Consequential Effects Sample Clauses

Consequential Effects. (a) The following provisions shall apply to the Occupied Part as from the Date of Practical Completion in respect of the Occupied Part until the completion of the remainder of the Works: (i) Release to the Contractor in the next Interim Certificate after the date of the Employer’s possession of the Occupied Part of a proportion of the first half of the Retention Monies under Clause 42 in respect of the Occupied Part, based upon the total value of the Occupied Part relative to the value of the whole of the Works. (ii) The provisions of Clause 27 (Defects After Completion) shall apply as if the Occupied Part was the subject of a separate and distinct contract between the Employer and the Contractor (iii) The Contractor may reduce the value of the Works insured under Clause 38A (if applicable) by the total value of the Occupied Part as from the Date of Practical Completion of the Occupied Part, from which date the Contractor's obligations under Clauses 34 and 38A (if applicable) shall cease in relation to the Occupied Part (except for any outstanding works in the Occupied Part until such time as their completion by the Contractor has been certified by the Superintending Officer.) (iv) The rate of Liquidated Damages for delay pursuant to Clause 26 shall be reduced proportionately based upon the total value of the Occupied Part relative to the total value of the whole of the Works. (v) On the expiry of the Defects Liability Period of the Occupied Part or upon the issue of the Certificate of Making Good Defects of the Occupied Part, whichever is the later, the Contractor shall be paid the second half of the Retention Monies calculated on the same basis as the first half. The Limit of Retention under Clause 42.3 shall be reduced by the amount of Retention Monies so released under this Clause 23. (b) For the avoidance of doubt, nothing contained in sub-clause 23.2(a) shall entitle the Contractor to the release of the whole or any part of the Performance Security Deposit deposited by him pursuant to Option Module F (if applicable). The Performance Security Deposit (if applicable) shall be released or refunded only upon the issue of the Certificate of Practical Completion for the whole of the Works or in respect of the last section of the Works, as the case may be.
Sample 1
AutoNDA by SimpleDocs

Related to Consequential Effects

  • No Consequential or Punitive Damages Neither Party hereto (or any of their respective Affiliates) shall, under any circumstance, be liable to the other Party (or its Affiliates) for any consequential, exemplary, special, indirect, incidental or punitive damages claimed by such other Party under the terms of or due to any breach of this Agreement, including, but not limited to, loss of revenue or income, cost of capital, or loss of business reputation or opportunity.

  • Consequential Damages Neither party to this Agreement shall be liable to the other party for special, indirect or consequential damages under any provision of this Agreement or for any special, indirect or consequential damages arising out of any act or failure to act hereunder.

  • No Consequential Damages Other than the Liquidated Damages heretofore described and the indemnity obligations set forth in Article 18.1, in no event shall any Party be liable under any provision of this Agreement for any losses, damages, costs or expenses for any special, indirect, incidental, consequential, or punitive damages, including but not limited to loss of profit or revenue, loss of the use of equipment, cost of capital, cost of temporary equipment or services, whether based in whole or in part in contract, in tort, including negligence, strict liability, or any other theory of liability; provided, however, that damages for which a Party may be liable to another Party under separate agreement will not be considered to be special, indirect, incidental, or consequential damages hereunder.

  • Limitation on Consequential Damages NEITHER PARTY WILL HAVE ANY OBLIGATION OR LIABILITY (WHETHER IN CONTRACT, WARRANTY, TORT (INCLUDING NEGLIGENCE) OR OTHERWISE, AND NOTWITHSTANDING ANY FAULT, NEGLIGENCE (WHETHER ACTIVE, PASSIVE OR IMPUTED), REPRESENTATION, STRICT LIABILITY OR PRODUCT LIABILITY), FOR COVER OR FOR ANY INCIDENTAL, INDIRECT, CONSEQUENTIAL, MULTIPLIED, PUNITIVE, SPECIAL, OR EXEMPLARY DAMAGES OR LOSS OF REVENUE, PROFIT, SAVINGS OR BUSINESS ARISING FROM OR OTHERWISE RELATED TO THIS AGREEMENT, EVEN IF A PARTY OR ITS REPRESENTATIVES HAVE BEEN ADVISED OF THE POSSIBILITY OF SUCH DAMAGES. THE PARTIES ACKNOWLEDGE THAT THESE EXCLUSIONS OF POTENTIAL DAMAGES WERE AN ESSENTIAL ELEMENT IN SETTING CONSIDERATION UNDER THIS AGREEMENT.

