Common use of Carried Forward R Clause in Contracts

Carried Forward R. Section No. 1 Bill No. 1 Preliminaries and General 7 CLAUSE 7.0 : COMPLIANCE WITH LAWS AND REGULATIONS Without limiting the generality of the provisions of clause 7.0 of the agreement, the contractor's attention is drawn to the provisions of the Construction Regulations, 2003 issued in terms of the Occupational Health and Safety Act, 1993 in which it is specifically stated that the employer shall prepare a documented health and safety specification for the works and that the employer shall ensure that the contractor has made provision for the cost of health and safety measures during the execution of the works. The principal agent shall, on behalf of the employer, issue such health and safety specification and the contractor shall price opposite this item for compliance with the act and the regulations and the provisions of the aforementioned health and safety specification, provided such provisions are reasonable in terms of the act and the regulations. F:............................ V:............................ T:............................ 8 CLAUSE 8.0 : WORKS RISK F:............................ V:............................ T:............................ 9 CLAUSE 9.0 : INDEMNITIES F:............................ V:............................ T:............................ 10 CLAUSE 10.0 : WORKS INSURANCES F:............................ V:............................ T:............................ 11 CLAUSE 11.0 : LIABILITY INSURANCES F:............................ V:............................ T:............................ 12 CLAUSE 12.0 : EFFECTING INSURANCES F:............................ V:............................ T:............................ 13 CLAUSE 13.0 : STATE PROVISIONS F:............................ V:............................ T:............................ 14 CLAUSE 14.0 : SECURITY F:............................ V:............................ T:............................

Carried Forward R. Section No. 1 3 Bill No. 1 Preliminaries and General 7 CLAUSE 7.0 : COMPLIANCE WITH LAWS AND REGULATIONS Without limiting the generality PRELIMINARIES 72 Co-operation of the provisions of clause 7.0 of the agreement, the contractor's attention is drawn to the provisions of the Construction Regulations, 2003 issued in terms of the Occupational Health and Safety Act, 1993 in which it contractor for cost management It is specifically stated agreed that the employer shall prepare a documented health and safety specification for contractor accepts the works and that obligation of assisting the employer shall principal agent in implementing proper cost management. The contractor will be advised by the principal agent of all cost management procedures which will be implemented to ensure that the contractor has made provision for final building cost does not exceed the cost of health and safety measures during the execution of the worksbudget. The principal agent shall, on behalf of undertakes to make available to the employer, issue such health contractor all budgetary allowances and safety specification cost assessments/reports to enable the proper procedure to be implemented and the contractor shall price opposite this item attend all cost plan review and cost management meetings. The contractor undertakes to extend these procedures, as necessary, to all subcontractors F:...........................V:.........................T:......................... Item 73 Propping of floors below The contractor is advised that propping of floors below may be required if he wishes to use any areas of completed suspended reinforced concrete slabs for compliance with vehicle access, storage of materials and goods and location of plant, scaffolding, etc. The location of these areas and any necessary propping shall be approved by the act principal agent and the regulations and cost thereof shall be borne by the provisions contractor F:......................... V:........................... T:.......................... Item 74 Testing of windows for watertightness Each window shall be tested for watertightness with water sprayed on using adequate pressure. If in the opinion of the aforementioned health and safety specificationprincipal agent, provided such provisions are reasonable in terms the pressure proves to be inadequate, then the pressure shall be boosted by means of the act and the regulations. compressed air or other approved means F:............................ ....................... V:............................ ......................... T:............................ 8 CLAUSE 8.0 : WORKS RISK F:............................ V:............................ T:............................ 9 CLAUSE 9.0 : INDEMNITIES F:............................ V:............................ T:............................ 10 CLAUSE 10.0 : WORKS INSURANCES F:............................ V:............................ T:............................ 11 CLAUSE 11.0 : LIABILITY INSURANCES F:............................ V:............................ T:............................ 12 CLAUSE 12.0 : EFFECTING INSURANCES F:............................ V:............................ T:............................ 13 CLAUSE 13.0 : STATE PROVISIONS F:............................ V:............................ T:............................ 14 CLAUSE 14.0 : SECURITY F:............................ V:............................ T:..................................................... Item

