Remedies for Environmental Defects (a) If any Environmental Defect described in a notice delivered in accordance with Section 4.03 is not cured on or before the Closing, and Seller has not elected to exclude the affected Assets from this sale or Buyer and Seller have not agreed for Seller to indemnify Buyer for the Environmental Defect, then the Purchase Price shall be reduced by the Environmental Defect Value of such Environmental Defect as agreed by the Parties. (b) If Buyer and Seller have not agreed as to the validity of any asserted Environmental Defect, or if the Parties have not agreed on the Environmental Defect Value therefor, and if Seller shall not have elected to exclude the affected Assets from this sale pursuant to Section 4.03(b)(ii), then either Party shall have the right to elect to have the validity of the asserted Environmental Defect, and/or the Environmental Defect Value for such Environmental Defect, determined by an Independent Expert pursuant to Section 16.03. If the validity of any such asserted Environmental Defect or the amount of any such Environmental Defect Value is not determined by the Closing, the Asset affected by such disputed Environmental Defect shall be excluded from the Closing and the Purchase Price paid at the Closing shall be reduced by the Allocated Value of that Asset. Upon resolution of such dispute, the Allocated Value of that Asset less the Environmental Defect Value, if any, found to be attributable to such Environmental Defect shall, subject to this Section 4.04, be paid by Buyer to Seller and the Asset conveyed to Buyer, if that is part of the mutually agreed settlement. Notwithstanding the foregoing, either Buyer or Seller shall have the right to exclude an Asset from the sale if the Environmental Defect Value exceeds the Allocated Value of the Asset(s) affected thereby. (c) Notwithstanding anything to the contrary in this Agreement, (i) if the Environmental Defect Value for a given individual Environmental Defect does not exceed $50,000, then no adjustment to the Purchase Price shall be made for such Environmental Defect; (ii) if the aggregate adjustment to the Purchase Price determined in accordance with this Agreement for Title Defects and Environmental Defects does not exceed three percent (3%) of the Purchase Price prior to any adjustments thereto, then no adjustment of the Purchase Price shall be made therefore and (iii) if the aggregate adjustment to the Purchase Price determined in accordance with this Agreement for Title Defects and Environmental Defects does exceed three percent (3%) of the Purchase Price prior to any adjustments thereto, then the Purchase Price shall only be adjusted by the amount of such excess.
CLAIMS FOR DAMAGES 7.4.1 Should either party to the Contract suffer injury or damage to person or property because of any act or omission of the other party or of any of his / her employees, agents or others for whose acts he / she is legally liable, claim shall be made in writing to such other party within a reasonable time after the first observance of such injury or damage.
Waiver of Notice and Claims Each Pledgor hereby waives, to the fullest extent permitted by applicable law, notice or judicial hearing in connection with the Collateral Agent’s taking possession or the Collateral Agent’s disposition of the Pledged Collateral or any part thereof, including any and all prior notice and hearing for any prejudgment remedy or remedies and any such right which such Pledgor would otherwise have under law, and each Pledgor hereby further waives, to the fullest extent permitted by applicable law: (i) all damages occasioned by such taking of possession, (ii) all other requirements as to the time, place and terms of sale or other requirements with respect to the enforcement of the Collateral Agent’s rights hereunder and (iii) all rights of redemption, appraisal, valuation, stay, extension or moratorium now or hereafter in force under any applicable law. The Collateral Agent shall not be liable for any incorrect or improper payment made pursuant to this Article IX in the absence of gross negligence or willful misconduct on the part of the Collateral Agent. Any sale of, or the grant of options to purchase, or any other realization upon, any Pledged Collateral shall operate to divest all right, title, interest, claim and demand, either at law or in equity, of the applicable Pledgor therein and thereto, and shall be a perpetual bar both at law and in equity against such Pledgor and against any and all persons claiming or attempting to claim the Pledged Collateral so sold, optioned or realized upon, or any part thereof, from, through or under such Pledgor.