  • Consequential Losses Except as otherwise specifically provided herein, neither Party shall be liable to the other Party for any indirect, incidental or consequential loss or damages irrespective of the causes, thereof including fault or negligence.

  • Limitation of Consequential Damages EXCEPT FOR (A) THIRD PARTY CLAIMS THAT ARE SUBJECT TO INDEMNIFICATION UNDER THIS ARTICLE 10, (B) CLAIMS ARISING OUT OF A PARTY’S WILLFUL MISCONDUCT OR FRAUD UNDER THIS AGREEMENT, (C) A PARTY’S BREACH OF ARTICLE 4, (D) NOVARTIS’ BREACH OF SECTION 6.5, OR (E) CLAIMS ARISING OUT OF A PARTY’S BREACH OF ITS CONFIDENTIALITY OBLIGATIONS UNDER THIS AGREEMENT, NEITHER PARTY NOR ANY OF ITS AFFILIATES WILL BE LIABLE TO THE OTHER PARTY TO THIS AGREEMENT OR ITS AFFILIATES FOR ANY INCIDENTAL, CONSEQUENTIAL, SPECIAL, PUNITIVE OR OTHER INDIRECT DAMAGES OR LOST OR IMPUTED PROFITS OR ROYALTIES, LOST DATA OR COST OF PROCUREMENT OF SUBSTITUTE GOODS OR SERVICES, WHETHER LIABILITY IS ASSERTED IN CONTRACT, TORT (INCLUDING NEGLIGENCE AND STRICT PRODUCT LIABILITY), INDEMNITY OR CONTRIBUTION, AND IRRESPECTIVE OF WHETHER THAT PARTY OR ANY REPRESENTATIVE OF THAT PARTY HAS BEEN ADVISED OF, OR OTHERWISE MIGHT HAVE ANTICIPATED THE POSSIBILITY OF, ANY SUCH LOSS OR DAMAGE.

  • Consequential Loss Notwithstanding anything contained in this Agreement, neither Party shall be liable to the other Party for any indirect, special, consequential, punitive, and/or exemplary damages or losses arising from any act or omission by that Party relating to this Agreement and each Party (the “Indemnifying Party”) shall defend, indemnify and hold the other Party (the “Indemnified Party”) harmless in respect of any and all such indirect, special, consequential, punitive, and/or exemplary damages or losses suffered or incurred by the Indemnifying Party (provided that nothing in this Clause 16 shall relieve any Party from any express obligation under this Agreement to make any payment to another).

  • Exclusion of Consequential Damages ‌ Notwithstanding anything contained herein to the contrary, neither Party will be liable under this Agreement or under any cause of action relating to the subject matter of this Agreement for any special, indirect, incidental, punitive, exemplary or consequential damages, including loss of profits, loss of use of any property or claims of customers or contractors of the Parties for any such damages.

  • Punitive Damages The Administrative Agent, the Lenders and the Borrower hereby agree that no such Person shall have a remedy of punitive or exemplary damages against any other party to a Loan Document and each such Person hereby waives any right or claim to punitive or exemplary damages that they may now have or may arise in the future in connection with any Dispute, whether such Dispute is resolved through arbitration or judicially.

  • Waiver of Consequential Damages To the fullest extent permitted by applicable Law, the Borrower shall not assert, and hereby waives, any claim against any Indemnitee, on any theory of liability, for special, indirect, consequential or punitive damages (as opposed to direct or actual damages) arising out of, in connection with, or as a result of, this Agreement, any other Loan Document, the Related Documents or any agreement or instrument contemplated hereby or thereby, the transactions contemplated hereby or thereby, any Term Loan or the use of the proceeds thereof. No Indemnitee referred to in subsection (b) above shall be liable for any damages arising from the use by unintended recipients of any information or other materials distributed by it through telecommunications, electronic or other information transmission systems in connection with this Agreement or the other Loan Documents, the Related Documents or the transactions contemplated hereby or thereby other than for direct or actual damages resulting from the gross negligence or willful misconduct of such Indemnitee as determined by a final and nonappealable judgment of a court of competent jurisdiction.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!