Carried Forward R. Section No. 1 Bill No. 1 Preliminaries There is a possibility that certain works related to tenant installation/user requirements may have to be delayed and General 7 CLAUSE 7.0 : COMPLIANCE WITH LAWS AND REGULATIONS Without limiting may consequently not be executed prior to practical completion Should the generality contractor be instructed to do so he shall execute this work under the conditions pertaining to this agreement on the basis that a separate amount for preliminaries appurtenant to this work (if applicable) is agreed to between the contractor and the principal agent and on condition that instruction to proceed with such work is given to him within a period of three (3) calendar months after the date of practical completion of the provisions works The employer reserves the right to omit such work without compensation to the contractor for loss of clause 7.0 profit or any other loss which the contractor may suffer as a result of such omission ? All costs incurred by the agreement, contractor in the preparation of claims shall be borne by the contractor's attention is drawn to the provisions of the Construction Regulations, 2003 issued . This provision shall not preclude an adjudicator or an arbitrator appointed in terms of this agreement [30.6 & 7] from making a determination on costs The contractor shall review, assess and adjudicate any claims received by him from any subcontractor and thereafter submit same to the Occupational Health and Safety Act, 1993 in which it is specifically stated that the employer shall prepare a documented health and safety specification for the works and that the employer shall ensure that the contractor has made provision for the cost of health and safety measures during the execution of the works. The principal agent shall, on behalf of with a recommendation in order to assist the employer, issue such health and safety specification and principal agent in adjudicating the contractor shall price opposite this item for compliance with the act and the regulations and the provisions of the aforementioned health and safety specification, provided such provisions are reasonable in terms of the act and the regulations. claim [26.6] F:............................ ............................. V:............................ T:............................ 8 CLAUSE 8.0 : WORKS RISK Item 27 Clause 27.0 - Recovery of expense and/or loss F:............................ ............................. V:............................ T:............................ 9 CLAUSE 9.0 : INDEMNITIES Item 28 Clause 28.0 - Suspension by the contractor Section No. 1 Bill No. 1 Preliminaries F:............................ ............................. V:............................ T:............................ 10 CLAUSE 10.0 : WORKS INSURANCES 29 Clause 29.0 - Termination Item F:............................ ............................. V:............................ T:............................ 11 CLAUSE 11.0 : LIABILITY INSURANCES Item 30 Clause 30.0 - Dispute resolution F:............................ ............................. V:............................ T:............................ 12 CLAUSE 12.0 : EFFECTING INSURANCES F:............................ V:............................ T:............................ 13 CLAUSE 13.0 : STATE PROVISIONS F:............................ V:............................ T:............................ 14 CLAUSE 14.0 : SECURITY F:............................ V:............................ T:............................Item

Carried Forward R. Section No. 1 Bill No. 1 Preliminaries & General There is a possibility that certain works related to tenant installation/user requirements may have to be delayed and General 7 CLAUSE 7.0 : COMPLIANCE WITH LAWS AND REGULATIONS Without limiting may consequently not be executed prior to practical completion Should the generality contractor be instructed to do so he shall execute this work under the conditions pertaining to this agreement on the basis that a separate amount for preliminaries appurtenant to this work (if applicable) is agreed to between the contractor and the principal agent and on condition that instruction to proceed with such work is given to him within a period of three (3) calendar months after the date of practical completion of the provisions works The employer reserves the right to omit such work without compensation to the contractor for loss of clause 7.0 profit or any other loss which the contractor may suffer as a result of such omission ? All costs incurred by the agreement, contractor in the preparation of claims shall be borne by the contractor's attention is drawn to the provisions of the Construction Regulations, 2003 issued . This provision shall not preclude an adjudicator or an arbitrator appointed in terms of this agreement [30.6 & 7] from making a determination on costs The contractor shall review, assess and adjudicate any claims received by him from any subcontractor and thereafter submit same to the Occupational Health and Safety Act, 1993 in which it is specifically stated that the employer shall prepare a documented health and safety specification for the works and that the employer shall ensure that the contractor has made provision for the cost of health and safety measures during the execution of the works. The principal agent shall, on behalf of with a recommendation in order to assist the employer, issue such health and safety specification and principal agent in adjudicating the contractor shall price opposite this item for compliance with the act and the regulations and the provisions of the aforementioned health and safety specification, provided such provisions are reasonable in terms of the act and the regulations. claim [26.6] F:............................ ............................. V:............................ T:............................ 8 CLAUSE 8.0 : WORKS RISK Item 27 Clause 27.0 - Recovery of expense and/or loss F:............................ ............................. V:............................ T:............................ 9 CLAUSE 9.0 : INDEMNITIES Item 28 Clause 28.0 - Suspension by the contractor Section No. 1 Bill No. 1 Preliminaries & General F:............................ ............................. V:............................ T:............................ 10 CLAUSE 10.0 : WORKS INSURANCES 29 Clause 29.0 - Termination Item F:............................ ............................. V:............................ T:............................ 11 CLAUSE 11.0 : LIABILITY INSURANCES Item 30 Clause 30.0 - Dispute resolution F:............................ ............................. V:............................ T:............................ 12 CLAUSE 12.0 : EFFECTING INSURANCES F:............................ V:............................ T:............................ 13 CLAUSE 13.0 : STATE PROVISIONS F:............................ V:............................ T:............................ 14 CLAUSE 14.0 : SECURITY F:............................ V:............................ T:............................Item

Carried Forward R. Section No. 1 2 Bill No. 1 Preliminaries and General 7 CLAUSE 7.0 : COMPLIANCE WITH LAWS AND REGULATIONS Without limiting the generality PRELIMINARIES 72 Co-operation of the provisions of clause 7.0 of the agreement, the contractor's attention is drawn to the provisions of the Construction Regulations, 2003 issued in terms of the Occupational Health and Safety Act, 1993 in which it contractor for cost management It is specifically stated agreed that the employer shall prepare a documented health and safety specification for contractor accepts the works and that obligation of assisting the employer shall principal agent in implementing proper cost management. The contractor will be advised by the principal agent of all cost management procedures which will be implemented to ensure that the contractor has made provision for final building cost does not exceed the cost of health and safety measures during the execution of the worksbudget. The principal agent shall, on behalf of undertakes to make available to the employer, issue such health contractor all budgetary allowances and safety specification cost assessments/reports to enable the proper procedure to be implemented and the contractor shall price opposite this item attend all cost plan review and cost management meetings. The contractor undertakes to extend these procedures, as necessary, to all subcontractors F:...........................V:.........................T:......................... Item 73 Propping of floors below The contractor is advised that propping of floors below may be required if he wishes to use any areas of completed suspended reinforced concrete slabs for compliance with vehicle access, storage of materials and goods and location of plant, scaffolding, etc. The location of these areas and any necessary propping shall be approved by the act principal agent and the regulations and cost thereof shall be borne by the provisions contractor F:......................... V:........................... T:.......................... Item 74 Testing of windows for watertightness Each window shall be tested for watertightness with water sprayed on using adequate pressure. If in the opinion of the aforementioned health and safety specificationprincipal agent, provided such provisions are reasonable in terms the pressure proves to be inadequate, then the pressure shall be boosted by means of the act and the regulations. compressed air or other approved means F:............................ ....................... V:............................ ......................... T:............................ 8 CLAUSE 8.0 : WORKS RISK F:............................ V:............................ T:............................ 9 CLAUSE 9.0 : INDEMNITIES F:............................ V:............................ T:............................ 10 CLAUSE 10.0 : WORKS INSURANCES F:............................ V:............................ T:............................ 11 CLAUSE 11.0 : LIABILITY INSURANCES F:............................ V:............................ T:............................ 12 CLAUSE 12.0 : EFFECTING INSURANCES F:............................ V:............................ T:............................ 13 CLAUSE 13.0 : STATE PROVISIONS F:............................ V:............................ T:............................ 14 CLAUSE 14.0 : SECURITY F:............................ V:............................ T:..................................................... Item

