Claim Dispute Resolution. In the event of any dispute or controversy with the City over any matter whatsoever, the Contractor shall not cause any delay or cessation in or of work, but shall proceed with the performance of the work in dispute. The Contractor shall retain any and all rights provided that pertain to the resolution of disputes and protests between the parties. The disputed work will be categorized as an "unresolved dispute" and payment, if any, shall be as later determined by mutual agreement or a court of law. The Contractor shall keep accurate, detailed records of all disputed work, claims and other disputed matters. All claims arising out of or related to the Agreement or this Project, and the consideration and payment of such claims, are subject to the Government Claims Act (Government Code Section 810 et seq.) with regard to filing claims. All such claims are also subject to Public Contract Code Section 9204 and Public Contract Code Section 20104 et seq. (Article 1.5), where applicable. This Contract hereby incorporates those provisions as though fully set forth herein. Thus, the Contractor or any Subcontractor must file a claim in accordance with the Government Claims Act as a prerequisite to filing a construction claim in compliance with Section 9204 and Article 1.5 (if applicable), and must then adhere to Article 1.5 and Section 9204, as applicable, pursuant to the definition of "claim" as individually defined therein.
Appears in 16 contracts
Samples: Minor Construction and Maintenance Services Agreement, Construction Contract, Construction Contract
Claim Dispute Resolution. In the event of any dispute or controversy with the City over any matter whatsoever, the Contractor shall not cause any delay or cessation in or of work, but shall proceed with the performance of the work in dispute. The Contractor shall retain any and all rights provided that pertain to the resolution of disputes and protests between the parties. The disputed work will be categorized as an "unresolved dispute" and payment, if any, shall be as later determined by mutual agreement or a court of law. The Contractor shall keep accurate, detailed records of all disputed work, claims and other disputed matters. All claims arising out of or related to the Agreement or this Project, and the consideration and payment of such claims, are subject to the Government Claims Act (Government Code Section 810 et seq.) with regard to filing claims. All such claims are also subject to Public Contract Code Section 9204 and Public Contract Code Section 20104 et seq. (Article 1.5), where applicable. This Contract hereby incorporates those provisions as though fully set forth herein. Thus, the Contractor or any Subcontractor must file a claim in accordance with the Government Claims Act as a prerequisite to filing a construction claim in compliance with Section 9204 and Article 1.5 (if applicable), and must then adhere to Article 1.5 and Section 9204, as applicable, pursuant to the definition of "claim" as individually defined therein.to
Appears in 1 contract
Samples: Minor Construction and Maintenance Services Agreement