Claims for Additional Time If the Contractor wishes to make a Claim for an increase in the Contract Time, written notice as provided herein shall be given. The Contractor’s Claim shall include an estimate of cost and of probable effect of delay on progress of the Work. In the case of a continuing delay, only one Claim is necessary.
Notice of Defects If, based on Consulting Engineer/Architect's involvement during the construction phase, Consulting Engineer/Architect observes or otherwise becomes aware of any defect in the work, he shall give prompt written notice to City of such defects and their approximate location on the Project. However, Consulting Engineer/Architect shall not have control over or charge of and shall not be responsible for construction means, methods, techniques, sequences or procedures, or for safety precautions, inspections and programs in connection with the work, since these are solely the contractor's responsibility under the contract for construction. Consulting Engineer/Architect shall not be responsible for the contractor's schedules or failure to carry out the work in accordance with the Contract Documents. Consulting Engineer/Architect shall not have control over or charge of acts or omissions of the contractor, contractor's subcontractors, or their agents or employees.
Claims for Consequential Damages The Owner retains its right to claim for consequential damages in the event the Design Professional fails to perform under this Contract.
Procedures for Third Party Claims In the case of any claim for indemnification arising from a claim of a third-party other than an Infringement Claim subject to Section 13.3 above (a “Third-Party Claim”), a party seeking indemnification hereunder (each an “Indemnified Party”) shall give prompt written notice, following such Indemnified Party’s receipt of such claim or demand, to the party from which indemnity is sought (each an “Indemnifying Party”) of any claim or demand of which such Indemnified Party has knowledge and as to which it may request indemnification hereunder; provided, however, that failure to give such notice will not affect such Indemnified Party’s rights hereunder unless, and then solely to the extent that, the rights of the Indemnifying Parties from whom indemnity is sought are prejudiced as a result of such failure. The Indemnifying Party shall have the right (and if it elects to exercise such right, shall do so within twenty (20) days after receiving such notice from the Indemnified Party) to defend and to direct the defense against any such claim or demand, in its name or in the name of the Indemnified Party, as the case may be, at the expense of the Indemnifying Party, and with counsel selected by the Indemnifying Party; provided, that the Indemnifying Party shall be entitled to assume control of the defense of such action only if the Indemnifying Party acknowledges in writing its indemnity obligations and assumes and holds the Indemnified Party harmless from and against all Losses resulting from such Third-Party Claim; and provided further that the Indemnifying Party shall not be entitled to assume control of such defense if (i) the Indemnifying Party shall not have notified the Indemnified Party of its exercise of its right to defend such Third-Party claim within such twenty (20) day period; (ii) such claim or demand seeks an injunction or other equitable relief against the Indemnified Party, (iii) the Indemnified Party shall have reasonably concluded that (x) there is a conflict of interest between the Indemnified Party and the Indemnifying Party in the conduct of the defense of such claim or demand or (y) the Indemnified Party has one or more defenses not available to the Indemnifying Party, (iv) such claim relates to or arises in connection with any criminal proceeding, action, indictment, allegation or investigation, or (v) the appropriate court rules that the Indemnifying Party failed or is failing to vigorously prosecute or defend such Third-Party Claim. Notwithstanding anything in this Agreement to the contrary, the Indemnified Party shall, at the expense of the Indemnifying Party, cooperate with the Indemnifying Party, and keep the Indemnifying Party fully informed, in the defense of such claim or demand. The Indemnified Party shall have the right to participate in the defense of any claim or demand with counsel employed at its own expense; provided, however, that, in the case of any claim or demand described in clause (i) or (ii) of the second preceding sentence or as to which the Indemnifying Party shall not in fact have employed counsel to assume the defense of such claim or demand, the reasonable fees and disbursements of such counsel shall be at the expense of the Indemnifying Party. The Indemnifying Party shall have no indemnification obligations with respect to any such claim or demand which shall be settled by the Indemnified Party without the prior written consent of the Indemnifying Party, which consent shall not be unreasonably withheld, delayed or conditioned. The Indemnifying Party shall not settle any such claim without the prior written consent of the Indemnified Party (which consent shall not be unreasonably withheld, delayed or conditioned if such settlement is accompanied by a document releasing the Indemnified Party from all liability with respect to the matter in controversy that is binding, valid and enforceable against all applicable Parties). Notwithstanding the foregoing, if the Indemnified Party fails to object to the settlement within five (5) Business Days of receipt of a written notice from the Indemnifying Party containing the terms and condition of such settlement, the Indemnified Party shall be deemed to have consented to the settlement.
