CCR California Code of Regulations. Change Order A modification of the Contract as provided by the "Changes" Section of the General Conditions. Change Order Request County's request for Contractor to provide a proposal and price/time quote for County's desired Change Order, or County’s description of work to be performed pursuant to Contractor’s Request for Change. County of Orange, OC Public Works Term Definition Changed Conditions Site conditions or materials of an unexpected nature or differing from those represented in the Contract Documents as provided by the "Changes" Section of the General Conditions. Code Sections Except where otherwise specified, all statutory references (e.g. "Labor Code" or "Public Contract Code") shall mean those laws enacted by the State of California, as they may be amended. Contract The complete agreement between County and Contractor covering the Project, as represented by the Contract Documents. Contract Documents Documents comprising the complete agreement between County and Contractor as enumerated in the "Contract Documents" Section of the Agreement. Contract Price The total dollar amount of the Contract identified in the "Contract Price and Time" Section of the Agreement as it may be adjusted in accordance with the "Changes" Section of the General Conditions. Contract Time The number of calendar days specified in the "Contract Price and Time" Section of the Agreement that Contractor has to complete the work after the issuance of a Notice to Proceed, as it may be adjusted in accordance with the "Changes" Section of the General Conditions. Contract Unit Price The amount stated in the Bid for a single unit of an item of work. Contractor The Party awarded the Contract by County. County The County of Orange, a political subdivision of the State of California, and its representatives. Defective Work Contractor's performance that does not conform to the requirements of the Contract Documents, industry standards, manufacturers' recommendations, or requirements of the "Quality of Materials and Workmanship" Section of the General Conditions. Director Except where otherwise provided, references to "Director" shall mean the Director of OC Public Works or designee. Dust Control Plan Contractor's plan for compliance with County's Fugitive Dust Emission Control Plan in conformance with the SCAQMD Rule 403 (See the "Performance" Section of the General Conditions.) Emergency/Contingency Plan Contractor's provisions for handling spills of hazardous, liquid, or nuisance materials prepared in accordance with the "Hazardous or Contaminated Materials" subsection of the "Performance" Section of the General Conditions. Engineer of Record The California-registered engineer in responsible charge for the design of the Project and whose seal appears on the Plans and Special Provisions. Escrowed Documents Those documents sealed, submitted, and held in accordance with the "Escrowed Documents" Section of the Agreement. Final Payment The last and complete payment by County to Contractor under the Contract as provided by the "Payments" Section of the General Conditions. General Conditions The portion of the Contract Documents setting forth various conditions and requirements of the Contract. County of Orange, OC Public Works Term Definition Health and Safety Plan (H&SP) Contractor's detailed provisions for compliance with all applicable health and safety laws, orders and regulations. (See the "Performance" Section of the General Conditions.)
Appears in 1 contract
Samples: Construction Contract
CCR California Code of Regulations. Change Order A modification of the Contract as provided by the "Changes" Section of the General Conditions. Change Order Request County's request for Contractor to provide a proposal and price/time quote for County's desired Change Order, or County’s description of work to be performed pursuant to Contractor’s Request for Change. County of Orange, OC Public Works Term Definition Changed Conditions Site conditions or materials of an unexpected nature or differing from those represented in the Contract Documents as provided by the "Changes" Section of the General Conditions. Code Sections Except where otherwise specified, all statutory references (e.g. "Labor Code" or "Public Contract Code") shall mean those laws enacted by the State of California, as they may be amended. Term Definition Contract The complete agreement between County and Contractor covering the Project, as represented by the Contract Documents. Contract Documents Documents comprising the complete agreement between County and Contractor as enumerated in the "Contract Documents" Section of the Agreement. Contract Price The total dollar amount of the Contract identified in the "Contract Price and Time" Section of the Agreement as it may be adjusted in accordance with the "Changes" Section of the General Conditions. Contract Time The number of calendar days specified in the "Contract Price and Time" Section of the Agreement that Contractor has to complete the work after the issuance of a Notice to Proceed, as it may be adjusted in accordance with the "Changes" Section of the General Conditions. Contract Unit Price The amount stated in the Bid for a single unit of an item of work. Contractor The