Carried Forward R. Section No. 1 Bill No. 1 Preliminaries and General 7 CLAUSE 7.0 : COMPLIANCE WITH LAWS AND REGULATIONS Without limiting the generality PRELIMINARIES 72 Co-operation of the provisions of clause 7.0 of the agreement, the contractor's attention is drawn to the provisions of the Construction Regulations, 2003 issued in terms of the Occupational Health and Safety Act, 1993 in which it contractor for cost management It is specifically stated agreed that the employer shall prepare a documented health and safety specification for contractor accepts the works and that obligation of assisting the employer shall principal agent in implementing proper cost management. The contractor will be advised by the principal agent of all cost management procedures which will be implemented to ensure that the contractor has made provision for final building cost does not exceed the cost of health and safety measures during the execution of the worksbudget. The principal agent shall, on behalf of undertakes to make available to the employer, issue such health contractor all budgetary allowances and safety specification cost assessments/reports to enable the proper procedure to be implemented and the contractor shall price opposite this item attend all cost plan review and cost management meetings. The contractor undertakes to extend these procedures, as necessary, to all subcontractors F:...........................V:.........................T:......................... Item 73 Propping of floors below The contractor is advised that propping of floors below may be required if he wishes to use any areas of completed suspended reinforced concrete slabs for compliance with vehicle access, storage of materials and goods and location of plant, scaffolding, etc. The location of these areas and any necessary propping shall be approved by the act principal agent and the regulations and cost thereof shall be borne by the provisions contractor F:......................... V:........................... T:.......................... Item 74 Testing of windows for watertightness Each window shall be tested for watertightness with water sprayed on using adequate pressure. If in the opinion of the aforementioned health and safety specificationprincipal agent, provided such provisions are reasonable in terms the pressure proves to be inadequate, then the pressure shall be boosted by means of the act and the regulations. compressed air or other approved means F:............................ ....................... V:............................ ......................... T:............................ 8 CLAUSE 8.0 : WORKS RISK F:............................ V:............................ T:............................ 9 CLAUSE 9.0 : INDEMNITIES F:............................ V:............................ T:............................ 10 CLAUSE 10.0 : WORKS INSURANCES F:............................ V:............................ T:............................ 11 CLAUSE 11.0 : LIABILITY INSURANCES F:............................ V:............................ T:............................ 12 CLAUSE 12.0 : EFFECTING INSURANCES F:............................ V:............................ T:............................ 13 CLAUSE 13.0 : STATE PROVISIONS F:............................ V:............................ T:............................ 14 CLAUSE 14.0 : SECURITY F:............................ V:............................ T:..................................................... Item

Carried Forward R. Section No. 1 Bill No. 1 Preliminaries and General 7 CLAUSE 7.0 : COMPLIANCE WITH LAWS AND REGULATIONS Without limiting the generality PRELIMINARIES 18 Clause 18.0 - Setting out of the provisions works The contractor shall notify the principal agent if any encroachments of clause 7.0 of the agreementadjoining foundations, the contractor's attention is drawn to the provisions of the Construction Regulationsbuildings, 2003 issued structures, pavements, boundaries, etc. exist in terms of the Occupational Health and Safety Act, 1993 in which it is specifically stated order that the employer shall prepare a documented health and safety specification necessary arrangements may be made for the rectification of any such encroachments [18.1]. F: ............................ V:...........................T:........................... Item 19 Clause 19.0 - Temporary works and that the employer shall ensure that the contractor has made provision for the cost of health and safety measures during the execution of the works. The principal agent shall, on behalf of the employer, issue such health and safety specification and the contractor shall price opposite this item for compliance with the act and the regulations and the provisions of the aforementioned health and safety specification, provided such provisions are reasonable in terms of the act and the regulations. plant F:............................ ............................. V:............................ T:............................ 8 CLAUSE 8.0 : WORKS RISK Item 20 Clause 20.0 - Nominated subcontractors Refer to the provisions on general attendance hereinafter F:............................ ............................. V:............................ T:............................ 9 CLAUSE 9.0 : INDEMNITIES Item 21 Clause 21.0 - Selected subcontractors General attendance of n/s subcontractors for pricing by the contractor shall be in accordance with the n/s agreement. Notwithstanding this provision, general attendance shall be deemed to include for the contractor to provide free of charge to any n/s subcontractor such scaffolding as may reasonably be required by such n/s subcontractor for the execution of the relevant subcontract work F:............................ ............................. V:............................ T:............................ 10 CLAUSE 10.0 : WORKS INSURANCES FItem 22 Clause 22.0 - Employer's direct contractorsF:............................ ............................. V:............................ T:............................ 11 CLAUSE 11.0 : LIABILITY INSURANCES FItem 23 Clause 23.0 - Contractor's domestic subcontractorsF:............................ ............................. V:............................ T:............................ 12 CLAUSE 12.0 : EFFECTING INSURANCES F:............................ V:............................ T:............................ 13 CLAUSE 13.0 : STATE PROVISIONS F:............................ V:............................ T:............................ 14 CLAUSE 14.0 : SECURITY F:............................ V:............................ T:............................Item

