do so he shall execute this work under the conditions pertaining to this agreement on the basis that a separate amount for preliminaries appurtenant to this work (if applicable) is agreed to between the contractor and the principal agent and on condition that instruction wish to proceed with accept any such work is given prices prior to him within a period of three (3) calendar months after the date of practical completion issue of the works The employer reserves certificate of final completion, it shall be in writing F:............................. V:............................ T:............................ Item 27 Clause 26.0 - Adjustment of the right to omit such work without compensation to the contractor for loss of profit or any other loss which the contractor may suffer as a result of such omission ? contract value and final account All costs incurred by the contractor in the preparation of claims shall be borne by the contractor. This provision shall not preclude an adjudicator or an arbitrator appointed in terms of this agreement [30.6 & 7] from making a determination on costs contractor The contractor shall review, assess and adjudicate any claims received by him from any subcontractor and thereafter submit same to the principal agent with a recommendation in order to assist the principal agent in adjudicating the claim [26.6] F:............................. V:............................ T:............................ Item 27 28 Clause 27.0 - Recovery of expense and/or loss F:............................. V:............................ T:............................ Item 28 29 Clause 28.0 - Suspension by the contractor Section No. 1 Bill No. 1 Preliminaries F:............................. V:............................ T:............................ 29 Clause 29.0 - Termination Item F:............................. V:............................ T:............................ Item 30 Clause 30.0 29.0 - Dispute resolution Termination F:............................. V:............................ T:............................ Item............................
Appears in 1 contract
Samples: Building Agreement
Carried Forward R. Section No. 1 Bill No. 1 Preliminaries There PRELIMINARIES 72 Co-operation of contractor for cost management It is a possibility specifically agreed that certain works related the contractor accepts the obligation of assisting the principal agent in implementing proper cost management. The contractor will be advised by the principal agent of all cost management procedures which will be implemented to tenant installationensure that the final building cost does not exceed the budget. The principal agent undertakes to make available to the contractor all budgetary allowances and cost assessments/user requirements may have reports to enable the proper procedure to be delayed implemented and may consequently not be executed prior to practical completion Should the contractor shall attend all cost plan review and cost management meetings. The contractor undertakes to extend these procedures, as necessary, to all subcontractors F:...........................V:.........................T:......................... Item 73 Propping of floors below The contractor is advised that propping of floors below may be instructed required if he wishes to do so he use any areas of completed suspended reinforced concrete slabs for vehicle access, storage of materials and goods and location of plant, scaffolding, etc. The location of these areas and any necessary propping shall execute this work under the conditions pertaining to this agreement on the basis that a separate amount for preliminaries appurtenant to this work (if applicable) is agreed to between the contractor and be approved by the principal agent and on condition that instruction to proceed with such work is given to him within a period of three (3) calendar months after the date of practical completion of the works The employer reserves the right to omit such work without compensation to the contractor for loss of profit or any other loss which the contractor may suffer as a result of such omission ? All costs incurred by the contractor in the preparation of claims cost thereof shall be borne by the contractorcontractor F:......................... V:........................... T:.......................... Item 74 Testing of windows for watertightness Each window shall be tested for watertightness with water sprayed on using adequate pressure. This provision shall not preclude an adjudicator or an arbitrator appointed If in terms the opinion of this agreement [30.6 & 7] from making a determination on costs The contractor shall review, assess and adjudicate any claims received by him from any subcontractor and thereafter submit same to the principal agent with a recommendation in order agent, the pressure proves to assist be inadequate, then the principal agent in adjudicating the claim [26.6] pressure shall be boosted by means of compressed air or other approved means F:............................. ....................... V:............................ ......................... T:............................ Item 27 Clause 27.0 - Recovery of expense and/or loss F:............................. V:............................ T:............................ Item 28 Clause 28.0 - Suspension by the contractor Section No. 1 Bill No. 1 Preliminaries F:............................. V:............................ T:............................ 29 Clause 29.0 - Termination Item F:............................. V:............................ T:............................ Item 30 Clause 30.0 - Dispute resolution F:............................. V:............................ T:............................ ......................... Item
Appears in 1 contract
Samples: Building Agreement
