Constructing Unit 14s Improvement Sample Clauses

Open Split View

Download

Share

Cite

Constructing Unit 14s Improvement 

Sample 1

Save

Copy

Related to Constructing Unit 14s Improvement

• Needs Improvement the Educator’s performance on a standard or overall is below the requirements of a standard or overall, but is not considered to be unsatisfactory at this time. Improvement is necessary and expected.

• School Improvement The parties do hereby mutually agree that the school improvement process currently in effect will continue. Any plan developed by the committees shall not be in conflict with the master agreement or board policy.

• Initial Improvements (a) On the Commencement Date, Tenant shall accept the Premises in its “as is” condition. All improvements, alterations and betterments (an “Alteration”) shall be performed by Tenant at Tenant’s expense in accordance with the terms of this Article 5. (b) Tenant may improve the Premises for Tenant’s initial occupancy in accordance with detailed specifications and working drawings to be prepared by Tenant’s engineers and architects. The detailed specifications and working drawings are hereinafter referred to as “Tenant’s Plans”, and the work shown by the Tenant’s Plans is hereinafter referred to as “Tenant’s Initial Improvements”. Tenant’s Initial Improvements shall include, and Landlord shall have no liability to tenant for not performing, the work specified on Exhibit H. (c) Tenant shall proceed forthwith to cause Tenant’s Plans to be prepared by an architect licensed as such in the State of New York. Tenant’s Plans, including structural and mechanical drawings and specifications, shall be prepared at Tenant’s sole cost and expense. Tenant shall submit five (5) sets of Tenant’s Plans and two (2) CAD discs which shall contain such Tenant’s Plans in CAD format to Landlord for Landlord’s approval. Landlord agrees to review Tenant’s Plans and to approve the same or make written exceptions thereto within fifteen (15) Business Days from the date of the submission of the plans. Landlord agrees not to unreasonably withhold or delay its approval of Tenant’s Plans, and failure by Landlord to provide the written exceptions within the fifteen (15) Business Day period aforesaid shall be deemed approval of Tenant’s Plans; provided, however, that five (5) Business Days prior to the expiration of such fifteen (15) Business Day period, Tenant shall send a second notice to Landlord with the phrase “FAILURE TO APPROVE OR DISAPPROVE TENANT’S PLANS WITHIN FIVE (5) BUSINESS DAYS AFTER THE DATE HEREOF SHALL RESULT IN THE DEEMED APPROVAL OF TENANT’S PLANS” in bold lettering at the top of such notice. If Landlord disapproves Tenant’s Plans, Tenant shall revise them and re-submit them to Landlord for approval. Any disapproval given by Landlord shall be accompanied by a statement in reasonable detail of the reasons for such disapproval, itemizing those portions of the plans so disapproved. Landlord shall advise Tenant within fifteen (15) Business Days following receipt of Tenant’s revised plans of Landlord’s approval or disapproval of the revised plans or portions thereof, and shall set forth its reasons for any such further disapproval in writing and in reasonable detail. If Landlord fails to approve or disapprove such revised plans within such fifteen (15) Business Day period, Landlord shall be deemed to have approved such revised plans or such portions thereof; provided, however, that five (5) Business Days prior to the expiration of such fifteen (15) Business Day period, Tenant shall send a second notice to Landlord with the phrase “FAILURE TO APPROVE OR DISAPPROVE TENANT’S PLANS, AS REVISED, WITHIN FIVE (5) BUSINESS DAYS AFTER THE DATE HEREOF SHALL RESULT IN THE DEEMED APPROVAL OF TENANT’S PLANS, AS REVISED” in bold lettering at the top of such notice. Any dispute regarding the reasonableness of Landlord’s withholding of its consent to Tenant’s Plans shall be submitted to expedited arbitration pursuant to Section 9.19 hereof. Upon approval by Landlord of Tenant’s Plans, Tenant shall submit the same to the New York City Department of Buildings for approval and for issuance of a building permit to perform the Improvements. Landlord agrees, at Tenant’s cost and expense, to reasonably cooperate with Tenant and Tenant’s independent licensed architect and engineer in providing information needed for the preparation of Tenant’s Plans, the application for a building permit and all other permits required for the Improvements, and to promptly execute all documents reasonably necessary to be signed by Landlord. (d) Tenant agrees to hire a reputable general contractor, construction manager or subcontractors and materialmen (hereinafter “Contractor(s)”) to be approved by Landlord such approval not to be unreasonably withheld or delayed (other than