Changes Involving Schedule Extensions Sample Clauses

Changes Involving Schedule Extensions. To the extent that Contractor demonstrates that an event for which it is entitled to a Change as described in Section 9.5.1 is the sole cause of critical path delay to Contractor’s ability to perform the Work despite Contractor’s use of commercially reasonable efforts to mitigate and avoid any such delay, Owner shall issue a Change Order to extend the dates in the Project Schedule as necessary to accommodate such delay. Contractor’s demonstration of the impact on the critical path of the Work must be made on a basis that analyzes the actual impacts of the given event on the then-current schedule for completion of the Work. In no event will Contractor be entitled to an extension of time under this Section 9.5.2 to the extent that the performance of the Work for which the extension is sought would have been suspended, delayed or interrupted by the concurrent fault, actions or omissions of Contractor.
AutoNDA by SimpleDocs
Changes Involving Schedule Extensions. To the extent that Supplier reasonably demonstrates that a Change will delay Supplier in complying with the Construction Schedule (taking into consideration implementation of reasonable mitigation of such delay), then System Owner will issue the Change Order including an equitable extension of the date(s) in the Construction Schedule.
Changes Involving Schedule Extensions. To the extent that Contractor demonstrates that a Change (or the Change Event necessitating a Change) as described in Section 10.2.2 or Section 10.3 will delay the achievement of the Required Contract Dates, then Owner shall cause a Change Order directing such Change (or resulting from such Change Event) to equitably extend the Required Contract Dates to account for the delay in the critical path of the Work.
Changes Involving Schedule Extensions. To the extent that Contractor demonstrates that a Change (or the Change Event necessitating a Change) as described in Section 10.2.2 or Section 10.3 will delay the achievement of the Target Completion Dates, then PSGC shall cause a Change Order directing such Change (or resulting from such Change Event) to equitably extend the Target Contract Dates to account for the delay in the critical path of the Work. The Parties agree that the measure of leeway in starting or completing an activity without affecting the duration of time between Contractor’s Base Target Substantial Completion Date for each Unit and the Contractual Target Substantial Completion Date for each such Unit belongs to Contractor when determining whether there has been an impact to the critical path for which Contractor may be entitled to schedule relief under this Agreement.
Changes Involving Schedule Extensions. To the extent that Company reasonably demonstrates that an event necessitating a Change as described in Section 10.5.1 will delay Company in performing the applicable Work by a Guaranteed Completion Date despite Company’s use of reasonable efforts to mitigate and avoid any such delay, Owner shall issue a Change Order extending the Project Schedule on an equitable basis as determined by the facts and circumstances surrounding such event and the effect on timing of the Work, including the time of year, the stage of the Work and the duration of the event, to enable Company to remedy the effect on Company’s ability to perform the Work including achievement of the applicable Key Milestone(s) demonstrated by Company as being required solely as a result of the event (or combination of events) as described in Section 10.5.1 necessitating the Change. Company’s demonstration of the impact on the progress of the Work must be made on a basis that analyzes the actual impacts of the given event on the then-current schedule for completion of the Work. In no event will Company be entitled to an extension of time under this Section 10.5.2 to the extent that the performance of the Work for which the extension is sought would have been suspended, delayed or interrupted by the concurrent fault, actions or omissions of Company or Subcontractors.
Changes Involving Schedule Extensions. Within five (5) Business Days of submission of a Change Order Notice under Section 19.2.1, or within ten (10) Business Days after submission of a Change Order Request under Section 19.2.2, the Contractor shall prepare and submit, on an Open Book basis, an analysis of the delay, if any, caused by such Change to the critical path progress of the Work. Contractor shall supplement this analysis on an Open Book basis with such other information as Owner may reasonably require. Any Change Order extending any date in the Approved Project Schedule will only extend such date(s) by a number of calendar days, at a maximum, equal to the number of calendar days of delay Directly Caused to the actual critical path of the Work at the time of the event giving rise to the Change Order and only to the extent that such delay to the critical path progress of the Work has been demonstrated by Contractor to Owner’s reasonable satisfaction.

Related to Changes Involving Schedule Extensions

  • Changes in Fiscal Periods Permit the fiscal year of the Borrower to end on a day other than December 31 or change the Borrower’s method of determining fiscal quarters.

  • Amendments, Changes and Modifications Except as to the termination rights of both Parties as indicated in the Facilities Lease, this Site Lease may not be amended, changed, modified, altered or terminated without the written agreement of both Parties hereto.

  • Changes and Modifications (i) DST shall have the right, at any time, to modify any systems, programs, procedures or facilities used in performing its obligations hereunder; provided that the Fund will be notified as promptly as possible prior to implementation of such modifications and that no such modification or deletion shall materially adversely change or affect the operations and procedures of the Fund in using the TA2000 System hereunder, the Services or the quality thereof, or the reports to be generated by such system and facilities hereunder, unless the Fund is given thirty (30) days’ prior notice to allow the Fund to change its procedures and DST provides the Fund with revised operating procedures and controls.

  • Procedure for Termination, Amendment, Extension or Waiver A termination of this Agreement pursuant to Section 7.01, an amendment of this Agreement pursuant to Section 7.03 or an extension or waiver of this Agreement pursuant to Section 7.04 shall, in order to be effective, require in the case of Parent, Sub or the Company, action by its Board of Directors.

  • Benchmark Replacement Conforming Changes In connection with the use, administration, adoption or implementation of a Benchmark Replacement, the Administrative Agent will have the right to make Conforming Changes from time to time and, notwithstanding anything to the contrary herein or in any other Loan Document, any amendments implementing such Conforming Changes will become effective without any further action or consent of any other party to this Agreement or any other Loan Document.

  • Limitation on Changes in Fiscal Periods Permit the fiscal year of the Borrower to end on a day other than December 31 or change the Borrower's method of determining fiscal quarters.

  • Specific Enforcement; Extension of Period (a) Employee acknowledges that the restrictions contained in Sections 6, 7, and 8 hereof are reasonable and necessary to protect the legitimate interests of the Company and its affiliates and that the Company would not have entered into this Agreement in the absence of such restrictions. Employee also acknowledges that any breach by him of Sections 6, 7, or 8 hereof will cause continuing and irreparable injury to the Company for which monetary damages would not be an adequate remedy. The Employee shall not, in any action or proceeding to enforce any of the provisions of this Agreement, assert the claim or defense that an adequate remedy at law exists. In the event of such breach by Employee, the Company shall have the right to enforce the provisions of Sections 6, 7, and 8 of this Agreement by seeking injunctive or other relief in any court, and this Agreement shall not in any way limit remedies of law or in equity otherwise available to the Company. If an action at law or in equity is necessary to enforce or interpret the terms of this Agreement, the prevailing party shall be entitled to recover, in addition to any other relief, reasonable attorneys' fees, costs and disbursements. In the event that the provisions of Sections 6, 7, or 8 hereof should ever be adjudicated to exceed the time, geographic, or other limitations permitted by applicable law in any applicable jurisdiction, then such provisions shall be deemed reformed in such jurisdiction to the maximum time, geographic, or other limitations permitted by applicable law.

  • Product Changes Vocera shall have the right, in its absolute discretion, without liability to End User, to update to provide new functionality or otherwise change the design of any Product or to discontinue the manufacture or sale of any Product. Vocera shall notify End User at least 90 days prior to the delivery of any Product which incorporates a change that adversely affects form, fit or function (“Material Change”). Vocera shall also notify End User at least 90 days prior to the discontinuance of manufacture of any Product. Notification will be made as soon as reasonably practical for changes associated with regulatory or health and safety issues.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!