Completion on notice. The Lease must be completed within 3 working days after service of a notice to complete and the parties must complete and the parties must perform their other obligations under this agreement.
Completion on notice Sample Clauses
Related to Completion on notice
Termination on Notice Notwithstanding any other provision of this Agreement, either party may terminate this Agreement at any time by giving thirty (30) days written notice to the other party. Unless otherwise terminated as provided in this Agreement, this Agreement will continue in force until the Services provided for in this Agreement have been fully and completely performed.
Notice of Completion Promptly after the completion of the distribution of the Securities by the Underwriters, the Representatives shall deliver to the Company a notice in writing confirming the completion of the distribution (the “Notice of Completion”).
Substantial Completion The Tenant Improvements shall be deemed to be “Substantially Completed” on the date that (i) the Tenant Improvements are essentially and satisfactorily completed in accordance with the Final Plans to the extent that the Leased Premises may be occupied by Tenant for its Approved Use, subject only to completion of minor finishing, adjustment of equipment, and other minor construction aspects (“punch list items”) which do not, in the aggregate, cause interference (other than minor inconvenience) with the use and occupancy of the Leased Premises for the Approved Use, and (ii) a certificate of occupancy, whether conditional or final, has been issued by the proper governmental authority. Landlord shall give Tenant at least 30 days prior notice (written or oral) of Landlord’s reasonable estimate of the date of Substantial Completion of the Tenant Improvements. Tenant shall schedule with Landlord a mutually acceptable date, which will not be later than 3 business days after the date of Substantial Completion (but in no event earlier than the Landlord’s estimated date of Substantial Completion), for a walk-through inspection of the Leased Premises. In such walk-through, Landlord and Tenant will mutually and reasonably agree upon a punch list, and subject to Tenant Delay, Landlord will use reasonable efforts to cause such punch list work to be completed within 30 days after such walk-through. Landlord hereby warrants to Tenant, which warranty shall survive for one year following the date of Substantial Completion of the Tenant Improvements, that (a) the materials and equipment furnished by Landlord and Landlord’s contractors in the completion of the Tenant Improvements will be of good quality and new, and (b) such materials and equipment and the work of such contractors shall be free from defects not inherent in the quality required or permitted hereunder. This warranty shall exclude damages or defects caused by Tenant, its agents, employees or contractors, improper or insufficient maintenance, improper operation or normal wear and tear under normal usage. Landlord shall use diligent and good faith efforts to cause the Tenant Improvements for the Fifth Floor Premises to be Substantially Completed by November 1, 2018. Subject only to Force Majeure (as defined in §11 hereof) and Tenant Delay, and provided that Landlord, using good faith efforts, obtains all required construction permits for the Tenant Improvements (the “Construction Permits”) by not later than June 30, 2018, then in the event that Landlord fails to cause the Tenant Improvements for the Fifth Floor Premises to be Substantially Completed on or before December 1, 2018, (the “Fifth Floor Substantial Completion Date”), Tenant shall be entitled to a day-for-day credit of Base Rent due as of the Commencement Date, for each day after the Fifth Floor Substantial Completion Date that the Tenant Improvements for the Fifth Floor Premises are not Substantially Completed; provided, however, that, for every day of delay which results from a Tenant Delay or a Force Majeure, the Fifth Floor Substantial Completion Date shall be moved back on a day-for-day basis. Such day-for-day credit of Base Rent shall commence upon the Commencement Date and shall continue until applied in full; provided that at no time may Tenant offset more than 50% of the Base Rent amount due each month until such abatement has been completed. Landlord shall use diligent and good faith efforts to cause the Tenant Improvements for the Fourth Floor Premises to be Substantially Completed by February 1, 2019. Subject only to Force Majeure (as defined in §11 hereof) and Tenant Delay, and provided that Landlord, using good faith efforts, obtains all required construction permits for the Tenant Improvements (the “Construction Permits”) by not later than June 30, 2018, then in the event that Landlord fails to cause the Tenant Improvements for the Fourth Floor Premises to be Substantially Completed on or before March 1, 2019, (the “Fourth Floor Substantial Completion Date”), Tenant shall be entitled to a day-for-day credit of Base Rent due as of the Commencement Date, for each day after the Fourth Floor Substantial Completion Date that the Tenant Improvements for the Fourth Floor Premises are not Substantially Completed; provided, however, that, for every day of delay which results from a Tenant Delay or a Force Majeure, the Fourth Floor Substantial Completion Date shall be moved back on a day-for-day basis. Such day-for-day credit of Base Rent shall