with respect to Contractors performing connections to any Building systems which Contractors shall be those designated by Landlord provided such Contractors shall perform such work at market prices). For purposes of Tenant’s Initial Improvements, Xxxxx, Xxxx & Xxxxxx and Xxxxxx Xxxxxxxx Consulting Engineers are deemed approved by Landlord. Tenant shall cause its Contractor(s) to perform Tenant’s Initial Improvements in a good and workmanlike manner in accordance with (x) the approved Tenant’s Plans and any material amendments or additions thereto approved by Tenant and Landlord and all municipal authorities having jurisdiction; provided, however, that, with respect to any subsequent amendments, additions, change orders or modifications after Landlord’s approval of Tenant’s Plans, Landlord shall approve or disapprove of such changes within fifteen (15) Business Days of the receipt of such changes from Tenant and (y) all provisions of Laws and any and all permits and other requirements specified by any ordinance, law or public regulation. If Landlord fails to approve or disapprove such subsequent amendments, additions, change orders or modifications within such fifteen (15) Business Day period, Landlord shall be deemed to have approved such subsequent amendments, additions, change orders or modifications or such portions thereof; provided, however, that five (5) Business Days prior to the expiration of such fifteen (15) Business Day period, Tenant shall send a second notice to Landlord with the phrase “FAILURE TO APPROVE OR DISAPPROVE TENANT’S PLANS, AS REVISED, WITHIN FIVE (5) BUSINESS DAYS AFTER THE DATE HEREOF SHALL RESULT IN THE DEEMED APPROVAL OF TENANT’S PLANS, AS REVISED” in bold lettering at the top of such notice. Tenant shall cause the Contractor(s) to obtain and maintain throughout the work, Workers’ Compensation Insurance and New York State Disability Insurance in the amounts required under any applicable Laws and comprehensive general liability insurance, including contractual liability coverage, in an amount of not less than $2 million combined single limit for bodily injury or death for any one occurrence, and for property damage, plus a $10 million umbrella policy; provided, however, that any subcontractor or materialman shall only be required to carry such liability insurance as is being carried by prudent subcontractors or materialmen within such trade at the time such subcontractor or materialman is being employed by Tenant or its Contractors. The liability coverage shall name Landlord and Overlandlord as additional insured parties, and Tenant shall deliver to Landlord proper certificates of insurance confirming the coverages described above prior to commencement of Tenant’s Initial Improvements. If Tenant acts as its own General Contractor or Construction Manager, Tenant shall obtain and maintain such insurance. All Contractor(s) shall be members of a union affiliated with the building trades in the City of New York that has jurisdiction over the Building and Tenant’s Initial Improvements. Tenant shall pay Landlord, within thirty (30) days after being billed therefor, the actual out of pocket fees and disbursements paid by Landlord to architects, engineers and other technical advisors, other than the regular staff of Landlord for reviewing Tenant’s Plans, provided such fees are commercially reasonable. (e) Landlord shall pay to Tenant pursuant to Section 5.01(f) hereof Construction Costs and Softs Costs (as hereinafter defined) in an amount (the “Construction Allowance”) which shall not exceed $1,638,850.00, provided, however, that payments in respect of Soft Costs shall not in the aggregate exceed fifteen percent (15%) of the Construction Allowance. Tenant shall pay from its own funds, and Landlord shall have no obligation with respect to, (y) any and all costs which are not Construction Costs or Softs Costs and/or (z) any and all Construction Costs in excess of the Construction Allowance or Soft Costs in excess of the limitation described in the foregoing sentence. As used in this Lease, the term “Construction Costs” means amounts actually incurred and paid by Tenant and Tenant’s contractors, subcontractors and vendors in connection with Tenant’s Initial Improvements solely for the documented, bona fide cost of (i) construction supplies and materials which are physically installed in and made a part of the Premises, including the documented, bona fide costs of carpeting, wall coverings, partitions, any electric meter or submeter, and permit fees, and (ii) labor actually performed within the Premises. The term “Soft Costs” means amounts actually incurred and paid by Tenant in connection with Tenant’s Initial Improvements solely for the documented, bona fide cost of accounting, legal, architectural, engineering and other professional or consulting services.