Party awarded the Contract by County. County The County of Orange, a political subdivision of the State of California, and its representatives. Defective Work Contractor's performance that does not conform to the requirements of the Contract Documents, industry standards, manufacturers' recommendations, or requirements of the "Quality of Materials and Workmanship" Section of the General Conditions. Director Except where otherwise provided, references to "Director" shall mean the Director of OC Public Works or designee. Dust Control Plan Contractor's plan for compliance with County's Fugitive Dust Emission Control Plan in conformance with the SCAQMD Rule 403 (See the "Performance" Section of the General Conditions.) Emergency/Contingency Plan Contractor's provisions for handling spills of hazardous, liquid, or nuisance materials prepared in accordance with the "Hazardous or Contaminated Materials" subsection of the "Performance" Section of the General Conditions. Engineer County of Orange Resident Engineer Construction Manager Engineer of Record The California-registered engineer in responsible charge for the design of the Project and whose seal appears on the Plans and Special Provisions. Escrowed Documents Those documents sealed, submitted, and held in accordance with the "Escrowed Documents" Section of the Agreement. Final Payment The last and complete payment by County to Contractor under the Contract as provided by the "Payments" Section of the General Conditions. General Conditions The portion of the Contract Documents setting forth various conditions and requirements of the Contract. County of Orange, OC Public Works Term Definition Health and Safety Plan (H&SP) Contractor's detailed provisions for compliance with all applicable health and safety laws, orders and regulations. (See the "Performance" Section of the General Conditions.)
Appears in 1 contract
Samples: Contract
CCR California Code of Regulations. Change Order A modification of the Contract as provided by the "Changes" Section of the General Conditions. Change Order Request County's request for Contractor D-BE to provide a proposal and price/time quote for County's desired Change Order, or County’s description of work to be performed pursuant to ContractorD-BE’s Request for Change. County of Orange, OC Public Works Term Definition Changed Conditions Site conditions or materials of an unexpected nature or differing from those represented in the Contract Documents as provided by the "Changes" Section of the General Conditions. Code Sections Except where otherwise specified, all statutory references (e.g. "Labor Code" or "Public Contract Code") shall mean those laws enacted by the State of California, as they may be amended. Construction Schedule D-BE's initial construction schedule after it has been accepted by County and designated as the Project Construction Schedule, and updated by each monthly schedule update. Contingency (County’s) A fund to cover cost growth during the Project used at the discretion of the County usually for costs that result from County directed changes or unforeseen site conditions. The amount of the County’s Contingency will be set by the County and will be in addition to the project costs included in the D-BE’s GMP packages. Use and management of the County’s Contingency during the construction phase is described in Section 3.2. Contingency (D-BE’s) A fund to cover cost growth during the Project used at the discretion of the D-BE usually for costs that result from Project circumstances. Contract The complete agreement between County and Contractor covering the Project, as represented by portion of the Contract Documents. , signed by both Parties, that contains the Project name, Contract Documents Documents comprising the complete agreement between County Price, Contract Time, Liquidated Damages, and Contractor as enumerated in the "Contract Documents" Section of the Agreementother terms and conditions. Contract Price The total dollar amount of the Contract identified in the "Contract Price and Time" Section of the Agreement as it may be adjusted in accordance with the "Changes" Section of the General Conditions. Contract Time The number of calendar days specified in the "Contract Price and And Time" Section of the Agreement that Contractor D-BE has to complete the work after the issuance of a Notice to ProceedProceed for GMP 1, as it may be adjusted in accordance with the "Changes" Section of the General Conditions. Contract Unit Price The amount stated in the Bid for a single unit of an item of work. Contractor The Party awarded the Contract by County. County The County of Orange, a political subdivision of the State of California, and its representatives, alternate designation, County, a body corporate and public. Design & Construction Critical Path Schedule Critical Path Schedule, means the sequence of activities from the start of the Work to the Substantial Completion of the Project. Any delay in the completion of these activities will extend the Substantial Completion date. Defective Work ContractorD-BE's performance that does not conform to the requirements of the Contract Documents, industry standards, manufacturers' recommendations, or requirements of the "Quality of Materials and And