Carried Forward R. Section No. 1 Preliminaries and General Bill No. 1 Preliminaries and General 7 CLAUSE 7.0 : COMPLIANCE WITH LAWS AND REGULATIONS Without limiting Where prices are submitted by the generality contractor or subcontractor during the progress of the provisions works in respect of clause 7.0 of contract instructions or in regard to a claim under the agreement, the contractor's attention is drawn to the provisions of the Construction Regulations, 2003 issued in terms of the Occupational Health agreement and Safety Actnotwithstanding the fact that such prices may be used in an interim payment certificate, 1993 in which it there is specifically stated that to be no presumption of acceptance. Should the employer shall prepare a documented health and safety specification for principal agent wish to accept any such prices prior to the works and that the employer shall ensure that the contractor has made provision for the cost of health and safety measures during the execution issue of the works. The principal agent shallcertificate of final completion, on behalf of the employer, issue such health and safety specification and the contractor it shall price opposite this item for compliance with the act and the regulations and the provisions of the aforementioned health and safety specification, provided such provisions are reasonable be in terms of the act and the regulations. writing F:............................ ............................. V:............................ T:............................ 8 CLAUSE 8.0 : WORKS RISK Item 27 Clause 26.0 - Adjustment of the contract value and final account All costs incurred by the contractor in the preparation of claims shall be borne by the contractor The contractor shall review, assess and adjudicate any claims received by him from any subcontractor and thereafter submit same to the principal agent with a recommendation to assist the principal agent in adjudicating the claim [26.6] F:............................ ............................. V:............................ T:............................ 9 CLAUSE 9.0 : INDEMNITIES Item 28 Clause 27.0 - Recovery of expense and/or loss F:............................ ............................. V:............................ T:............................ 10 CLAUSE 10.0 : WORKS INSURANCES Item 29 Clause 28.0 - Suspension by the contractor F:............................ ............................. V:............................ T:............................ 11 CLAUSE 11.0 : LIABILITY INSURANCES Item 30 Clause 29.0 - Termination F:............................ V:............................ T:............................ 12 CLAUSE 12.0 : EFFECTING INSURANCES F:............................ V:............................ T:............................ 13 CLAUSE 13.0 : STATE PROVISIONS F:............................ V:............................ T:............................ 14 CLAUSE 14.0 : SECURITY F:............................ ............................. V:............................ T:............................

Carried Forward R. Section No. 1 Bill No. 1 Preliminaries A Clause 14.0 - Contract instructions Site instructions Instructions issued on site are to be recorded in a site instruction book which is to be supplied and General 7 CLAUSE 7.0 : COMPLIANCE WITH LAWS AND REGULATIONS Without limiting the generality of the provisions of clause 7.0 of the agreement, the contractor's attention is drawn to the provisions of the Construction Regulations, 2003 issued in terms of the Occupational Health and Safety Act, 1993 in which it is specifically stated that the employer shall prepare a documented health and safety specification for the works and that the employer shall ensure that maintained on site by the contractor has made provision for the cost of health and safety measures during the execution of the works. The principal agent shall, on behalf of the employer, issue such health and safety specification and the contractor shall price opposite this item for compliance with the act and the regulations and the provisions of the aforementioned health and safety specification, provided such provisions are reasonable in terms of the act and the regulations. F:............................ ............................. V:............................ T:............................ 8 CLAUSE 8.0 : WORKS RISK Item B Clause 15.0 - Practical completion F:............................ ............................. V:............................ T:............................ 9 CLAUSE 9.0 : INDEMNITIES Item C Clause 16.0 - Defects liability period and final completion F:............................ ............................. V:............................ T:............................ 