• Project 3.01. The Recipient declares its commitment to the objectives of the Project. To this end, the Recipient shall carry out the Project in accordance with the provisions of Article IV of the General Conditions.

• Construction of the Project Highway (i) The Contractor shall construct the Project Highway as specified in Schedule- B and Schedule-C, and in conformity with the Specifications and Standards set forth in Schedule-D. The Contractor shall be responsible for the correct positioning of all parts of the Works, and shall rectify any error in the positions, levels, dimensions or alignment of the Works. The [650th (six hundred and fiftieth) day] from the Appointed Date shall be the scheduled completion date (the “Scheduled Completion Date”) and the Contractor agrees and undertakes that the construction shall be completed on or before the Scheduled Completion Date, including any extension thereof. (ii) The Contractor shall construct the Project Highway in accordance with the Project Completion Schedule set forth in Schedule-J. In the event that the Contractor fails to achieve any Project Milestone or the Scheduled Completion Date within a period of 30 (thirty) days from the date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, it shall pay Damages to the Authority of a sum calculated at the rate of 0.05% (zero point zero five percent) of the Contract Price for delay of each day reckoned from the date specified in Schedule –J and until such Project Milestone is achieved or the Project Highway is completed; provided that if the period for any or all Project Milestones or the Scheduled Completion Date is extended in accordance with the provisions of this Agreement, the dates set forth in Schedule-J shall be deemed to be modified accordingly and the provisions of this Agreement shall apply as if Schedule-J has been amended as above; provided further that in the event the Project Highway is completed within or before the Scheduled Completion Date including any Time Extension, applicable for that work or section, the Damages paid under this Clause 10.3 (ii) shall be refunded by the Authority to the Contractor, but without any interest thereon. The Parties agree that for determining achievement or delays in completion of the Project Milestones or the Project on the due date, the works affected due to delay in providing the site for which time extension has been granted beyond the Scheduled Completion Date will be excluded. For example on the due date to achieve the Project Milestone-I (i.e., Stage Payments of 10% (ten percent) of Contract Price on 180th (one hundred and eighty) day from the Appointed Date), if 5% (five percent) of the project length corresponding to the Project Milestone-I is not handed over or lately handed over resulting in the extension of completion of this 5% (five percent) length beyond Scheduled Completion Date, Stage Payment of 10% X 0.95 = 9.5% only is to be achieved by 180th (one hundred and eighty) day. For the avoidance of doubt, it is agreed that recovery of Damages under this Clause 10.3 (ii) shall be without prejudice to the rights of the Authority under this Agreement including the right of Termination thereof. The Partiesfurther agree that Time Extension hereunder shall only be reckoned for and in respect of the affected Works as specified in Clause 10.5 (ii). (iii) The Authority shall notify the Contractor of its decision to impose Damages in pursuance with the provisions of this Clause 10.3. Provided that no deduction on account of Damages shall be effected by the Authority without notifying the Contractor of its decision to impose the Damages, and taking into consideration the representation, if any, made by the Contractor within 20 (twenty) days of such notice. The Parties expressly agree that the total amount of Damages under Clause 10.3 (ii) shall not exceed 10% (ten percent) of the Contract Price. If the damages exceed 10% (ten percent) of the Contract Price, the Contractor shall be deemed to be in default of this agreement having no cure and the Authority shall be entitled to terminate this Agreement by issuing a Termination Notice in accordance with the provisions of Clause 23.1 (ii). (iv) In the event that the Contractor fails to achieve the Project Completion within a period of 90 (ninety) days from the Schedule Completion Date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, the contractor shall be deemed to be ineligible for bidding any future projects of the Authority, both as the sole party or as one of the parties of Joint Venture/ Consortium during the period from Scheduled Completion Date to issuance of Completion Certificate. This restriction is applicable if the contract value of the delayed project is not less than Rs. 300 Crore.