Workmanship" Section of the General Conditions. Design-Build Entity “Design-Build Entity” (D-BE), is used in the State’s Public Contract Code section 20133(c)(3) to describe the partnership, corporation, or other legal entity that is able to provide appropriately licensed contracting, architectural, and engineering services as needed pursuant to a design-build contract. Director Except where otherwise provided, references to "Director" shall mean the Director of OC Public Works or his or her designee. Term Definition Directed, Requested, etc.: Where not otherwise explained, terms such as "directed," "requested," "authorized," "selected," "approved," "required," "accepted," and "permitted" mean "directed by A-E," "requested by A-E," "requested by A-E," and similar phrases. However, no such implied meaning will be interpreted to extend A-E's responsibility into the D-BEs area of construction responsibility. Division 01 to 39 Specifications Division 01-39 Specifications: refers to Construction Specification Institute (CSI) format the organization of specifications. CSI is an organization that keeps and changes the standardization of construction language as it pertains to building specifications. Dust Control Plan ContractorD-BE's plan for compliance with County's Fugitive Dust Emission Control Plan in conformance with the SCAQMD Rule 403 (See the "Performance" Section of the General Conditions.) Emergency/Contingency Plan ContractorD-BE's provisions for handling spills of hazardous, liquid, or nuisance materials prepared in accordance with the "Hazardous or Contaminated Materials" subsection of the "Performance" Section of the General Conditions. Engineer or Architect of Record The California-registered architect or engineer in responsible charge for the design of the Project and whose seal appears on the Plans and Special Provisions. Escrowed Documents Those documents sealed, submitted, and held in accordance with the "Escrowed Documents" Section of the Agreement. Final Payment The last and complete payment by County to Contractor D-BE under the Contract as provided by the "Payments" Section of the General Conditions. General Conditions The portion of the Contract Documents setting forth various conditions and requirements of the Contract. County General Requirements The provisions of Orange, OC Public Works Term Definition Division 01 (1) CSI sections that shall apply to the entire work. GMP Guaranteed Maximum Price Health and Safety Plan (H&SP) ContractorD-BE's detailed provisions for compliance with all applicable health and safety laws, orders and regulations. (See the "Performance" Section of the General Conditions.)) Liquidated Damages Damages specified in the "Liquidated Damages" Section of the Agreement, payable to County for D-BE's failure to complete the work within the Contract Time.
Appears in 1 contract
Samples: Construction Contract
CCR California Code of Regulations. Change Order A modification of the Contract as provided by the "Changes" Section of the General Conditions. Term Definition Change Order Request County's request for Contractor CMARE to provide a proposal and price/time quote for County's desired Change Order, or County’s description of County work to be performed pursuant to Contractor’s Request for Change. County of Orange, OC Public Works Term Definition CMARE Changed Conditions Site conditions or materials of an unexpected nature or differing from those represented in the Contract Documents as provided by the "Changes" Section of the General Conditions. Code Sections Except where otherwise specified, all statutory references (e.g. "Labor Code" or "Public Contract Code") shall mean those laws enacted by the State of California, as they may be amended. Construction Fee costs, home office overhead and additional indirect costs) and Profit, Project Manager, Project Engineer, Superintendent and Safety Officer shall be included as indirect project costs with the appropriate utilization rates. All other indirect labor shall be included in the general administration and overhead portion of the construction fee. Construction Schedule CMARE's initial construction schedule after it has been accepted by County and designated as the Project Construction Schedule and updated by each monthly schedule update. Contract The complete agreement Contract between County and Contractor CMARE covering the Project, as represented by the Contract Documents. Contract Documents Documents comprising the complete agreement Contract between County and Contractor CMARE as enumerated in the "Contract Documents" Section of the AgreementContract. Contract Price The total dollar amount of the Contract identified in the "Contract Price and Time" Section of the Agreement Contract as it may be adjusted in accordance with the "Changes" Section of the General Conditions. Contract Time The number of calendar days specified in the "Contract Price and Time" Section of the Agreement Contract that Contractor CMARE has to complete the work after the issuance of a Notice to Proceed, as it may be adjusted in accordance with the "Changes" Section of the General Conditions. Contract Unit Price The amount stated in the Bid for a single unit of an item of work. Contractor The Party awarded the Contract by