HUB Subcontracting Plan The Owner has adopted Exhibit H, Policy on Utilization of Historically Underutilized Business ("Policy"), which is incorporated herein by reference. Contractor, as a provision of the Agreement must comply with the requirements of the Policy and adhere to the HUB Subcontracting Plan submitted with Contractor's Proposal and attached as Exhibit I. No changes to the HUB Subcontracting Plan can be made by the Contractor without the prior written approval of the Owner in accordance with the Policy.
Uncovering and Correction of Work 12.1 The Contractor shall promptly correct Work rejected by the Owner or failing to conform to the requirements of the Contract Documents, whether observed before or after Substantial Completion and whether or not fabricated, installed or completed, and shall correct any Work found to be not in accordance with the requirements of the Contract Documents within a period of two years from the date of Substantial Completion, or by terms of an applicable special warranty required by the Contract Documents. The provisions of this Article apply to work done by Subcontractors as well as to Work done by direct employees of the Contractor. 12.2 At any time during the progress of the work, or in any case where the nature of the defects shall be such that it is not expedient to have them corrected, the Owner, at their option, shall have the right to deduct such sum, or sums, of money from the amount of the contract as they consider justified to adjust the difference in value between the defective work and that required under contract including any damage to the structure.
Statement of Work The Statement of Work to which Grantee is bound is incorporated into and made a part of this Grant Agreement for all purposes and included as Attachment A.
SCOPE OF ARCHITECT’S BASIC SERVICES 3.1 The Architect’s Basic Services consist of those described in this Article 3 and include usual and customary structural, mechanical, and electrical engineering services. Services not set forth in this Article 3 are Supplemental or Additional Services. § 3.1.1 The Architect shall manage the Architect’s services, research applicable design criteria, attend Project meetings, communicate with members of the Project team, and report progress to the Owner. § 3.1.2 The Architect shall coordinate its services with those services provided by the Owner and the Owner’s consultants. The Architect shall be entitled to rely on, and shall not be responsible for, the accuracy, completeness, and timeliness of, services and information furnished by the Owner and the Owner’s consultants. The Architect shall provide prompt written notice to the Owner if the Architect becomes aware of any error, omission, or inconsistency in such services or information. § 3.1.3 As soon as practicable after the date of this Agreement, the Architect shall submit for the Owner’s approval a schedule for the performance of the Architect’s services. The schedule initially shall include anticipated dates for the commencement of construction and for Substantial Completion of the Work as set forth in the Initial Information. The schedule shall include allowances for periods of time required for the Owner’s review, for the performance of the Owner’s consultants, and for approval of submissions by authorities having jurisdiction over the Project. Once approved by the Owner, time limits established by the schedule shall not, except for reasonable cause, be exceeded by the Architect or Owner. With the Owner’s approval, the Architect shall adjust the schedule, if necessary, as the Project proceeds until the commencement of construction. § 3.1.4 The Architect shall not be responsible for an Owner’s directive or substitution, or for the Owner’s acceptance of non-conforming Work, made or given without the Architect’s written approval. § 3.1.5 The Architect shall contact governmental authorities required to approve the Construction Documents and entities providing utility services to the Project. The Architect shall respond to applicable design requirements imposed by those authorities and entities. § 3.1.6 The Architect shall assist the Owner in connection with the Owner’s responsibility for filing documents required for the approval of governmental authorities having jurisdiction over the Project.
Contractor Changes The Contractor shall notify DAS in writing no later than ten (10) Days from the effective date of any change in: a. its certificate of incorporation or other organizational document; b. more than a controlling interest in the ownership of the Contractor; or c. the individual(s) in charge of the Performance. This change shall not relieve the Contractor of any responsibility for the accuracy and completeness of the Performance. DAS, after receiving written notice by the Contractor of any such change, may require such agreements, releases and other instruments evidencing, to DAS’s satisfaction, that any individuals retiring or otherwise separating from the Contractor have been compensated in full or that provision has been made for compensation in full, for all work performed under terms of the Contract. The Contractor shall deliver such documents to DAS in accordance with the terms of DAS’s written request. DAS may also require, and the Contractor shall deliver, a financial statement showing that solvency of the Contractor is maintained. The death of any Contractor Party, as applicable, shall not release the Contractor from the obligation to Perform under the Contract; the surviving Contractor Parties, as appropriate, must continue to Perform under the Contract until Performance is fully completed.
Assignment and Subcontracting City and Consultant recognize and agree that this Agreement contemplates personal performance by Consultant and is based upon a determination of Consultant’s unique personal competence, experience, and specialized personal knowledge. Moreover, a substantial inducement to City for entering into this Agreement was and is the professional reputation and competence of Consultant. Consultant may not assign this Agreement or any interest therein without the prior written approval of the City. Consultant shall not subcontract any portion of the performance contemplated and provided for herein, other than to the subcontractors listed in the Consultant’s proposal, without prior written approval of the City.