• ALTERATIONS & IMPROVEMENTS Tenant shall not make any alterations, additions or improvements or do any type of construction to the Property without first obtaining Landlord's written consent. Unless prior written agreement is reached between Tenant and Landlord, any such alterations, additions, improvements or construction shall become part of the Property and shall remain at the expiration of Tenant's Lease term. If Landlord approves of alterations, additions, improvements or construction in writing and Tenant intends to use contractors to undertake such work, the contractors must first be approved in writing by Landlord. Tenant must also place any funds to cover the amount of any alterations, additions, improvements or construction in an escrow account approved by Landlord before the commencement of the work. Landlord shall designate the times and manner of the work being done, exclusively.

• Premises Building Project and Common Areas 1.1 Premises, Building, Project and Common Areas.

• Lessee Improvements Lessor and Lessee shall meet to discuss the design and construction of those improvements desired by Lessee, such improvements including, but not being limited to, M.E.P. systems, computer flooring, interior walls, wall coverings, window treatments, and floor coverings for the entire 84,518 square feet of the Leased Premises (the “Lessee Improvements”). Lessee shall prepare final plans and specifications for the Lessee Improvements and other construction documents for Lessor’s approval within five (5) days from receipt thereof and Lessor shall have five (5) days to review and approve such final plans and specifications. In the event such five (5) day review period expires with no response from Lessor, such plans shall be deemed approved. However, in no event shall actual or deemed approval of the final plans and specifications constitute approval for accuracy, completeness, quality or effectiveness of design, compliance with applicable laws or otherwise. Lessee shall not be required to remove the Lessee Improvements designed for general office use, i.e., drywall, electrical, plumbing, carpeting nor the cafeteria, upon expiration or termination of this Lease. The approved final plans and specifications for the Lessee Improvements being herein called the “Lessee Improvements Final Plans and Specifications”. All costs involved in approving, drafting and preparing the Lessee Improvements Final Plans and Specifications shall be charged against the Improvement Allowance described below. Except for immaterial field changes, modifications to the Lessee Improvements Final Plans and Specifications must be made and accepted only by written change order or agreement signed by Lessor and Lessee and will constitute an amendment to this Lease. Lessee shall be responsible for payment of all work and construction resulting from changes in the Lessee Improvements Final Plans and Specifications requested by Lessee prior to requesting reimbursement from the Improvement Allowance. The Lessee Improvements Final Plans and Specifications (when approved by Lessor and Lessee) are incorporated in this Lease by reference. For the purpose of this Section, an “immaterial field change” shall mean such field changes which are required by any governmental authority or changes which (i) do not affect the size, configuration, structural integrity, quality, character, architectural appearance and standard of workmanship contemplated in the Lessee Improvements Final Plans and Specifications, (ii) will not result in any default in any obligation to any person or violation of any governmental requirements, and (iii) the cost of or reduction resulting from any single field change or extra does not exceed $50,000 and the aggregate amount of all such changes and extras does not exceed $250,000.

• Project Site The “Project Site” is the place where the Work is being carried on.

• Notice to Proceed - Site Improvements The Recipient shall not commence, or cause to be commenced, any site improvements or other work on the Land until the Director has issued a Notice to Proceed to the Recipient. Such Notice to Proceed will not be issued until the Director is assured that the Recipient has complied with all requirements for the approval of a grant under Revised Code Sections 164.20 through 164.27 and has completed any land acquisition required by the Project. A Notice to Proceed shall be required for all Project prime contractors or direct procurement initiated by the Recipient following execution of this Agreement.