Carried Forward R. Section No. 1 Bill No. 1 Preliminaries There is a possibility that certain works related to tenant installation/user requirements may have to be delayed and may consequently not be executed prior to practical completion Should the contractor be instructed to do so he shall execute this work under the conditions pertaining to this agreement on the basis that a separate amount for preliminaries appurtenant to this work (if applicable) is agreed to between the contractor and the principal agent and on condition that instruction to proceed with such work is given to him within a period of three (3) calendar months after the date of practical completion PRELIMINARIES 18 Clause 18.0 - Setting out of the works The employer reserves the right to omit such work without compensation to the contractor for loss of profit or any other loss which the contractor may suffer as a result of such omission ? All costs incurred by the contractor in the preparation of claims shall be borne by the contractor. This provision shall not preclude an adjudicator or an arbitrator appointed in terms of this agreement [30.6 & 7] from making a determination on costs The contractor shall review, assess and adjudicate any claims received by him from any subcontractor and thereafter submit same to notify the principal agent with a recommendation if any encroachments of adjoining foundations, buildings, structures, pavements, boundaries, etc. exist in order to assist that the principal agent in adjudicating necessary arrangements may be made for the claim rectification of any such encroachments [26.6] 18.1]. F: ............................ V:...........................T:........................... Item 19 Clause 19.0 - Temporary works and plant F:............................. V:............................ T:............................ Item 27 20 Clause 27.0 20.0 - Recovery of expense and/or loss Nominated subcontractors Refer to the provisions on general attendance hereinafter F:............................. V:............................ T:............................ Item 28 21 Clause 28.0 21.0 - Suspension Selected subcontractors General attendance of n/s subcontractors for pricing by the contractor Section Noshall be in accordance with the n/s agreement. 1 Bill No. 1 Preliminaries F:............................. V:............................ T:............................ 29 Clause 29.0 - Termination Item Notwithstanding this provision, general attendance shall be deemed to include for the contractor to provide free of charge to any n/s subcontractor such scaffolding as may reasonably be required by such n/s subcontractor for the execution of the relevant subcontract work F:............................. V:............................ T:............................ Item 30 22 Clause 30.0 22.0 - Dispute resolution FEmployer's direct contractorsF:............................. V:............................ T:............................ Item 23 Clause 23.0 - Contractor's domestic subcontractorsF:............................. V:............................ T:............................ Item
Appears in 1 contract
Samples: Building Agreement
Carried Forward R. Section No. 1 2 Bill No. 1 Preliminaries There is a possibility that certain works related to tenant installation/user requirements may have to be delayed and may consequently not be executed prior to practical completion Should the contractor be instructed to do so he shall execute this work under the conditions pertaining to this agreement on the basis that a separate amount for preliminaries appurtenant to this work (if applicable) is agreed to between the contractor and the principal agent and on condition that instruction to proceed with such work is given to him within a period of three (3) calendar months after the date of practical completion PRELIMINARIES 18 Clause 18.0 - Setting out of the works The employer reserves the right to omit such work without compensation to the contractor for loss of profit or any other loss which the contractor may suffer as a result of such omission ? All costs incurred by the contractor in the preparation of claims shall be borne by the contractor. This provision shall not preclude an adjudicator or an arbitrator appointed in terms of this agreement [30.6 & 7] from making a determination on costs The contractor shall review, assess and adjudicate any claims received by him from any subcontractor and thereafter submit same to notify the principal agent with a recommendation if any encroachments of adjoining foundations, buildings, structures, pavements, boundaries, etc. exist in order to assist that the principal agent in adjudicating necessary arrangements may be made for the claim rectification of any such encroachments [26.6] 18.1]. F: ............................ V:...........................T:........................... Item 19 Clause 19.0 - Temporary works and plant F:............................. V:............................ T:............................ Item 27 20 Clause 27.0 20.0 - Recovery of expense and/or loss Nominated subcontractors Refer to the provisions on general attendance hereinafter F:............................. V:............................ T:............................ Item 28 21 Clause 28.0 21.0 - Suspension Selected subcontractors General attendance of n/s subcontractors for pricing by the contractor Section Noshall be in accordance with the n/s agreement. 1 Bill No. 1 Preliminaries F:............................. V:............................ T:............................ 29 Clause 29.0 - Termination Item Notwithstanding this provision, general attendance shall be deemed to include for the contractor to provide free of charge to any n/s subcontractor such scaffolding as may reasonably be required by such n/s subcontractor for the execution of the relevant subcontract work F:............................. V:............................ T:............................ Item 30 22 Clause 30.0 22.0 - Dispute resolution FEmployer's direct contractorsF:............................. V:............................ T:............................ Item 23 Clause 23.0 - Contractor's domestic subcontractorsF:............................. V:............................ T:............................ Item