commence upon the June 1, 2019, and shall continue until applied in full; provided that at no time may Tenant offset more than 50% of the Base Rent amount due each month until such abatement has been completed. Subject only to Force Majeure and Tenant Delay, and provided that Landlord, using good faith efforts, obtains all required Construction Permits by not later than June 30, 2018, if the Tenant Improvements for the Leased Premises are not Substantially Completed on or before April 1, 2019 (“Outside Completion Date”), then Tenant shall have the one-time right by not later than 10 days after the Outside Completion Date to terminate this lease by delivering written notice to Landlord, which notice shall be hand delivered to 0000 Xxxx Xxxxx Xxxxx, Xxxxxxxx, Xxxx 00000, Attention: Xxxxxx X. Xxxxx, Xx., and upon hand delivery of such termination notice to said address, this lease shall be deemed null and void and the parties shall have no further rights or obligations hereunder, except those that specifically survive the expiration or earlier termination of this lease. Landlord and Tenant acknowledge and agree that Tenant’s damages as a result of Landlord’s failure to cause the Tenant Improvements for the Fifth Floor Premises to be Substantially Completed by not later than the Fifth Floor Substantial Completion Date or the Fourth Floor Premises to be Substantially Completed by not later than the Fourth Floor Substantial Completion Date are difficult to ascertain, that such amounts set forth above are a reasonable pre-estimate of Tenant’s probable loss as a result thereof and that such damages constitute reasonable liquidated damages for Tenant’s loss and not a penalty.
Events Requiring Notice The Company shall be required to give the notice described in this Section 8 upon one or more of the following events: (i) if the Company shall take a record of the holders of its Shares for the purpose of entitling them to receive a dividend or distribution payable otherwise than in cash, or a cash dividend or distribution payable otherwise than out of retained earnings, as indicated by the accounting treatment of such dividend or distribution on the books of the Company, (ii) the Company shall offer to all the holders of its Shares any additional shares of capital stock of the Company or securities convertible into or exchangeable for shares of capital stock of the Company, or any option, right or warrant to subscribe therefor, or (iii) a dissolution, liquidation or winding up of the Company (other than in connection with a consolidation or share reconstruction or amalgamation) or a sale of all or substantially all of its property, assets and business shall be proposed.
Notice to Allow Conversion by Xxxxxx If (A) the Company shall declare a dividend (or any other distribution in whatever form) on the Common Stock, (B) the Company shall declare a special nonrecurring cash dividend on or a redemption of the Common Stock, (C) the Company shall authorize the granting to all holders of the Common Stock of rights or warrants to subscribe for or purchase any shares of capital stock of any class or of any rights, (D) the approval of any stockholders of the Company shall be required in connection with any reclassification of the Common Stock, any consolidation or merger to which the Company is a party, any sale or transfer of all or substantially all of the assets of the Company, or any compulsory share exchange whereby the Common Stock is converted into other securities, cash or property or (E) the Company shall authorize the voluntary or involuntary dissolution, liquidation or winding up of the affairs of the Company, then, in each case, the Company shall cause to be filed at each office or agency maintained for the purpose of conversion of this Note, and shall cause to be delivered to the Holder at its last address as it shall appear upon the Note Register, at least twenty (20) calendar days prior to the applicable record or effective date hereinafter specified, a notice stating (x) the date on which a record is to be taken for the purpose of such dividend, distribution, redemption, rights or warrants, or if a record is not to be taken, the date as of which the holders of the Common Stock of record to be entitled to such dividend, distributions, redemption, rights or warrants are to be determined or (y) the date on which such reclassification, consolidation, merger, sale, transfer or share exchange is expected to become effective or close, and the date as of which it is expected that holders of the Common Stock of record shall be entitled to exchange their shares of the Common Stock for securities, cash or other property deliverable upon such reclassification, consolidation, merger, sale, transfer or share exchange, provided that the failure to deliver such notice or any defect therein or in the delivery thereof shall not affect the validity of the corporate action required to be specified in such notice. To the extent that any notice provided hereunder constitutes, or contains, material, non-public information regarding the Company or any of the Subsidiaries, the Company shall simultaneously file such notice with the Commission pursuant to a Current Report on Form 8-K. The Holder shall remain entitled to convert this Note during the 20-day period commencing on the date of such notice through the effective date of the event triggering such notice except as may otherwise be expressly set forth herein.