10 CLAUSE 10.0 : WORKS INSURANCES D Clause 17.0 - Revision of the date for practical completion The removal or substitution of any materials and goods which do not conform to the specification or the contract drawings shall not constitute grounds for the extension of the construction period nor for the adjustment of the contract value [14.1.8; 17.1 & 2] Item F:............................ ............................. V:............................ T:............................ 11 CLAUSE 11.0 : LIABILITY INSURANCES Item E Clause 18.0 - Penalty for late or non-completion F:............................ ............................. V:............................ T:............................ 12 CLAUSE 12.0 : EFFECTING INSURANCES Item F Clause 19.0 - Payment Bill No. 1 Preliminaries Where prices are submitted by the contractor or subcontractor during the progress of the works in respect of contract instructions or in regard to a claim under the terms of this agreement and notwithstanding the fact that such prices may be used in an interim payment certificate, there is to be no presumption of acceptance. Should the principal agent wish to accept any such prices prior to the issue of the certificate of final completion, it shall be in writing F:............................ ............................. V:............................ T:............................ 13 CLAUSE 13.0 : STATE PROVISIONS A Clause 20.0 - Adjustment of the contract value and Item All costs incurred by the contractor in the preparation of claims shall be borne by the contractor. This provision shall not preclude an adjudicator or an arbitrator appointed in terms of this agreement [22.5 & 6] from making a determination on costs F:............................ ............................. V:............................ T:............................ 14 CLAUSE 14.0 : SECURITY Item B Clause 21.0 - Suspension or termination F:............................. V:............................ T:............................ Item C Clause 22.0 - Dispute resolution F:............................. V:............................ T:............................ Item D Agreement Bill No. 1 Preliminaries The required information of the parties and the amount of the contract sum shall be inserted in the agreement for signature of the agreement by the parties F:............................. V:............................ T:............................

Carried Forward R. Section No. 1 2 Bill No. 1 Preliminaries and General 7 CLAUSE 7.0 : COMPLIANCE WITH LAWS AND REGULATIONS Without limiting the generality PRELIMINARIES 18 Clause 18.0 - Setting out of the provisions works The contractor shall notify the principal agent if any encroachments of clause 7.0 of the agreementadjoining foundations, the contractor's attention is drawn to the provisions of the Construction Regulationsbuildings, 2003 issued structures, pavements, boundaries, etc. exist in terms of the Occupational Health and Safety Act, 1993 in which it is specifically stated order that the employer shall prepare a documented health and safety specification necessary arrangements may be made for the rectification of any such encroachments [18.1]. F: ............................ V:...........................T:........................... Item 19 Clause 19.0 - Temporary works and that the employer shall ensure that the contractor has made provision for the cost of health and safety measures during the execution of the works. The principal agent shall, on behalf of the employer, issue such health and safety specification and the contractor shall price opposite this item for compliance with the act and the regulations and the provisions of the aforementioned health and safety specification, provided such provisions are reasonable in terms of the act and the regulations. plant F:............................ ............................. V:............................ T:............................ 8 CLAUSE 8.0 : WORKS RISK Item 20 Clause 20.0 - Nominated subcontractors Refer to the provisions on general attendance hereinafter F:............................ ............................. V:............................ T:............................ 9 CLAUSE 9.0 : INDEMNITIES Item 21 Clause 21.0 - Selected subcontractors General attendance of n/s subcontractors for pricing by the contractor shall be in accordance with the n/s agreement. Notwithstanding this provision, general attendance shall be deemed to include for the contractor to provide free of charge to any n/s subcontractor such scaffolding as may reasonably be required by such n/s subcontractor for the execution of the relevant subcontract work F:............................ ............................. V:............................ T:............................ 10 CLAUSE 10.0 : WORKS INSURANCES FItem 22 Clause 22.0 - Employer's direct contractorsF:............................ ............................. V:............................ T:............................ 11 CLAUSE 11.0 : LIABILITY INSURANCES FItem 23 Clause 23.0 - Contractor's domestic subcontractorsF:............................ ............................. V:............................ T:............................ 12 CLAUSE 12.0 : EFFECTING INSURANCES F:............................ V:............................ T:............................ 13 CLAUSE 13.0 : STATE PROVISIONS F:............................ V:............................ T:............................ 14 CLAUSE 14.0 : SECURITY F:............................ V:............................ T:............................Item