Appears in 1 contract
Samples: Building Agreement
Carried Forward R. Section No. 1 3 Bill No. 1 Preliminaries There PRELIMINARIES 72 Co-operation of contractor for cost management It is a possibility specifically agreed that certain works related the contractor accepts the obligation of assisting the principal agent in implementing proper cost management. The contractor will be advised by the principal agent of all cost management procedures which will be implemented to tenant installationensure that the final building cost does not exceed the budget. The principal agent undertakes to make available to the contractor all budgetary allowances and cost assessments/user requirements may have reports to enable the proper procedure to be delayed implemented and may consequently not be executed prior to practical completion Should the contractor shall attend all cost plan review and cost management meetings. The contractor undertakes to extend these procedures, as necessary, to all subcontractors F:...........................V:.........................T:......................... Item 73 Propping of floors below The contractor is advised that propping of floors below may be instructed required if he wishes to do so he use any areas of completed suspended reinforced concrete slabs for vehicle access, storage of materials and goods and location of plant, scaffolding, etc. The location of these areas and any necessary propping shall execute this work under the conditions pertaining to this agreement on the basis that a separate amount for preliminaries appurtenant to this work (if applicable) is agreed to between the contractor and be approved by the principal agent and on condition that instruction to proceed with such work is given to him within a period of three (3) calendar months after the date of practical completion of the works The employer reserves the right to omit such work without compensation to the contractor for loss of profit or any other loss which the contractor may suffer as a result of such omission ? All costs incurred by the contractor in the preparation of claims cost thereof shall be borne by the contractorcontractor F:......................... V:........................... T:.......................... Item 74 Testing of windows for watertightness Each window shall be tested for watertightness with water sprayed on using adequate pressure. This provision shall not preclude an adjudicator or an arbitrator appointed If in terms the opinion of this agreement [30.6 & 7] from making a determination on costs The contractor shall review, assess and adjudicate any claims received by him from any subcontractor and thereafter submit same to the principal agent with a recommendation in order agent, the pressure proves to assist be inadequate, then the principal agent in adjudicating the claim [26.6] pressure shall be boosted by means of compressed air or other approved means F:............................. ....................... V:............................ ......................... T:............................ Item 27 Clause 27.0 - Recovery of expense and/or loss F:............................. V:............................ T:............................ Item 28 Clause 28.0 - Suspension by the contractor Section No. 1 Bill No. 1 Preliminaries F:............................. V:............................ T:............................ 29 Clause 29.0 - Termination Item F:............................. V:............................ T:............................ Item 30 Clause 30.0 - Dispute resolution F:............................. V:............................ T:............................ ......................... Item
Appears in 1 contract
Samples: Building Agreement
Carried Forward R. Section No. 1 2 Bill No. 1 Preliminaries There PRELIMINARIES 72 Co-operation of contractor for cost management It is a possibility specifically agreed that certain works related the contractor accepts the obligation of assisting the principal agent in implementing proper cost management. The contractor will be advised by the principal agent of all cost management procedures which will be implemented to tenant installationensure that the final building cost does not exceed the budget. The principal agent undertakes to make available to the contractor all budgetary allowances and cost assessments/user requirements may have reports to enable the proper procedure to be delayed implemented and may consequently not be executed prior to practical completion Should the contractor shall attend all cost plan review and cost management meetings. The contractor undertakes to extend these procedures, as necessary, to all subcontractors F:...........................V:.........................T:......................... Item 73 Propping of floors below The contractor is advised that propping of floors below may be instructed required if he wishes to do so he use any areas of completed suspended reinforced concrete slabs for vehicle access, storage of materials and goods and location of plant, scaffolding, etc. The location of these areas and any necessary propping shall execute this work under the conditions pertaining to this agreement on the basis that a separate amount for preliminaries appurtenant to this work (if applicable) is agreed to between the contractor and be approved by the principal agent and on condition that instruction to proceed with such work is given to him within a period of three (3) calendar months after the date of practical completion of the works The employer reserves the