Events Requiring Notice to the Representative The Company shall use its best efforts to cause the Registration Statement to remain effective with a current prospectus for at least nine (9) months after the Applicable Time, and shall notify the Representative immediately and confirm the notice in writing: (i) of the issuance by the Commission of any stop order or of the initiation, or the threatening, of any proceeding for that purpose; (ii) of the issuance by any state securities commission of any proceedings for the suspension of the qualification of the Public Securities for offering or sale in any jurisdiction or of the initiation, or the threatening, of any proceeding for that purpose; (iii) of the mailing and delivery to the Commission for filing of any amendment or supplement to the Registration Statement or Prospectus; (iv) of the receipt of any comments or request for any additional information from the Commission; and (v) of the happening of any event during the period described in this Section 3.5 that, in the judgment of the Company, makes any statement of a material fact made in the Registration Statement, the Pricing Disclosure Package or the Prospectus untrue or that requires the making of any changes in (a) the Registration Statement in order to make the statements therein not misleading, or (b) in the Pricing Disclosure Package or the Prospectus in order to make the statements therein, in light of the circumstances under which they were made, not misleading. If the Commission or any state securities commission shall enter a stop order or suspend such qualification at any time, the Company shall make every reasonable effort to obtain promptly the lifting of such order.
Completion of Project The Project shall have been completed per the Plans and Specifications and a Completion Certificate shall have been obtained;
Completion of Repairs Borrower will commence any Repairs as soon as practicable after the date of this Loan Agreement and will diligently proceed with and complete such Repairs on or before the Completion Date. All Repairs and Capital Replacements will be completed in a good and workmanlike manner, with suitable materials, and in accordance with good building practices and all applicable laws, ordinances, rules, regulations, building setback lines and restrictions applicable to the Mortgaged Property. Borrower agrees to cause the replacement of any material or work that is defective, unworkmanlike or that does not comply with the requirements of this Loan Agreement, as determined by Lender.
Satisfactory Completion of Due Diligence The Company and the Shareholders shall have completed their legal, accounting and business due diligence of the Parent and the results thereof shall be satisfactory to the Company and the Shareholders in their sole and absolute discretion.
Notice to Allow Conversion by Hxxxxx If (A) Borrower shall declare a dividend (or any other distribution in whatever form) on the Common Stock, (B) Borrower shall declare a special nonrecurring cash dividend on or a redemption of the Common Stock, (C) Borrower shall authorize the granting to all holders of the Common Stock of rights or warrants to subscribe for or purchase any shares of capital stock of any class or of any rights, (D) the approval of any stockholders of Borrower shall be required in connection with any reclassification of the Common Stock, any consolidation or merger to which Borrower is a party, any sale or transfer of all or substantially all of the assets of Borrower, or any compulsory share exchange whereby the Common Stock is converted into other securities, cash or property or (E) Borrower shall authorize the voluntary or involuntary dissolution, liquidation or winding up of the affairs of Borrower, then, in each case, Borrower shall cause to be filed at each office or agency maintained for the purpose of conversion of this Note, and shall cause to be delivered to the Holder at its last address as it shall appear upon the Note Register, at least twenty (20) calendar days prior to the applicable record or effective date hereinafter specified, a notice stating (x) the date on which a record is to be taken for the purpose of such dividend, distribution, redemption, rights or warrants, or if a record is not to be taken, the date as of which the holders of the Common Stock of record to be entitled to such dividend, distributions, redemption, rights or warrants are to be determined or (y) the date on which such reclassification, consolidation, merger, sale, transfer or share exchange is expected to become effective or close, and the date as of which it is expected that holders of the Common Stock of record shall be entitled to exchange their shares of the Common Stock for securities, cash or other property deliverable upon such reclassification, consolidation, merger, sale, transfer or share exchange, provided that the failure to deliver such notice or any defect therein or in the delivery thereof shall not affect the validity of the corporate action required to be specified in such notice. To the extent that any notice provided hereunder constitutes, or contains, material, non-public information regarding Borrower or any of the Subsidiaries, Borrower shall simultaneously file such notice with the Commission pursuant to a Current Report on Form 8-K. The Holder shall remain entitled to convert this Note during the 20-day period commencing on the date of such notice through the effective date of the event triggering such notice except as may otherwise be expressly set forth herein.
