Condition at Delivery Sample Clauses

Condition at Delivery. LESSOR has advised LESSEE that at Delivery the Aircraft will be as set forth in Exhibit A and in the condition set forth in Exhibit B. To the extent that at Delivery there are non-substantial or minor deviations from the condition set forth in Exhibit B which do not affect the airworthiness of the Aircraft, LESSEE will nonetheless accept the Aircraft and LESSEE and LESSOR will adjust the return conditions of the Aircraft set forth in Article 23 accordingly.
Sample 1Sample 2See All (4)
Condition at Delivery. Landlord warrants and will cause all Building systems (including, without limitation, heating, air conditioning, plumbing, fire sprinkler, lighting and electrical systems and utilities), as well as the Building's structural components (including, without limitation, the roof, roof membrane, foundation, structural and exterior walls) to be in good working order and condition at the time the Premises are delivered to Tenant. Except as aforesaid, Tenant shall receive the Premises broom clean in their "as is" condition as of the date of this Lease without any demolition or other work having been done. Tenant agrees to accept possession of the Premises in such condition, and Tenant shall notify Landlord of any defects in the condition of the Premises within thirty (30) days after Tenant takes possession of the Premises. By so accepting the Premises and thereafter occupying the Premises for such thirty (30) days without notifying Landlord of any defects. Tenant shall be deemed to have accepted the same and to have acknowledged that the Premises fully comply with Landlord's obligations under this Section. Upon receipt of any such notification, Landlord shall promptly and diligently repair such defects at Landlord's sole cost and expense. Landlord makes no representation or warranty as to the nature, quality, or suitability for Tenant's business of the Tenant Improvements, the Project, the Building, or the Premises, and Tenant shall have no rights against Landlord by reason of such matters or any claimed deficiencies therein.
Sample 1
Condition at Delivery. In addition to the disclaimers in Clause 18, Lessor has advised Lessee that at Delivery the Aircraft will be substantially and materially in the condition set forth in Schedule 4, provided that this confirmation expires as at Delivery.
Sample 1Sample 2
Condition at Delivery. Lessor has advised Lessee that at Delivery the Aircraft will be in the condition set forth in Schedule 1 (“Delivery Condition”). To the extent that at Delivery there are non-substantial or minor deviations from the condition set forth in Schedule 1 which do not affect the airworthiness of the Aircraft, Lessee will nonetheless accept the Aircraft and Lessee and Lessor will adjust the return conditions of the Aircraft set forth in Schedule 5 accordingly, if necessary.
Sample 1Sample 2
Condition at Delivery. When delivery of the Vessel is tendered to Owner under this Agreement it shall conform to the requirements of the Contract Documents and the terms of this Agreement and be free and clear of all liens and encumbrances, in a fully cleaned condition and ready for Owner to provision and depart. All required outfit shall be properly stowed, and all tanks and bilges and other spaces shall be clean and thoroughly cleared of dunnage, scrap and refuse. On and from delivery Owner shall provide the Vessel’s master, crew, fuel, oils and all necessary supplies.
Sample 1Sample 2
Condition at Delivery. Landlord will cause all Building --------------------- systems to be in good working order and condition at the time the Premises are delivered to Tenant. Except as aforesaid, Tenant shall receive the Premises broom clean in their "as is" condition as of the date of this Lease without any demolition or other work having been done and subject to reasonable wear and tear arising from any current tenant's or occupant's occupancy and moving out of the Premises. Tenant agrees to accept possession of the Premises in such condition, and Tenant shall notify Landlord of any defects in the condition of the Premises within thirty (30) days after Tenant takes possession of the Premises. By so accepting the Premises and thereafter occupying the Premises for such thirty (30) days without notifying Landlord of any defects, Tenant shall be deemed to have accepted the same and to have acknowledged that the Premises fully comply with Landlord's obligations under this Section.
Sample 1
Condition at Delivery. LESSOR has advised LESSEE that at Delivery the Aircraft will be as set forth in Exhibit A and in the condition set forth in Exhibit B. To the extent that at Delivery there are non substantial or minor deviations from the condition set forth in Exhibit B which do not affect the airworthiness of the Aircraft, LESSEE will nonetheless accept the Aircraft subject to such deviations and LESSEE and LESSOR will mutually agree to either (i) adjust the return conditions of the Aircraft set forth in Article 23 accordingly or (ii) arrange for LESSOR to reimburse LESSEE for the reasonable cost of rectification of such deviations.
Sample 1