right to omit such work without compensation to the contractor for loss of profit or any other loss which the contractor may suffer as a result of such omission ? All costs incurred by the contractor in the preparation of claims cost thereof shall be borne by the contractorcontractor F:......................... V:........................... T:.......................... Item 74 Testing of windows for watertightness Each window shall be tested for watertightness with water sprayed on using adequate pressure. This provision shall not preclude an adjudicator or an arbitrator appointed If in terms the opinion of this agreement [30.6 & 7] from making a determination on costs The contractor shall review, assess and adjudicate any claims received by him from any subcontractor and thereafter submit same to the principal agent with a recommendation in order agent, the pressure proves to assist be inadequate, then the principal agent in adjudicating the claim [26.6] pressure shall be boosted by means of compressed air or other approved means F:............................. ....................... V:............................ ......................... T:............................ Item 27 Clause 27.0 - Recovery of expense and/or loss F:............................. V:............................ T:............................ Item 28 Clause 28.0 - Suspension by the contractor Section No. 1 Bill No. 1 Preliminaries F:............................. V:............................ T:............................ 29 Clause 29.0 - Termination Item F:............................. V:............................ T:............................ Item 30 Clause 30.0 - Dispute resolution F:............................. V:............................ T:............................ ......................... Item
Appears in 1 contract
Samples: Building Agreement
Carried Forward R. Section No. 1 Bill No. 1 Preliminaries & General There is a possibility that certain works related to tenant installation/user requirements may have to be delayed and may consequently not be executed prior to practical completion Should the contractor be instructed to do so he shall execute this work under the conditions pertaining to this agreement on the basis that a separate amount for preliminaries appurtenant to this work (if applicable) is agreed to between the contractor and the principal agent and on condition that instruction to proceed with such work is given to him within a period of three (3) calendar months after the date of practical completion of the works The employer reserves the right to omit such work without compensation to the contractor for loss of profit or any other loss which the contractor may suffer as a result of such omission ? All costs incurred by the contractor in the preparation of claims shall be borne by the contractor. This provision shall not preclude an adjudicator or an arbitrator appointed in terms of this agreement [30.6 & 7] from making a determination on costs The contractor shall review, assess and adjudicate any claims received by him from any subcontractor and thereafter submit same to the principal agent with a recommendation in order to assist the principal agent in adjudicating the claim [26.6] F:............................. V:............................ T:............................ Item 27 Clause 27.0 - Recovery of expense and/or loss F:............................. V:............................ T:............................ Item 28 Clause 28.0 - Suspension by the contractor Section No. 1 Bill No. 1 Preliminaries & General F:............................. V:............................ T:............................ 29 Clause 29.0 - Termination Item F:............................. V:............................ T:............................ Item 30 Clause 30.0 - Dispute resolution F:............................. V:............................ T:............................ Item
Appears in 1 contract
Samples: Building Agreement
Carried Forward R. Section No. 1 Bill No. 1 Preliminaries There is a possibility that certain works related to tenant installation/user requirements may have to be delayed and may consequently not be executed prior to practical completion Should General 101 The contractor shall undertake monthly digital photographic records of the contractor be instructed to do so he shall execute this work under project, recording the conditions pertaining to this agreement on the basis that a separate amount for preliminaries appurtenant to this work (if applicable) is agreed to between the contractor and the principal agent and on condition that instruction to proceed with such work is given to him within a period state of three (3) calendar months after the date of practical completion progress of the works The employer reserves contractor shall undertake a detailed photographic record of all neighbouring properties and their existing defects F:........................ V:........................T:......................... Item 102 Where warranties for materials and/or workmanship are called for, the right to omit such work without compensation contractor shall obtain a written warranty, addressed to the contractor for loss of profit or any other loss which employer, from the contractor may suffer as a result of such omission ? All costs incurred by firm supplying the contractor in materials and/or doing the preparation of claims work and shall be borne by the contractor. This provision shall not preclude an adjudicator or an arbitrator appointed in terms of this agreement [30.6 & 7] from making a determination on costs The contractor shall review, assess and adjudicate any claims received by him from any subcontractor and thereafter submit deliver same to the principal agent with not later than the works completion date The warranty shall state that workmanship, materials and installation are warranty for a recommendation in order to assist specific period from the final completion and that any defects that may arise during the specific period shall be made good at the expense of the firm supplying the materials and/or doing the work, upon written notice from the principal agent to do so The warranty will not be enforced if the work is damaged by defects in adjudicating the claim [26.6] construction of the building, in which case the responsibility for replacement shall rest entirely with the contractor. The principal agent shall be the sole judge of the cause responsible for defects in the works F:............................. V:............................ ........................ V:........................T:............................ ......................... Item 27 Clause 27.0 - Recovery of expense and/or loss F:............................. V:............................ T:............................ Item 28 Clause 28.0 - Suspension by the contractor Section No. 1 Bill No. 1 Preliminaries and General 103 It is specifically agreed that the contractor accepts the obligation of assisting the principal agent in implementing proper cost management on this project. The contractor will be advised by the principal agent of all cost management procedures which will be implemented to ensure that the final account does not exceed the budget F:............................. V:............................ ........................ V:........................T:............................ 29 Clause 29.0 - Termination ......................... Item F:............................. V:............................ T:............................ Item 30 Clause 30.0 - Dispute resolution F:............................. V:............................ T:............................ Item104 "Taking delivery" of goods, or articles, etc, on site by the contractor is hereby deemed to mean receiving, offloading, getting in, unpacking, checking that the quantity is correct, and that the goods comply with their specific order, are complete and undamaged, submitting a written report thereon to the interested parties and issuing authorised vouchers for the receipt of such goods. Such "Taking delivery" is deemed to include, amongst other things, the cost of the contractor
Appears in 1 contract
Samples: Principal Building Agreement
Carried Forward R. Section No. 1 Bill No. 1 Preliminaries There is a possibility that certain works related to tenant installation/user requirements may have to be delayed and may consequently not be executed prior to practical completion Should General 7 CLAUSE 7.0 : COMPLIANCE WITH LAWS AND REGULATIONS Without limiting the contractor be instructed to do so he shall execute this work under the conditions pertaining to this agreement on the basis that a separate amount for preliminaries appurtenant to this work (if applicable) is agreed to between the contractor and the principal agent and on condition that instruction to proceed with such work is given to him within a period of three (3) calendar months after the date of practical completion generality of the works The employer reserves provisions of clause 7.0 of the right to omit such work without compensation agreement, the contractor's attention is drawn to the contractor for loss provisions of profit or any other loss which the contractor may suffer as a result of such omission ? All costs incurred by the contractor in the preparation of claims shall be borne by the contractor. This provision shall not preclude an adjudicator or an arbitrator appointed Construction Regulations, 2003 issued in terms of this agreement [30.6 & 7] from making the Occupational Health and Safety Act, 1993 in which it is specifically stated that the employer shall prepare a determination documented health and safety specification for the works and that the employer shall ensure that the contractor has made provision for the cost of health and safety measures during the execution of the works. The principal agent shall, on costs The behalf of the employer, issue such health and safety specification and the contractor shall reviewprice opposite this item for compliance with the act and the regulations and the provisions of the aforementioned health and safety specification, assess provided such provisions are reasonable in terms of the act and adjudicate any claims received by him from any subcontractor and thereafter submit same to the principal agent with a recommendation in order to assist the principal agent in adjudicating the claim [26.6] regulations. F:............................. ............................ V:............................ T:............................ Item 27 Clause 27.0 - Recovery of expense and/or loss 8 CLAUSE 8.0 : WORKS RISK F:............................. ............................ V:............................ T:............................ Item 28 Clause 28.0 - Suspension by the contractor Section No. 1 Bill No. 1 Preliminaries 9 CLAUSE 9.0 : INDEMNITIES F:............................. ............................ V:............................ T:............................ 29 Clause 29.0 - Termination Item 10 CLAUSE 10.0 : WORKS INSURANCES F:............................. ............................ V:............................ T:............................ Item 30 Clause 30.0 - Dispute resolution 11 CLAUSE 11.0 : LIABILITY INSURANCES F:............................. ............................ V:............................ T:............................ Item12 CLAUSE 12.0 : EFFECTING INSURANCES F:............................ V:............................ T:............................ 13 CLAUSE 13.0 : STATE PROVISIONS F:............................ V:............................ T:............................ 14 CLAUSE 14.0 : SECURITY F:............................ V:............................ T:............................