Rejection State Street reserves the right to decline to process or delay the processing of a payment order which (a) is in excess of the collected balance in the account to be charged at the time of State Street's receipt of such payment order; (b) if initiating such payment order would cause State Street, in State Street's sole judgment, to exceed any volume, aggregate dollar, network, time, credit or similar limits upon wire transfers which are applicable to State Street; or (c) if State Street, in good faith, is unable to satisfy itself that the transaction has been properly authorized.
Time Limits for Submission of Claim Failure by Purchaser to submit a Claim within established time limits shall relinquish the United States from any and all obligations whatsoever arising under the contract or portions thereof. Purchaser shall file such Claim within the following time limits: (a) When Purchaser constructs Specified Road, Pur- chaser must file any Claim not later than 60 days after re- ceipt of Forest Service written notification of acceptance; (b) When Forest Service constructs Specified Road, Purchaser must file any Claim not later than 60 days after receipt of Forest Service written notification authorizing use of road; (c) For subdivisions or cutting units, Purchaser must file any Claim not later than 60 days after receipt of Forest Service written notification that subdivision or cutting unit has been accepted; and (d) In all other cases, Purchaser must file any Claim not later than 60 days after receipt of Contracting Officer written notification that timber sale is closed.
REMEDY OF DEFECTS (a) The BUILDER shall remedy, at its expense, any defects, against which the VESSEL is guaranteed under this Article, by making all necessary repairs or replacements at the SHIPYARD or elsewhere as provided for in (b) hereinbelow. In such case, the VESSEL shall be taken at the BUYER's cost and responsibility to the place selected, ready in all respects for such repairs or replacements and in any event, the BUILDER shall not be responsible for towage, dockage, wharfage, port charges and anything else incurred for the BUYER's getting and keeping the VESSEL ready for such repairing or replacing. (b) However, if it is impractical (which shall include, but not be limited to, an emergency) to bring the VESSEL to the SHIPYARD, the BUYER may cause the necessary repairs or replacements to be made elsewhere which is deemed by the BUYER with the consent of the BUILDER which shall not be unreasonably withheld, to be suitable for the purpose, provided that, in such event, the BUILDER may forward or supply replacement parts or materials under the terms described in (c) hereinbelow, unless forwarding or supplying thereof under the terms described in (c) hereinbelow would impair or delay the operation or working schedule of the VESSEL. In the event that the BUYER proposes to cause the necessary repairs or replacements to be made to the VESSEL at any shipyard or works other than the SHIPYARD, the BUYER shall first (but in all events as soon as reasonably possible) give the BUILDER notice by email or facsimile of the time and place such repairs will be made, and if the VESSEL is not thereby delayed, or her operation or working schedule is not thereby impaired, the BUILDER shall have the right to verify by its own representative(s) the nature and extent of the defects complained of. The BUILDER shall, in such case, promptly advise the BUYER by email or facsimile, after such examination has been completed, of its acceptance or rejection of the defects as ones that are covered by the guarantee herein provided. Upon the BUILDER's acceptance of the defects as justifying remedy under this Article, or upon award of the arbitration so determining, the BUILDER shall compensate the BUYER an amount equal to the reasonable cost of making the same repairs or replacements at the SHIPYARD. (c) In the event that it is necessary for the BUILDER to forward a replacement for a defective part under this guarantee, replacement parts shall be shipped to the BUYER under the C.I.F terms to the BUYER's nominated port. The BUILDER reserves the option to retrieve, at the BUILDER's cost, any of the replaced equipment/parts in case defects are remedied in accordance with the provisions in this Article. (d) Any dispute under this Article shall be referred to arbitration in accordance with the provisions of Article XIII hereof.