Related to Condition at Delivery

  • Document Delivery The Trust has delivered to Forum copies of (i) the Trust's Trust Instrument and Bylaws (collectively, as amended from time to time, "Organic Documents"), (ii) the Trust's Registration Statement and all amendments thereto filed with the U.S. Securities and Exchange Commission ("SEC") pursuant to the Securities Act of 1933, as amended (the "Securities Act"), or the Investment Company Act of 1940, as amended ("1940 Act")(the "Registration Statement"), (iii) the Trust's current Prospectus and Statement of Additional Information of each Fund (collectively, as currently in effect and as amended or supplemented, the "Prospectus"), (iv) each current plan of distribution or similar document adopted by the Trust under Rule 12b-1 under the 1940 Act ("Plan") and each current shareholder service plan or similar document adopted by the Trust ("Service Plan"), and (v) all procedures adopted by the Trust with respect to the Funds (i.e., repurchase agreement procedures), and shall promptly furnish Forum with all amendments of or supplements to the foregoing. The Trust shall deliver to Forum a certified copy of the resolution of the Board of Trustees of the Trust (the "Board") appointing Forum and authorizing the execution and delivery of this Agreement.

  • Delivery Notice Notice of the Aircraft's Delivery Date, given by the Lessee as provided in Section 3.01 of the Participation Agreement and including any notice with respect to a postponed Delivery Date given by the Lessee pursuant to Section 3.05(c) of the Participation Agreement.

  • Notice to Purchaser DO NOT SIGN THIS CONTRACT UNTIL YOU READ IT OR IF IT CONTAINS BLANK SPACES.

  • Project Delivery Contractor shall construct the Project in accordance with the Contract Documents, and Contractor shall deliver the Project completed in accordance with the Contract Documents, substantially free from defects, and within the Contract Time.

  • PRICE/DELIVERY Price(s) bid must be the price(s) for new goods, unless otherwise specified. Any bids containing modifying or “escalator” clauses will not be considered unless specifically requested in the bid specifications.

  • Response to Notice Within ten business days of receiving the Claim Notice, the Respondent must notify the Claimant of its representative to negotiate the dispute.

  • PRODUCT DELIVERY Delivery must be made as ordered to the address specified on the Purchase Order and in accordance with the terms of the Contract or Contract Award Notice. Unless otherwise specified in the Bid Documents, delivery shall be made within thirty calendar days after receipt of a Purchase Order by the Contractor. The decision of the Commissioner as to compliance with delivery terms shall be final. The burden of proof for delay in receipt of Purchase Order shall rest with the Contractor. In all instances of a potential or actual delay in delivery, the Contractor shall immediately notify the Commissioner and the Authorized User, and confirm in writing the explanation of the delay, and take appropriate action to avoid any subsequent late deliveries. Any extension of time for delivery must be requested in writing by the Contractor and approved in writing by the Authorized User. Failure to meet such delivery time schedule may be grounds for cancellation of the order or, in the Commissioner’s discretion, the Contract.

  • Non-Compliant Delivery Overshipments and/or early deliveries may be returned at Supplier’s sole expense, or DXC may delay processing the early delivery invoice until the Delivery Date.

  • Physical Delivery All notices must be in writing, except as provided in § 21.2. Any document, including a signed 234 document or notice, delivered to the other party to this Buyer Listing Contract, is effective upon physical receipt. Delivery to 235 Buyer is effective when physically received by Xxxxx, any signator on behalf of Xxxxx, any named individual of Buyer or 236 representative of Buyer.

  • SPECIAL DELIVERY INSTRUCTIONS All shipments will be FOB destination (as specified on Ordering Entity Purchase Order).