County. Construction Manager At- Risk Entity (CMARE) County The County of Orange, a political subdivision of the State of California, and its representatives, alternate designation, County, a body corporate and public. Defective Work ContractorCMARE's performance that does not conform to the requirements of the Contract Documents, industry standards, manufacturers' recommendations, or requirements of the "Quality of Materials and Workmanship" Section of the General Conditions. Director Except where otherwise provided, references to "Director" shall mean the Director of OC Public Works or his or her designee. Term Definition Directed, Requested, etc.: Where not otherwise explained, terms such as "directed," "requested," "authorized," "selected," "approved," "required," "accepted," and "permitted" mean "directed by A-E," "requested by A-E," "requested by A-E," and similar phrases. However, no such implied meaning will be interpreted to extend A-E's responsibility into the CMARE's area of construction responsibility. Division 01 to 39 Specifications Division 01-39 Specifications: refers to Construction Specification Institute (CSI) format the organization of specifications. CSI is an organization that keeps and changes the standardization of construction language as it pertains to building specifications. Dust Control Plan ContractorCMARE's plan for compliance with County's Fugitive Dust Emission Control Plan in conformance with the SCAQMD Rule 403 (See the "Performance" Section of the General Conditions.) Emergency/Contingency Plan ContractorCMARE's provisions for handling spills of hazardous, liquid, or nuisance materials prepared in accordance with the "Hazardous or Or Contaminated Materials" subsection of the "Performance" Section of the General Conditions. Engineer or Architect of Record The California-registered architect or engineer in responsible charge for the design of the Project and whose seal appears on the Plans and Special Provisions. Escrowed Documents Those documents sealed, submitted, and held in accordance with the "Escrowed Documents" Section of the Agreement. Final Payment The last and complete payment by County to Contractor CMARE under the Contract as provided by the "Payments" Section of the General Conditions. General Conditions The portion of the Contract Documents setting forth various conditions and requirements of the Contract. General Requirements The provisions of Division 01 (1) CSI sections that shall apply to the entire work. GMP Guaranteed Maximum Price GMP Item An item of work or task listed in the GMP Schedule including the description, quantity (where applicable), and unit cost. GMP Item, Deletable A GMP Item that is considered part of the GMP, but which may or may not be deleted from the Contract Price at any time prior to completion of the work. GMP Item, Specialty A GMP Item that is considered part of the GMP but not considered part of the CMARE 25 percent (25%) of the work. GMP Proposal A GMP Proposal is an offer made by the CMARE to the County in accordance with the Instruction to Respondents. GMP Schedule The detailed list of items of work with associated quantities, prices, and type of cost, submitted with each GMP. Liquidated Damages within the Contract Time. Lump Sum (LS) for all labor, materials, overhead, and other costs associated with the work item (s. Term Definition Manifests Required documents that identify the generator, transporter, disposal facility and type of hazardous material(s). Manifests include but are not limited to: documents entitled Uniform Hazardous Waste Manifest(s), Bills of lading, or similar documentation concerning the handling, transportation, and disposal of materials (See the "Hazardous Or Contaminated Materials" subsection of the "Performance" Section of the General Conditions.) Notice of Completion The document recorded by County in accordance with Civil Code Section 8182 after completion of the work. Notice of Termination County's notice to CMARE specifying the effective date of a termination of the Contract (in whole or in part), as provided by the "Termination for Convenience of County" Section of the General Conditions. OCPW Orange County Public Works, A County of OrangeOrange Agency/Department Party / Parties The County and/or CMARE. Plans The drawings, OC profiles, cross sections, standard plans, working drawings, and shop drawings, or reproductions thereof, approved by County, which show the location, character, dimensions, or details of the Project. Project All work performed by CMARE as required by, and in strict accordance with, the Contract Documents. Project Manager (PM) The County representative identified in the Contract Documents or otherwise specified by County or CMARE in writing. Promptly One (1) week beginning with th acknowledge and initiate action(s). Reference Specifications Those bulletins, standards, rules, methods of analysis or testing, codes, and specifications of other agencies, engineering societies or industrial association referred to in the Contract Documents. These shall refer to the latest edition, including amendments in effect and published at the time of advertising the Contract or issuing the permit, unless specifically referred to by edition, volume or date. Retention The