Appears in 1 contract
Samples: Preliminaries Agreement
Carried Forward R. Section No. 1 Bill No. 1 Preliminaries There is a possibility that certain works related to tenant installation/user requirements may have A Clause 14.0 - Contract instructions Site instructions Instructions issued on site are to be delayed recorded in a site instruction book which is to be supplied and may consequently not be executed prior to maintained on site by the contractor F:............................. V:............................ T:............................ Item B Clause 15.0 - Practical completion F:............................. V:............................ T:............................ Item C Clause 16.0 - Defects liability period and final completion F:............................. V:............................ T:............................ D Clause 17.0 - Revision of the date for practical completion Should The removal or substitution of any materials and goods which do not conform to the specification or the contract drawings shall not constitute grounds for the extension of the construction period nor for the adjustment of the contract value [14.1.8; 17.1 & 2] Item F:............................. V:............................ T:............................ Item E Clause 18.0 - Penalty for late or non-completion F:............................. V:............................ T:............................ Item F Clause 19.0 - Payment Bill No. 1 Preliminaries Where prices are submitted by the contractor be instructed or subcontractor during the progress of the works in respect of contract instructions or in regard to do so he shall execute this work a claim under the conditions pertaining to terms of this agreement on and notwithstanding the basis fact that a separate amount for preliminaries appurtenant such prices may be used in an interim payment certificate, there is to this work (if applicable) is agreed to between the contractor and be no presumption of acceptance. Should the principal agent and on condition that instruction wish to proceed with accept any such work is given prices prior to him within a period of three (3) calendar months after the date of practical completion issue of the works The employer reserves certificate of final completion, it shall be in writing F:............................. V:............................ T:............................ A Clause 20.0 - Adjustment of the right to omit such work without compensation to the contractor for loss of profit or any other loss which the contractor may suffer as a result of such omission ? contract value and Item All costs incurred by the contractor in the preparation of claims shall be borne by the contractor. This provision shall not preclude an adjudicator or an arbitrator appointed in terms of this agreement [30.6 22.5 & 76] from making a determination on costs The contractor shall review, assess and adjudicate any claims received by him from any subcontractor and thereafter submit same to the principal agent with a recommendation in order to assist the principal agent in adjudicating the claim [26.6] F:............................. V:............................ T:............................ Item 27 B Clause 27.0 21.0 - Recovery of expense and/or loss Suspension or termination F:............................. V:............................ T:............................ Item 28 C Clause 28.0 - Suspension by the contractor Section No. 1 Bill No. 1 Preliminaries F:............................. V:............................ T:............................ 29 Clause 29.0 - Termination Item F:............................. V:............................ T:............................ Item 30 Clause 30.0 22.0 - Dispute resolution F:............................. V:............................ T:............................ ItemItem D Agreement Bill No. 1 Preliminaries The required information of the parties and the amount of the contract sum shall be inserted in the agreement for signature of the agreement by the parties F:............................. V:............................ T:............................
Appears in 1 contract
Samples: Building Agreement
