RESPONDENT LIABILITY FOR DAMAGE TO GOVERNMENT PROPERTY The Respondent shall be liable for all damages to government-owned, leased, or occupied property and equipment caused by the Respondent and its employees, agents, subcontractors, and suppliers, including any delivery or cartage company, in connection with any performance pursuant to the Contract. The Respondent shall notify the City of Xxxxxx Procurement Manager in writing of any such damage within one (1) calendar day.
Uncontrollable Forces Tariff Provisions Section 14.1 of the CAISO Tariff shall be incorporated by reference into this Agreement except that all references in Section 14.1 of the CAISO Tariff to Market Participants shall be read as a reference to the Participating Generator and references to the CAISO Tariff shall be read as references to this Agreement.
Interruption of Services Tenant agrees that Landlord shall not be liable in damages, by abatement of Rent or otherwise, for failure to furnish or delay in furnishing any service, or for any diminution in the quality or quantity thereof, when such failure or delay or diminution is occasioned, in whole or in part, by repairs, renewals, or improvements, by any strike, lockout or other labor trouble, by inability to secure electricity, gas, water, or other fuel at the Building after reasonable effort so to do, by any accident or casualty whatsoever, by act or default of Tenant or other parties, or by any other cause beyond Landlord’s reasonable control; and such failures or delays or diminution (any such event, a “Service Failure”) shall never be deemed to constitute an eviction or disturbance of Tenant’s use and possession of the Premises or relieve Tenant from paying Rent or performing any of its obligations under this Lease. Notwithstanding the foregoing, if the Premises, or a material portion of the Premises, is made untenantable (that is, Tenant cannot conduct its business in such portion) or inaccessible for a period in excess of five (5) consecutive business days as a result of the Service Failure that has been caused by Landlord’s act or omission with respect to matters within Landlord’s control (“Controlled Service Failure”), then Tenant, as its sole remedy, shall be entitled to receive an abatement of Rent payable hereunder during the period beginning on the sixth (61 ) consecutive business day of the Controlled Service Failure and ending on the day the service has been restored. If the entire Premises has not been rendered untenantable or inaccessible by such a Controlled Service Failure, the amount of abatement that Tenant is entitled to receive by reason of such a Controlled Service Failure shall be prorated based upon the percentage of the Premises rendered untenantable or inaccessible and not used by Tenant. Notwithstanding the foregoing, business days during which the Premises or a material portion thereof are untenantable or inaccessible, or during which all or nearly all the Premises are unusable, by reason of a Service Failure which arises from a fire or other casualty which is covered by the provisions of ARTICLE 13 shall in no event be considered in determining whether Tenant is entitled to an abatement of Rent under this Section 8.03 (in such event the provisions of Section 13.01 shall govern Tenant’s rights). In no event shall Landlord be liable to Tenant for any loss or damage, including the theft of Tenant’s property, arising out of or in connection with the failure of any security services, personnel or equipment.
Liability for Acts or Omissions of Third Parties Neither BellSouth nor Mpower shall be liable for any act or omission of another telecommunications company providing a portion of the services provided under this Agreement.
Indemnity Consequential Damages and Insurance 18.1 Indemnity 18.1.1 Indemnified Party 18.1.2 Indemnifying Party 18.1.3 Indemnity Procedures 18.2 Consequential Damages 18.3 Insurance 18.3.1 18.3.2 18.3.3 18.3.4 18.3.5 18.3.6 18.3.7 18.3.8 18.3.9 18.3.10 18.3.11
Outages and Interruptions Outages.
Use of Interconnection Facilities by Third Parties 6551 Error! Hyperlink reference not valid.9.9.1 Purpose of Interconnection Facilities. 6551
Damages for delay by the Concessionaire In the event that (i) the Concessionaire does not procure fulfilment of any or all of the Conditions Precedent set forth in Clause 4.1.3 within a period of 180 (one hundred and eighty) days from the date of this Agreement, and (ii) the delay has not occurred as a result of failure to fulfil the obligations under Clause 4.1.2 or other breach of this Agreement by the Authority, or due to Force Majeure, the Concessionaire shall pay to the Authority Damages in an amount calculated at the rate of 0.2% (zero point two per cent) of the Performance Security for each day's delay until the fulfilment of such Conditions Precedent, subject to a maximum of 20% (twenty percent) of the Performance Security.
Negligent or Willful Damage Un- designated timber meeting Utilization Standards and un- necessarily damaged or negligently or willfully cut by Pur- chaser, if included by Contracting Officer.
Causes The contract may be terminated before the stated completion date by any of the following conditions.