amount of progress payments withheld by County as security for CMARE r performance of the Contract as provided by the "Payments" Section of the General Conditions. Retention Payment Payment of the Retention in accordance with Public Works Contract Code 7107 and the "Retention Payment" Section of the General Conditions. Request for Change CMARE's request that County issue a Change Order. Schedule of Values Detailed breakdown by discipline or unit prices and costs as defined for the project in the Schedule of Values in the Construction Contract and its General Conditions, as attached hereto. Schedule Update(s) CMARE's monthly update of work progress. (See the "Project Subcontractor(s) Those contractors independently engaged by CMARE to perform portions of the work. Term Definition Health Submittals Items that the Contract Documents require CMARE to submit to County after award of the Contract and Safety issuance of the Notice to Proceed, as provided by the "Submittals" Section of the General Conditions. Supplementary General Conditions The portion of the Contract Documents identified describing additions and revisions to the General Conditions setting forth conditions and requirements peculiar to the Project. Traffic Control Plan (H&SPTCP) ContractorCMARE's detailed provisions for compliance with all applicable health and safety laws, orders and regulationscoordination of its traffic at the Project site. (See the "Performance" Section of the General Conditions.)) Unilateral Change Order A Change Order issued by the County where County and CMARE cannot reach an agreement on a proposed modification to the Contract.
Appears in 1 contract
Samples: Construction Services Contract
CCR California Code of Regulations. Change Order A modification of the Contract as provided by the "Changes" Section of the General Conditions. Change Order Request County's request for Contractor to provide a proposal and price/time quote for County's desired Change Order, or County’s description of County work to be performed pursuant to Contractor’s Request Contractor for Change. County of Orange, OC Public Works Term Definition Changed Conditions Site conditions or materials of an unexpected nature or differing from those represented in the Contract Documents as provided by the "Changes" Section of the General Conditions. Code Sections Except where otherwise specified, all statutory references (e.g. "Labor Code" or "Public Contract Code") shall mean those laws enacted by the State of California, as they may be amended. Contract The complete agreement between County and Contractor covering the Project, as represented by the Contract Documents. Contract Documents Documents comprising the complete agreement between County and Contractor as enumerated in the "Contract Documents" Section of the Agreement. Contract Price The total dollar amount of the Contract identified in the "Contract Price and Time" Section of the Agreement as it may be adjusted in accordance with the "Changes" Section of the General Conditions. Contract Time The number of calendar days specified in the "Contract Price and Time" Section of the Agreement that Contractor has to complete the work after the issuance of a Notice to Proceed, as it may be adjusted in accordance with the "Changes" Section of the General Conditions. Contract Unit Price The amount stated in the Bid for a single unit of an item of work. Contractor The Party awarded the Contract by County. County The County of Orange, a political subdivision of the State of California, and its representatives. Defective Work Contractor's performance that does not conform to the requirements of the Contract Documents, industry standards, manufacturers' recommendations, or requirements of the "Quality of Materials and Workmanship" Section of the General Conditions. Director Except where otherwise provided, references to "Director" shall mean the Director of OC Public Works or designee. Dust Control Plan Contractor's plan for compliance with County's Fugitive Dust Emission Control Plan in conformance with the SCAQMD Rule 403 (See the "Performance" Section of the General Conditions.) Emergency/Contingency Plan Contractor's provisions for handling spills of hazardous, liquid, or nuisance materials prepared in accordance with the "Hazardous or Contaminated Materials" subsection of the "Performance" Section of the General Conditions. Engineer of Record The California-registered engineer in responsible charge for the design of the Project and whose seal appears on the Plans and Special Provisions. Escrowed Documents Those documents sealed, submitted, and held in accordance with the "Escrowed Documents" Section of the Agreement. Final Payment The last and complete payment by County to Contractor under the Contract as provided by the "Payments" Section of the General Conditions. General Conditions The portion of the Contract Documents setting forth various conditions and requirements of the Contract. County of Orange, OC Public Works Term Definition Health and Safety Plan (H&SP) Contractor's detailed provisions for compliance with all applicable health and safety laws, orders and regulations. (See the "Performance" Section of the General Conditions.)
Appears in 1 contract
Samples: Construction Contract