Vendor’s Subcontractors TIPS recognizes that many vendors operate in the open market through the use of subcontractors. For that reason, TIPS permits Vendor to utilize subcontractors as authorized and permitted by the TIPS Member Customer. However, all purchase documents must include: (1) Vendor’s Name, as known to TIPS, and; (2) Vendor’s TIPS Contract Name and Number under which it is making the TIPS Sale. Vendor must report the sale pursuant to the terms herein and Vendor agrees that it is legally responsible for all reporting and fee payment as described herein for TIPS Sales even when subcontractors are utilized. The TIPS Administration Fee is assessed on the amount paid by the TIPS Member to Vendor. The Parties intend that Vendor shall be responsible and for actions of subcontractors during a TIPS Sale. Vendor agrees that it is voluntarily authorizing subcontractors and in doing so, Xxxxxx agrees that it is doing so at its own risk and agrees to protect, indemnify, and hold TIPS harmless in accordance with Sections 14-17 above related to subcontractor TIPS Sales made pursuant to this Agreement or purporting to be made pursuant to this Agreement that may be asserted against Vendor whether rightfully brought or otherwise. The Parties further agree that it is no defense to Vendor’s breach of this Agreement that a subcontractor caused Vendor of breach this Agreement.
Use of Subservicers and Subcontractors (a) The Master Servicer shall cause any Subservicer used by the Master Servicer (or by any Subservicer) for the benefit of the Depositor to comply with the provisions of Section 3.16 and this Article XI to the same extent as if such Subservicer were the Master Servicer (except with respect to the Master Servicer's duties with respect to preparing and filing any Exchange Act Reports or as the Certifying Person). The Master Servicer shall be responsible for obtaining from each Subservicer and delivering to the Depositor any servicer compliance statement required to be delivered by such Subservicer under Section 3.16, any assessment of compliance and attestation required to be delivered by such Subservicer under Section 11.07 and any certification required to be delivered to the Certifying Person under Section 11.05 as and when required to be delivered. As a condition to the succession to any Subservicer as subservicer under this Agreement by any Person (i) into which such Subservicer may be merged or consolidated, or (ii) which may be appointed as a successor to any Subservicer, the Master Servicer shall provide to the Depositor, at least 15 calendar days prior to the effective date of such succession or appointment, (x) written notice to the Depositor of such succession or appointment and (y) in writing and in form and substance reasonably satisfactory to the Depositor, all information reasonably requested by the Depositor in order to comply with its reporting obligation under Item 6.02 of Form 8-K. (b) It shall not be necessary for the Master Servicer, any Subservicer or the Trustee to seek the consent of the Depositor or any other party hereto to the utilization of any Subcontractor. The Master Servicer or the Trustee, as applicable, shall promptly upon request provide to the Depositor (or any designee of the Depositor, such as the Master Servicer or administrator) a written description (in form and substance satisfactory to the Depositor) of the role and function of each Subcontractor utilized by such Person (or in the case of the Master Servicer or any Subservicer), specifying (i) the identity of each such Subcontractor, (ii) which (if any) of such Subcontractors are "participating in the servicing function" within the meaning of Item 1122 of Regulation AB, and (iii) which elements of the Servicing Criteria will be addressed in assessments of compliance provided by each Subcontractor identified pursuant to clause (ii) of this paragraph. As a condition to the utilization of any Subcontractor determined to be a Reporting Subcontractor, the Master Servicer or the Trustee, as applicable, shall cause any such Subcontractor used by such Person (or in the case of the Master Servicer or any Subservicer) for the benefit of the Depositor to comply with the provisions of Sections 11.07 and 11.09 of this Agreement to the same extent as if such Subcontractor were the Master Servicer (except with respect to the Master Servicer's duties with respect to preparing and filing any Exchange Act Reports or as the Certifying Person) or the Trustee, as applicable. The Master Servicer or the Trustee, as applicable, shall be responsible for obtaining from each Subcontractor and delivering to the Depositor and the Master Servicer, any assessment of compliance and attestation required to be delivered by such Subcontractor under Section 11.05 and Section 11.07, in each case as and when required to be delivered.
Support and Maintenance Services Information about Teradici’s support and maintenance for the Licensed Product may be found at xxxxx://xxxx.xxxxxxxx.xxx.
Maintenance and Support Services If this Agreement is for IT goods or services, this section applies: Unless otherwise specified in this Agreement: The Contractor shall promptly provide the Court with all Upgrades, including without limitation: (i) all Upgrades generally made available by Contractor to its other customers; (ii) Upgrades as necessary so that the Work complies with the Specifications and Applicable Law (including changes in Applicable Law); (iii) Upgrades as necessary so that the Work operates under new versions or releases of the Court’s operating system or database platform; and (iv) all on-site services necessary for installation of Upgrades. Without limiting any other obligation of Contractor under this Agreement, Contractor represents and warrants that it will maintain services, equipment, software or any other part of the Work so that they operate in accordance with their Specifications and Documentation; and The Contractor shall respond to the Court within four (4) hours after the Court reports a Technical Support Incident (such hours all occurring during Standard M&S Hours) to Contractor. DELIVERY, ACCEPTANCE, AND PAYMENT Delivery. Contractor shall deliver to the Court the Deliverables in accordance with this Agreement, including the Statement of Work. Unless otherwise specified by this Agreement, Contractor will deliver all goods purchased by the Court “Free on Board Destination Freight Prepaid” to the Court at the address and location specified by the Court. Title to all goods purchased by the Court vests in the Court upon payment of the applicable purchase price. Contractor will bear the risk of loss for any Work being delivered until received by the Court at the proper location. All shipments by Contractor or its Subcontractors must include packing sheets identifying: this Agreement number, the Court’s purchase order number, item number, quantity and unit of measure, part number and description of the goods shipped, and appropriate evidence of inspection, if required. Goods for different Agreements shall be listed on separate packing sheets.